FILED
United States Court of Appeals
Tenth Circuit
July 8, 2008
PUBLISH Elisabeth A. Shumaker
Clerk of Court
UNITED STATES COURT OF APPEALS
TENTH CIRCUIT
MORRISON KNUDSEN CORPORATION,
doing business as MK-Ferguson Company,
now known as Washington Group
International, Inc., an Ohio corporation,
Plaintiff/Counter-Defendant -
Appellant/Cross-Appellee,
v. Nos. 06-1434, 06-1435
and 06-1463
GROUND IMPROVEMENT
TECHNIQUES, INC., a Florida corporation,
Defendant/Counter-Claimant -
Appellee/Cross-Appellant,
____________________________
FEDERAL INSURANCE COMPANY,
Interested Party -
Appellant/Cross-Appellee.
APPEAL FROM THE UNITED STATES DISTRICT COURT
FOR THE DISTRICT OF COLORADO
(D.C. NO. 95-CV-2510-JLK-BNB)
Daniel R. Frost, Holland & Hart LLP, Denver, Colorado, and Jeffrey S. Price,
Manier & Herod, PC, Nashville, Tennessee (Joseph W. Halpern, Timothy W.
Gordon, and Anthony J. Navarro, Holland & Hart LLP, Denver, Colorado; L. Jay
Labe, Pendleton, Friedberg, Wilson & Hennessey, P.C., Denver, Colorado; and
Sam H. Poteet, Jr., Manier & Herod, PC, Nashville, Tennessee, with them on the
briefs), for Plaintiff/Counter-Defendant - Appellant/Cross-Appellee and Interested
Party - Appellant/Cross-Appellee.
Steven R. Schooley, Holland & Knight, Orlando, Florida (Frederick Huff, Law
Offices of Frederick Huff, Denver, Colorado, with him on the briefs), for
Defendant/Counter-Claimant - Appellee/Cross-Appellant.
Before BRISCOE, EBEL, and MURPHY, Circuit Judges.
MURPHY, Circuit Judge.
I. INTRODUCTION
Morrison Knudsen Corporation (“MK”), a federal contractor, terminated its
subcontractor, Ground Improvement Techniques, Inc. (“GIT”) for an alleged
default and sued GIT for damages. GIT counterclaimed for wrongful termination.
The case initially went to trial in November of 1996. Concluding the termination
was wrongful, the jury awarded GIT $5.6 million. The case was appealed to this
court in Morrison Knudsen Corporation v. Fireman’s Fund Insurance Company
(Morrison Knudsen I), 175 F.3d 1221 (10th Cir. 1999). In connection with the
appeal, MK and its surety, Federal Insurance Company (“Federal”) posted a
supersedeas bond. In Morrison Knudsen I, we affirmed liability, but reversed and
remanded to the district court on the issue of damages.
Following a retrial on damages, GIT was awarded over fifteen million
dollars. The district court held Federal and MK jointly and severally liable for
the amount of the supersedeas bond. MK and Federal appeal from that judgment,
-2-
arguing the supersedeas bond was discharged and is now void. MK also
challenges the district court’s award of prejudgment interest; alleges that the
damages award contains duplication; and claims, as a matter of law, the district
court should have entered judgment for MK on claims relating to R.N. Robinson
& Son, Inc. (“Robinson”), Fireman’s Fund, and an equitable adjustment claim on
a performance bond. GIT cross-appeals, arguing the district court applied
incorrect interest rates in its calculation of prejudgment and post-judgment
interest. It also contends MK and Federal should be jointly and severally liable
for the entire judgment. Our appellate jurisdiction arises under 28 U.S.C. § 1291.
We affirm in part, reverse in part, and remand for further proceedings consistent
with this opinion.
II. BACKGROUND
This appeal arises out of a long-standing contract dispute between MK 1 and
GIT. In 1983, the United States Department of Energy hired MK to manage its
Uranium Mill Tailing Remedial Action project, a cleanup of radioactive mill
tailings at sites around the country. MK subcontracted with GIT (the “contract”)
in March 1995 to clean up the Slick Rock, Colorado site. GIT hired several
lower-tier subcontractors (“subs”), including Robinson, for excavation; Bogue
Construction, for trucks; Keers Environmental, Inc., for asbestos abatement; and
G.A. Western Construction Co., for bridge work.
1
MK is now known as Washington Group International, Inc.
-3-
The project did not go well. GIT and its subs encountered delays,
difficulties, and increased costs. GIT attributed these to MK’s defective
specifications, failure to timely secure permits, rigid interpretation of
specifications and safety requirements, and propensity to reject work plans. In
September 1995, MK terminated GIT for default and simultaneously sued GIT for
damages. GIT counterclaimed for wrongful termination, seeking damages in the
form of payment for completed work under the contract and compensation for
additional costs occasioned by MK and not contemplated under the contract.
The case went to trial in November of 1996. The jury concluded MK’s
termination of GIT was wrongful and awarded GIT $5.6 million. MK
unsuccessfully moved for judgment as a matter of law, claiming deficiencies in
GIT’s evidence of damages and of MK’s liability. The case was then appealed to
this court in Morrison Knudsen I, 175 F.3d at 1221. In connection with the
appeal, MK posted a supersedeas bond for $7,075,000 through its surety, Federal.
Although this court affirmed the ruling on liability, we reversed the damage
award because GIT failed, in several categories of damages, