IN THE COURT OF APPEALS OF TENNESSEE
AT NASHVILLE
November 4, 2004, Session
HERMAN TAYLOR v. STATE OF TENNESSEE
Appeal from the Chancery Court for Davidson County
No. 00-209-II Carol L. McCoy, Chancellor
No. M2002-02608-COA-R3-CV - Filed March 17, 2005
This is an action for breach of contract filed by Plaintiff/Contractor against the State, together with
a Counterclaim and a Third-Party Complaint against the surety company for Plaintiff/Contractor.
The trial court granted partial summary judgment to Plaintiff as to liability because the State had
failed to comply with the requirements of Tennessee Rule of Civil Procedure 56 in answering
Plaintiff’s Motion for Summary Judgment. After much procedural combat, the trial court adhered
to its ruling on the Motion for Summary Judgment, dismissed the Third-Party Complaint against the
surety and the Counterclaim of the State against Plaintiff, held that Plaintiff had failed to prove any
damages against the State, and sustained the Motion of the State for an involuntary dismissal of
Plaintiff’s entire claim, taxing the costs to Plaintiff. We find that the trial court erred in granting
summary judgment to Plaintiff as to liability without considering documentation and evidence
submitted by the State subsequent to the initial non-final order granting partial summary judgment
as to liability. It follows that the court also erred in dismissing the Counterclaim and the Third-Party
Complaint against the surety. The grant of partial summary judgment as to liability is reversed, and
the case is remanded to the trial court for trial on the merits.
Tenn. R. App. P. 3; Appeal as of Right; Judgment of the Chancery Court Reversed
WILLIAM B. CAIN , J., delivered the opinion of the court, in which WILLIAM C. KOCH , JR., P.J., M.S.,
and HERSCHEL P. FRANKS, P.J., joined.
G. Kline Preston, IV, Nashville, Tennessee, for the appellant, Herman B. Taylor.
Paul G. Summers, Attorney General and Reporter; Michael Moore, Solicitor General; S. Elizabeth
Martin, Sr. Counsel; and William J. Marett, Jr., for the third-party appellants, State of Tennessee
and The Board of Regents.
Brett A. Oeser, Nashville, Tennessee, for the appellee, North American Specialty Insurance
Company.
OPINION
In this breach of contract action, it is necessary to set forth a detailed chronology of the
procedural history evidenced by the trial court proceedings.
Herman B. Taylor, d/b/a Herman Taylor Construction Company, filed suit on January 20,
2000, against the State of Tennessee and The Board of Regents in the Chancery Court of Davidson
County. His claim was based on a March 5, 1996, contract to renovate an addition to the Tennessee
Technology Center located in Dickson, Tennessee. He alleged negligence on the part of Defendants
because the architect improperly designed portions of the project causing delays in the project, as
well as additional expense. He further alleged that, on May 17, 1997, he was wrongfully terminated
and suffered damages in the amount of $736,323.53, for which he demanded judgment against
Defendants.
On April 5, 2000, Defendants answered asserting numerous defenses and essentially denying
any liability to Plaintiff. Defendants then asserted a Counterclaim against Plaintiff and a Third-Party
Complaint against North American Specialty Insurance Company, surety for Plaintiff on the project.
This Counterclaim asserted material breaches of contract by Plaintiff in failing to properly manage
the project, failing to provide qualified workers, failing to pay some subcontractors and suppliers,
and failing to abide by project scheduling. This Counterclaim and Third-Party Complaint asserted
that Plaintiff/Counter Defendant and Third-Party Defendant were jointly liable to the State for
damages in the amount of $1,045,351.50. On July 6, 2000, Herman Taylor and North American
Specialty Insurance Company answered these charges against them denying any liability to the State
of Tennessee.
On May 22, 2002, Plaintiff filed a Motion for Summary Judgment on the Counterclaim of
Defendant and on the issue of liability in Plaintiff’s Complaint. This Motion was supported by the
Affidavit of Herman Taylor together with a Statement of Undisputed Material Facts with specific
reference to the record to support such facts.
The response of the State to this Motion for Summary Judgment did not comply with the
provisions of Tennessee Rule of Civil Procedure 56, and such failure was of great concern to the trial
judge, as reflected in her Memorandum and Order of July 2, 2002 (“July 2, 2002 Order”). The trial
court observed:
On June 21, 2002, the State of Tennessee filed a response to the motion and the
affidavit of Jerry Preston. On June 24, 2002, the State filed another document that
purported to be an affidavit; it had no oath and therefore, was insufficient to
constitute an affidavit. Attached to this last filing was another document entitled
WMB Report and numerous exhibits. The attached exhibits were copies of
correspondence in 1997 between Mr. Taylor and the architect regarding various
disputes. On June 24, 2002, the State also filed a Response to Mr. Taylor’s
Statement of Material Facts Not In Dispute. This Response did not comply with
Rule 56.02. The State responded to many of Mr. Taylor’s facts by simply denying
the factual statement without reference to any specific part of the record. Many of
-2-
the responses stated “Denied. See WMB report.” In one instance, the State
responded to undisputed fact No. 14 as follows: “See response to Paragraph 14.” The
State’s response did not contain a specific reference to the record in order for the
Court to determine which facts supported its denial. The State filed no memorandum
of law to assist the Court in trying to utilize the material that the State had filed.
After discussing at length the shortcomings of the State’s response to the Motion for
Summary Judgment, the trial court held: “For the foregoing reasons and after careful review and
reconsideration of the record, partial summary judgment on the issue of liability is entered on behalf
of Mr. Taylor. Further, the State’s counterclaim alleging breach of contract and negligence on behalf
of Mr. Taylor is dismissed. The issue of damages shall be heard on July 29, 2002.”
It is from this point forward that the case becomes a procedural mine field. Having granted
partial summary judgment as to liability in favor of Plaintiff in its July 2, 2002 Order, the
corresponding dismissal of the State’s Counterclaim necessarily had to follow. As the grant of
partial summary judgment and the dismissal of the Counterclaim did not resolve all issues between
the parties, the July 2, 2002 Order could not be a final judgment in the absence of a Tennessee Rule
of Civil Procedure 54.02 designation, which was not contained in the July 2, 2002 Order.
North American Specialty Insurance Company was quick to respond to the July 2, 2002
Order when, on July 5, 2002, it filed a Motion to Dismiss asserting that, as a matter of law, the
Third-Party Complaint should be dismissed.
On July 17, 2002, the State filed a Tennessee Rule of Civil Procedure 60.02 Motion for
Relief from Judgment (“Rule 60.02 Motion”) seeking to have the July 2, 2002 Order set aside and
the case set for trial on its merits. This Rule 60.02 Motion was accompanied by extensive
evidentiary materials asserting material issues of disputed fact which were obviously intended to cure
the defects in the State’s response to the original Motion for Summary Judgment. These materials
included the Affidavit of Jerry Preston, an architect, to the effect that there was nothing wrong with
the architectural drawings in the contract and a 23-page response to Plaintiff’s Statement of
Undisputed Facts filed pursuant to Rule 56.03. This response disputes 30 of the 37 undisputed facts
asserted in Plaintiff’s Statement of Undisputed Facts.
Extensive briefing by the parties addressing the criteria for granting Rule 60.02 motions
preceded the hearing on July 22, 2002, resulting in an Order of August 21, 2002, (“August 21, 2002
Order”) of the trial court reaffirming its grant of partial summary judgment on the basis that:
The Court finds that Tennessee Rules of Civil Procedure Rule 60.02(5)
requires that clear and convincing evidence be submitted before Rule 60 relief can
be granted. The Court finds that the State of Tennessee and The Tennessee Board
of Regents have not submitted clear and convincing evidence in support of their
Motion. Therefore, it is ORDERED, DECREED, and ADJUDGED that the Rule
60.02(5) Motion is DENIED.
-3-
On August 22, 2002, the trial court entered another Order (“August 22, 2002 Order”) granting
the Motion of North American Specialty Insurance Company to dismiss the Third-Party Complaint
against it. However, this Order contained a finding pursuant to Rule 54.02 that the Order was final
as to North American Specialty Insurance Company and that there was no just reason for delay.
On that same day, the State filed its Motion to Revise Non-Final Order, or In the Alternative,
to Alter or Amend Final Judgment (“Motion to Revise”) regarding both the court’s grant of partial
summary judgment and dismissal of the Third-Party Complaint. This Motion to Revise was filed
pursuant to Tennessee Rule of Civil Procedure 54.02 and, in the alternative, 59.04. On September
13, the trial court heard the Motion to Revise and entered an Order on September 25, 2002
(“September 25, 2002 Order”), providing:
This cause came before the Court on the 13th day of September, 2002, upon
motion of the STATE OF TENNESSEE and the TENNESSEE BOARD OF REGENTS [State
Defendants], pursuant to TENNESSEE RULES OF CIVIL PROCEDURE 54.02 or, in the
alternative, Rule 59.04, seeking the Court to revise, or alter or amend, the order
granting Plaintiff partial summary judgment, and to alter or amend the Order
dismissing State Defendants’ claims against Defendant NORTH AMERICAN
SPECIALTY INSURANCE COMPANY , the responses in opposition to same of Plaintiff
and Counter-Defendant Herman B. Taylor and Defendant North American Specialty
Insurance Company, the arguments of counsel, and the entire record of this cause,
from all of which the Court finds as follows:
The oral ruling of the Court has been transcribed by a certified court reporter
and is attached hereto and incorporated by reference, as if fully set forth verbatim,
herein.
As to the merits of the State Defendant’s motion, the Court finds that neither
Rule 54 nor Rule 59 give this Court authority to consider State Defendants’
AMENDED AND SUPPLEMENTARY MEMORANDUM IN OPPOSITION TO PLAINTIFF’S
MOTION FOR SUMMARY JUDGMENT , RESPONSE TO PLAINTIFF’S STATEMENT OF
MATERIAL FACTS NOT IN DISPUTE , AFFIDAVIT OF KEN SWANN , Portions of the
DEPOSITION OF JERRY PRESTON taken on February 15, 2002, and AFFIDAVIT OF
JERRY PRESTON , submitted by State Defendants following the Court’s July 2, 2002
Order granting Plaintiff partial summary judgment.
Defendants State of Tennessee and Tennessee Board of Regent’s MOTION TO
REVISE NON -FINAL ORDER, OR IN THE ALTERNATIVE , TO ALTER OR AMEND FINAL
JUDGMENT is therefore, DENIED .
TENNESSEE RULES OF APPELLATE PROCEDURE 9 CERTIFICATION
-4-
The Court grants State Defendants’ oral motion for permission to appeal,
pursuant to Rule 9 of the TENNESSEE RULES OF APPELLATE PROCEDURE , its ORDER
granting Plaintiff partial summary judgment, dated July 2, 2002, and the Court’s
denials of State Defendants’ MOTION FOR RELIEF FROM JUDGMENT , pursuant to
TENNESSEE RULE OF CIVIL PROCEDURE 60.02, and the State Defendants’ MOTION TO
REVISE NON -FINAL ORDER , OR IN THE ALTERNATIVE , TO ALTER OR AMEND FINAL
JUDGMENT , pursuant to TENNESSEE RULES OF CIVIL PROCEDURE 54.02 or, in the
alternative, Rule 59.04, for the following reasons: (1) the need to prevent irreparable
injury, giving consideration to the severity of the potential injury, the probability of
its occurrence, and the probability that review upon entry of final judgment will be
ineffective; and (2) the need to prevent needless, expensive, and protracted litigation,
giving consideration to whether the challenged order would be a basis for reversal
upon entry of a final judgment, the probability of reversal, and whether an
interlocutory appeal will result in a net reduction in the duration and expense of the
litigation if the challenged order is reversed. The Court finds that if its prior rulings
are in error, then it should consider the previously not considered documents
submitted by State Defendants. If these documents had been properly before the
Court at the hearing on the motion for summary judgment, said documents may
contain facts that establish that there are questions of fact on the issue of liability
remaining, and that trial was necessary to resolve these matters. In addition, this
Court has previously held that its ORDER grating [sic] Defendant North American
Specialty Insurance company’s MOTION TO DISMISS is a final order, for which State
Defendants may file an appeal as of right. Therefore, to avoid duplicative litigation
and appeals, and to resolve all issues at once, it is in the interests of justice and
judicial economy that State Defendants be granted permission to file an interlocutory
appeal.
Such being the essential record in this case, the State filed its application, pursuant to
Tennessee Rule of Appellate Procedure 9, for an interlocutory appeal. This application was denied
by this Court on October 28, 2002, by Order (“October 28, 2002 Order”) asserting:
Having reviewed the application, we cannot conclude that an interlocutory
appeal is necessary to prevent needless, expensive and protracted litigation or to
prevent irreparable injury. However, the State defendants have filed a notice of
appeal from the final judgment dismissing their claims against North American, and
an appeal as of right from that order is, presumably, proceeding. We concur with the
trial court’s conclusion that resolving all issues at once will avoid duplicative
litigation and appeals and further the interests of justice and judicial economy.
Accordingly, the appeal as of right from the dismissal of the claims against North
American should be stayed pending entry of a final judgment regarding the remaining
claims between the plaintiff and the State defendants. Should an appeal be filed from
such a final judgment, it should be consolidated with the appeal from the dismissal
of the claims against North American.
-5-
The Rule 9 application of the State having been denied, the case was remanded for trial of the only
issue left between the parties, the amount of damages, if any, to be awarded to Mr. Taylor.
After a number of procedural struggles, the case came on for hearing on June 17, 2003, and,
on June 27, 2003, the trial court entered the following Final Order:
This cause having come before the Court on the 17th day of June, 2003, for
a hearing on the matter of Plaintiff’s damages by virtue of this Court’s prior ruling
on liability that arose out of a summary judgment sought by Plaintiff in which the
State Defendants failed to adequately respond to the motion.
Upon the close of Plaintiff’s proof, the State Defendants moved for an
involuntarily dismissal asserting that Mr. Taylor had failed to prove in any credible
way and with any certainty the damages that he asserted in his complaint. Due to this
Court’s prior ruling, Mr. Taylor was entitled, through an offer of proof, to submit any
documentation that might persuade the Court that he has damages for which he is
entitled to be compensated. The Court has been underwhelmed by the lack of any
documentation to support the allegations made by Mr. Taylor with regards to any
damages that he has sustained. Mr. Taylor’s testimony is all that he presented to the
Court in support of his damages claim.
The Court concludes that it cannot put any weight into Mr. Taylor’s testimony
and finds him to be not credible on the testimony with regards to damages. Based on
the evidence that has been submitted, it appears that Mr. Taylor was not forthright
in talking about his prior background. That was never explained, nor did his counsel
inquire into it to allow Mr. Taylor an opportunity to explain. Therefore the Court
finds that Plaintiff Herman Banks Taylor is the one and same person as identified in
the Department of Correction records. That proof weakens what credibility the Court
might have otherwise put in Mr. Taylor’s testimony, but was not the main factor
upon which the Court relied in determining the credibility of Mr. Taylor. Mr.
Taylor’s testimony could best be described as consisting solely of generalizations.
His memory was faulty. He was not consistent in his testimony. The figures that Mr.
Taylor testified to as to the amount that he is due were incomprehensible to the
Court. Mr. Taylor sought damages that have labels unknown to the Court.
Therefore, the Court finds that Mr. Taylor has not proven damages for unpaid
change orders. He has not proven any damages for what he asserts is a wrongful
termination. He has not proven any damages for delay, and in this instance, the Court
is unaware that one would recover damages for delay since this is a contract dispute,
and such requires liquidated damages which are capable of determination if proper,
reasonable evidence is submitted. Mr. Taylor has not proven other consequential
damages. There is no reliable proof in the record for which the Court can award Mr.
Taylor any lost profit.
-6-
Accordingly, at the close of Plaintiff’s proof, the Court granted State
Defendants’ motion for involuntary dismissal on all claims for unpaid change
orders, wrongful termination, delays, consequential damages, or lost profit.
The Court, however, found that there was a retainage account that was
accumulated by reserving five [5] percent of any moneys due Mr. Taylor when he
submitted an application for payment. The proof reflects that there were twelve [12]
applications for payment and that payments were made pursuant to those
applications, with a retainage amount of $115,021.58. Mr. Taylor takes the position
that his money was wrongfully retained by the State. At the close of Plaintiff’s proof,
the Court could not conclude that the State Defendants had clearly demonstrated that
the retainage was used to pay the subcontractors. Although it is clear is [sic] that
there was a retainage account and that the State took possession of those funds,
testimony as to how those funds were used had not been put into the record. State
Defendants were required to submit proof on this issue, and as to this issue, the Court
reserved its decision on the State Defendants’ motion for involuntary dismissal.
Having then heard the State Defendants’ proof as to how the retainage funds
were used, the Court finds that State Defendants have made a showing of specific
amounts that constitute liquidated damages that have been paid by State Defendants
and that these liquidated damages more than exceed the amount of the retainage that
was in the retainage account at the time of termination. The funds that were being
held in the retainage account for the contractor were used by State Defendants to pay
subcontractors and vendors who had completed work and who were entitled to be
compensated for that work. The Court further finds that the complaint acknowledges
that any moneys to which Mr. Taylor might be entitled in this lawsuit should be
reduced by any amounts paid by State Defendants on behalf of the plaintiff. The
retainage account was thus properly used in its entirety by State Defendants to pay
subcontractors and vendors, and Plaintiff is entitled to no recovery of any funds that
the State took possession of upon the termination of the contract.
Therefore, the Court finds that the State Defendants’ motion for an
involuntary dismissal of all of Plaintiff’s claims is appropriate. The Court
grants the motion for involuntary dismissal, enters a judgment in favor of the
State Defendants, and dismisses this action in its entirety.
Finally, the Court finds that the Plaintiff instituted this lawsuit and had the
primary burden of persuasion as to liability and with regards to proof of damages.
Once having prevailed on the issue of liability through the motion for summary
judgment, it was incumbent upon Mr. Taylor to put forth the very best case that he
could. Finding that the presentation of Plaintiff’s case was woefully lacking, the
Court concludes that the costs of this matter should be assessed solely against the
-7-
Plaintiff. The costs are assessed against the Plaintiff for which execution may
issue if necessary.
Since the State filed the first Notice of Appeal, it appears as the appellant in this Court, to
which everybody except the surety complains.
On appeal, the State asserts four issues for review:
1. Whether the Chancellor erred in granting Plaintiff’s Motion for Partial
Summary Judgment solely because State Defendant failed to fully comply with Rule
56 of the Tennessee Rules of Civil Procedure.
2. Whether the Chancellor erred in granting Summary Judgment to Plaintiff
who had not met his burden to establish that there was no genuine issue of material
fact and that he was entitled to judgment in his favor as a matter of law.
3. Whether the Chancellor abused her discretion by failing to consider
documentation submitted by State Defendants in Support of Motions under Rule 54
and Rule 59.
4. Whether the Chancellor’s grant of Summary Judgment to the surety should
be reversed.
Herman Taylor submits the following issues for review on appeal:
1. The Trial Court Did Not Err in Granting The Plaintiff’s Motion for
Summary Judgment.
2. The Trial Court Did Not Abuse Its Discretion In Allowing The State
Additional Time To Respond To The Motion For Summary Judgment.
3. The Trial Court Erred In Allowing The State To Setoff Damages.
4. The Trial Court Erred In Not Awarding Damages To Mr. Taylor For Delay
And Other Damages.
North American Specialty Insurance Company asserts the following issues on appeal:
I. Whether the Chancellor properly granted partial summary judgment,
dismissing the State’s counterclaim against Taylor, when Taylor established that he
was entitled to partial summary judgment, and the State failed to offer any evidence
to dispute his contention.
-8-
II. Whether, having properly dismissed the State’s counterclaim against
Taylor, the Chancellor properly dismissed the State’s third party claim against
NASIC.
III. Whether the Chancellor properly denied the State’s Motion for relief
under Rules 54.02 and 59.04, when the State failed to demonstrate that it was entitled
to such relief.
The difficulty facing this Court is that there was never a final judgment in this case until the
Final Order of the court on June 27, 2003. Neither a Rule 60.02 motion nor a Rule 59 motion will
lie prior to the entry of a final judgment. The grant of partial summary judgment to Plaintiff in the
July 2, 2002 Order left open for future disposition the issue of Plaintiff’s damages. In the absence
of a Rule 54.02 designation by the trial court, such a judgment is not “final” for any purposes.
Tennessee Rule of Civil Procedure 54.02 provides:
54.02. Multiple Claims for Relief. — When more than one claim for relief is
present in an action, whether as a claim, counterclaim, cross-claim, or third party
claim, or when multiple parties are involved, the court, whether at law or in equity,
may direct the entry of a final judgment as to one or more but fewer than all of the
claims or parties only upon an express determination that there is no just reason for
delay and upon an express direction for the entry of judgment. In the absence of such
determination and direction, any order or other form of decision, however designated,
that adjudicates fewer than all the claims or the rights and liabilities of fewer than all
the parties shall not terminate the action as to any of the claims or parties, and the
order or other form of decision is subject to revision at any time before the entry of
the judgment adjudicating all the claims and the rights and liabilities of all the
parties.
The difficulties started when the State filed its Rule 60.02 Motion rather than a motion to
revise under Rule 54.02. See Harris v. Chern, 33 S.W.3d 741 (Tenn. 2000). The parties and the trial
court, thereafter, took the Rule 60.02 Motion literally and applied the narrow construction rule
mandated by Toney v. Mueller Co., 810 S.W.2d 145 (Tenn. 1991) and NCNB National Bank of North
Carolina v. Thrailkill, 856 S.W.2d 150 (Tenn.Ct.App. 1993).
The issue is whether the affidavits demonstrate that the judgment entered was
based upon a “mistake” within the meaning of rule 60.02, Tenn.R.Civ.P., which
states in pertinent part:
On motion and upon such terms as are just, the court may relieve a
party or his legal representative from a final judgment, order or
proceeding for the following reasons: (1) mistake, inadvertence,
surprise or excusable neglect.
Rule 60.02 is not meant to be used in every case in which the circumstances
of a party change after the entry of a judgment or order. Nor is the rule a mechanism
-9-
for use by a party who is merely dissatisfied with the result of a particular case. Rule
60.02 is meant to be used only in those few cases that meet one or more of the criteria
stated. As recently stated by this Court, “Rule 60.02 acts as an escape valve from
possible inequity that might otherwise arise from the unrelenting imposition of the
principle of finality imbedded in our procedural rules.” Thompson v. Firemen’s Fund
Ins. Co., 798 S.W.2d 235, 238 (Tenn. 1990). Because of the importance of this
“principle of finality,” the “escape valve” should not be easily opened.
Toney, 810 S.W.2d at 146.
That the trial court applied this strict rule in disposing of the State’s Rule 60.02 Motion is
established in the August 21, 2002 Order wherein the court held: “The Court finds that Tennessee
Rules of Civil Procedure Rule 60.02(5) requires that clear and convincing evidence must be
submitted before Rule 60 relief can be granted.”
The Supreme Court held in Harris v. Chern:
Rule 54.02 requires that a judgment disposing of fewer than all of the claims
or fewer than all of the parties is final only when the trial court makes “an express
determination that there is no just reason for delay and upon an express direction for
the entry of judgment.” Tenn. R. Civ. P. 54.02. This determination is an “absolute
prerequisite” to a final judgment in such a case. Fox v. Fox, 657 S.W.2d 747, 749
(Tenn. 1983); Stidham v. Fickle Heirs, 643 S.W.2d 324, 325 (Tenn. 1982)
(addressing Rule 54.02 in its previous form at Tenn.Code Ann. § 27-305). The
record reveals no express determination of finality by the trial court in the initial
grant of summary judgment. Accordingly, the initial grant of summary judgment in
this case was non-final and was subject to revision until it was expressly made final
in accordance with Rule 54.02.
Harris, 33 S.W. 3d at 744.
The requirements of Rule 54.02 in this respect are so clear and unambiguous that
“construction” of these provisions is neither warranted nor necessary. Nonetheless, since the
provisions are identical to the provisions of Federal Rule of Civil Procedure 54, federal case law
interpreting the rule is persuasive authority in Tennessee. Bowman v. Henard, 547 S.W.2d 527, 530
(Tenn.1977); March v. Levine, 115 S.W.3d 892, 908 (Tenn.Ct.App. 2003).
In addressing the exact issue that is before this Court, the Fifth Circuit Court of Appeals held:
This partial summary judgment order did not even determine Avondale’s liability –
there being no determination either of fault on its part or of causation – much less
King’s damages, and hence was interlocutory and not appealable. Cf. Fed. R. Civ.
P. 56(c) (summary judgment on liability alone “interlocutory in character”). Not only
-10-
is such an order not appealable, but it remains within the plenary power of the district
court to revise or set aside in its sound discretion without any necessity to meet the
requirements of Fed. R. Civ. P. 60(b).
Avondale Shipyards, Inc. v. Insured Lloyd’s, 786 F.2d 1265, 1269 (5th Cir. 1986).
The Fifth Circuit Court of Appeals again addressed the question in circumstances markedly
similar to the case at bar.
The district court allowed Chevron to file a motion for summary judgment,
granted the motion, but deferred the question of amount to allow the parties an
opportunity to reach an agreement. The judgment was only partial, the court
reserving the jurisdiction over the unresolved issues. “An order of a district court
granting partial summary judgment which leaves claims to be adjudicated may
constitute a final order ‘only upon an express determination that there is no just
reason for delay and upon an express determination for the entry of judgment’.”
Eudy v. Motor Guide, Herschede Hall Clock Co., 604 F.2d 17, 18 (5th Cir. 1979),
Fed.R.Civ.P. 54(b), Gonzales v. Texas Employment Commission, 563 F.2d 776, 777
(5th Cir. 1977). There was no rule 54(b) certification rendering the judgment final in
the instant case. Oil Well’s cross claims, filed three months after the partial summary
judgment, were filed while the matter was still within the jurisdiction of the district
court. The motion was timely file. The contention of Teledyne that Oil Well was not
a party to the action is devoid of merit. Oil Well was brought in as a third party
defendant. Its attorney was present throughout the trial of the main demand.
Hobbs v. Teledyne Movible Offshore, Inc., 632 F.2d 1238, 1240 (5Th Cir. 1980).
Since the trial court’s July 2, 2002 Order contained no Rule 54.02 designation of finality, it
was not a final order for any purposes under the express provisions of that rule. Treating the Rule
60.02 Motion as, in fact, a motion to revise under Rule 54.02, See Harris, 33 S.W.3d at 744, and
Savage v. Hildenbrandt, No. M1999-00630-COA-R3-CV, 2001 WL 1013056 (Tenn.Ct.App. Sept.
6, 2001), the merits of the Rule 60.02 Motion should have been subjected to the Harris analysis
rather than the Rule 60.02 analysis. Further, the August 21, 2002 Order overruling the Rule 60.02
Motion of the State was no more a final order than the July 2, 2002 Order. It contained no Rule
54.02 designation of finality, and the issue of damages remained to be tried.
So it is that the State’s August 22, 2002, Motion to Revise cannot be considered, at least as
to the State and Herman Taylor, to be a Rule 59.04 motion. As to those parties, it will be treated as
another Rule 54.02 motion since the August 21, 2002 Order lacked finality. Since the August 22,
2002 Order dismissing North American Specialty Insurance Company did, in fact, contain a Rule
54.02 designation of finality, the State was left with little alternative but to file the August 22 Motion
to Revise alternatively under Rule 59.04 in order to protect its rights against the surety.
-11-
In its September 25, 2002 Order denying both the State’s Rule 54.02 motion and its
alternative Rule 59.04 motion contained in the Motion to Revise, the trial court held:
As to the merits of the State Defendants’ Motion, the Court finds that neither
Rule 54 nor Rule 59 give this Court authority to consider State Defendants’
AMENDED AND SUPPLEMENTARY MEMORANDUM IN OPPOSITION TO PLAINTIFF’S
MOTION FOR SUMMARY JUDGMENT , RESPONSE TO PLAINTIFF’S STATEMENT OF
MATERIAL FACTS NOT IN DISPUTE , AFFIDAVIT OF KEN SWANN , Portions of the
DEPOSITION OF JERRY PRESTON taken on Feb. 15, 2002, and AFFIDAVIT OF JERRY
PRESTON , submitted by State Defendants following the Court’s July 2, 2002 Order
granting Plaintiff partial summary judgment.
The trial court is in error in so holding. No final judgment had yet been entered, and it is
clear that “Rule 54.02 confers upon the trial court ‘the privilege of reversing itself up to and
including the date of entry of a final judgment’”. Harris, 33 S.W.3d at 744.
The true test applicable under these conditions is set forth clearly by the Supreme Court.
When additional evidence is submitted in support of a Rule 54.02 motion to
revise a grant of summary judgment, a trial court should consider, when applicable:
1) the movant’s efforts to obtain evidence to respond to the motion for summary
judgment; 2) the importance of the newly submitted evidence to the movant’s case;
3) the explanation offered by the movant for its failure to offer the newly submitted
evidence in its initial response to the motion for summary judgment; 4) the likelihood
that the nonmoving party will suffer unfair prejudice; and 5) any other relevant
factor.
Accordingly, we hold that the “newly discovered evidence” standard need not
be satisfied before a trial court revises a partial summary judgment under Rule 54.02
on the basis of additional evidence. When additional evidence is offered by a litigant
to overcome a grant of summary judgment pursuant to Rule 54.02, trial courts must
undertake the above-stated balancing analysis and should make adequate findings of
fact and conclusions of law on the record to support their rulings.
Harris, 33 S.W.3d at 745 (citations omitted). Just as the “newly discovered evidence” standard need
not be satisfied before a trial court revises a partial summary judgment under Rule 54.02 on the basis
of additional evidence, so the restrictive standard of Rule 60.02 does not have to be met as to such
additional evidence.
It is clear, therefore, that as in Harris, the grant of partial summary judgment in this case
must be reversed. We perceive no reason, however, to remand the case as was done in Harris for
further trial court consideration of the post-partial summary judgment evidence presented by the
State. In the Order of September 25, 2002 granting the Tennessee Rule of Appellate Procedure 9
-12-
Interlocutory Appeal, the trial court asserted, “If these documents had been properly before the Court
at the hearing on the motion for summary judgment, said documents may contain facts that establish
that there are questions of fact on the issue of liability remaining, and that trial was necessary to
resolve these matters.” The evidence on which the trial court spoke is in the record and before this
Court for appellate review. It is clear from the evidence presented that disputed questions of material
fact as to liability exists and summary judgment as to that issue was improperly granted.
When this Court entered its October 28, 2002 Order denying the State’s application for a
Rule 9 interlocutory appeal, we recognized the procedural problems resulting from the trial court’s
designation of finality in its August 22, 2002 Order dismissing the Third-Party Complaint against
North American Specialty Insurance Company. We held, “Accordingly, the appeal as of right from
the dismissal of the claims against North American should be stayed pending entry of a final
judgment regarding the remaining claims between the plaintiff and the State defendants.” Since the
dismissal of the Counterclaim of the State against Plaintiff and the dismissal of the Third-Party
Complaint against North American were predicated upon the erroneous grant of partial summary
judgment to the Plaintiff as to the liability of the State, it follows that the dismissal of the
Counterclaim and the Third-Party Complaint must be reversed.
This leaves us with the very troublesome problem of the issues asserted on appeal by
Plaintiff, Herman Taylor. With the State’s Counterclaim and the Third-Party Complaint against the
surety effectively removed from the case by the July 2, 2002 Order granting partial summary
judgment to Plaintiff as to liability, the case proceeded on the issue of Plaintiff’s damages in a
hearing on June 17, 2003. The burden was upon Plaintiff to establish his damages, and the level of
frustration besetting the trial court is reflected in its Final Order of June 27, 2003, wherein the
defendant’s Motion for Involuntary Dismissal was sustained.
In the present state of the record, efforts to effect proper appellate review are an exercise in
futility. Between the rulings of the trial court limiting the scope of evidence because of Plaintiff’s
failure to make proper discovery and the near total failure to correlate the uncorraborated testimony
of Herman Taylor with the myriad of exhibits offered, we are unable to make sense out of the record
on appeal.
What was bound to happen was clearly foreseen by the trial court prior to the beginning of
Mr. Taylor’s testimony. The record reflects:
THE COURT: All right. Let’s do that then.
This is a motion in limine filed by the State to enter an order
prohibiting the plaintiff from relying upon any documentation obtained from Jerry
Preston or Ken Swann pursuant to the subpoena served after the June 6, 2003
hearing.
With regards to the plaintiff’s offer of proof, the plaintiff is
entitled, based on my prior ruling, to make an offer of proof with regards to the
-13-
documents that the plaintiff has as to how he calculated his damages. The documents
should be the ones that were used to prepare the summary statements.
At the time that we were here before, I inquired as to how the
summaries were prepared. Mr. Preston, you advised me that either you or someone
in your office had used the documents available to you to prepare those summaries.
It is my expectation through that order that you will be allowed
to make an offer of proof.
Typically, an offer of proof is made with me off of the bench.
I think under these circumstances I may have to stay on the bench. But you will be
allowed to do that. However, you are only going to be allowed to do that in the same
way that you prepared the summaries, and that is either through your witnesses or
your assistant or whoever helped you and the documents that were available to you
in your office, because that was the intent of the offer of proof.
You brought to the deposition these summaries as to how you
calculated the damages. Mr. Marett had a right to explore how that was done. And
he had requested that whatever documents you intended to rely upon be brought to
the deposition. For reasons unbeknownst to me, that was not done.
As a consequence, I am not going to permit documents that
were not identified in the deposition to be introduced now. That’s not the proper way
to conduct discovery. The State had requested all of the documents. They had a right
to do it. All the documents were presented to Ms. Steele. They were not Bates
stamped. They were not identified. They weren’t collated. They weren’t segregated.
They were just delivered.
In order to be able to determine and make sense out of these
documents, Mr. Marett wanted to depose your client and asked him to bring the
documents that had been furnished. I suspect that Mr. Marett had all the documents
and tried to make some sense out of them before he wanted to depose your clients.
But your client needed to bring those records to the deposition, and he didn’t.
You asserted that you had prepared these summaries, and it is
on that basis that he filed his motion for sanctions. I’ve made the ruling. At this time
I am going to grant the order that with regards to your proof that may be submitted
pursuant to my ruling and that is whatever documentation you intend to supply as an
offer of proof will not be through Jerry Preston or Ken Swann since they did not help
you prepare the summaries.
-14-
MR. PRESTON: Your Honor, does that address – your order
talked about the documents which were identified. And the ones that I am concerned
about are the ones that – payment applications which we submit don’t fall under that
category, because they were in the summaries specifically identified by number. I
don’t think there’s any question those were in the State’s possession at the time and
should not, therefore, be excluded.
Is it your ruling that those documents are excluded even
though they were identified?
THE COURT: Mr. Preston, you’ve asked me a question that
I’m going to have to have a little more assistance on before I can answer, but I would
like to do these things in an orderly fashion. So what I’ve got right now is the motion
in limine to prohibit the plaintiff from relying on any documentation obtained from
Jerry Preston or Ken Swann pursuant to the subpoenas. That’s the ruling.
The answer is yes, I am going to prohibit you from relying on
any documentation obtained from Jerry Preston or Ken Swann pursuant to the
subpoenas. All right. I have just gone through all the documents that you requested,
and by and large it looks like you have most of those documents in your possession.
You will not be able to call Ken Swann or Jerry Preston to the stand during your offer
of proof.
Now, with regards to the question that you just posed to me,
you have – and Mr. Marett not quite as long – been involved in this lawsuit. I am
basically uneducated with regards to the facts in this lawsuit. I have minimal
knowledge of this lawsuit, and it is for a variety of reasons.
When the motion for summary judgment was filed, you
benefited [sic] because Ms. Steele was in a position that she did not properly respond
to the motion for summary judgment. I was unable to go through all the documents
that she filed and make sense of them.
You now ask me a question about documents that I have not
been able to make sense of because I haven’t had the time nor have I had the benefit
of preliminary motions that would facilitate my understanding of what pay
application documents are versus the equipment and fuel cost/loss of productivity
documents or the documents that purport to represent delays caused due to
architectural errors. I have no idea how to segregate whatever documents there are
and how to answer your question as to what you mean when you say, “Do the pay
application documents fall under a certain category for exclusion or inclusion?”
-15-
If I knew what the documents were, if I had the ability to look
at them and read them – and I really do take the time, if it’s presented in a proper
way, to try and understand what the proof will be either before trial or during trial.
I know what a pay application looks like, but it’s not my duty to ferret it out.
I don’t know that I could clearly say what is an equipment
documentation or a fuel cost documentation if they are all run together. I know what
a bill looks like for gas; I could do that. But that’s not my responsibility. And that’s
why I say you have an uneducated judge sitting here, because I don’t have the benefit
of any preliminary motions that help me gain an understanding of what the
documents are that are going to be tendered to prove the damages. And that is of
concern to me.
Proving liability is only one half of a lawsuit. The other half
of a lawsuit is proving the damages to which you are entitled. This is a very
important portion of the lawsuit.
For all practical purposes, the only evidence offered by Plaintiff was the testimony of Mr.
Taylor, and quite apart from the credibility issues from which he suffered in the trial court, his
testimony demonstrated a rather marked lack of familiarity with his own records and, by and large,
was couched in abstract generalities.
On appeal of the damages issues, we are left in something of a quandary. Based on the record
we have, it would be easy enough to sustain the action of the trial court in the involuntary dismissal
of Plaintiff’s claim because of the total failure of his proof as to damages. We have a case, however,
which must go back to the trial court for further proceedings because of errors, not all of which can
be laid at the door of Plaintiff. It was, after all, the State of Tennessee that filed the grossly
inadequate response to Plaintiff’s Rule 56 Motion for Summary Judgment and, after the partial
summary judgment was granted, responded with a Rule 60.02 Motion. The trial court, taking its cue,
in part, from the State’s Rule 60.02 Motion, applied the restrictive criteria of a Rule 60.02 motion
rather than the criteria of Harris v. Chern under Rule 54.02. The resulting overruling of the State’s
Rule 60.02 Motion under those restrictive criteria buttressed the erroneous dismissal of the
Counterclaim and the Third-Party Complaint. Sending the case back to the trial court for trial on the
Counterclaim and the Third-Party Complaint without regard to Plaintiff’s allegation of damages
involves a less-than-satisfactory result.
This court has the statutory power to remand cases when we determine that
complete justice cannot be done on appeal and when the record indicates that more
satisfactory evidence can be presented which will enable the trial court to render a
more just decision. See Tenn. Code Ann. § 27-3-128 (1980); Haury and Smith
Realty Co. v. Piccadilly Partners I, 802 S.W.2d 612, 616 (Tenn.Ct.App. 1990).
State ex rel. Vaughn v. Kaatrude, 21 S.W.3d 244, 250 (Tenn.Ct.App. 2000).
-16-
We choose to vacate the judgment as to Plaintiff’s damages and remand the case to the trial
court for trial on all issues made by the pleadings. Such proceedings on remand will be without
prejudice to the trial court’s previous ruling relative to Plaintiff’s failure in response to discovery.
We might add that, if Plaintiff cannot do something to improve the quality of his proof as to
damages, the road ahead is effectively blocked.
The judgment of the trial court is reversed, and the case is remanded for further proceedings
consistent with this opinion.
Costs of the cause are taxed equally to Herman Taylor and the State of Tennessee.
___________________________________
WILLIAM B.CAIN, JUDGE
-17-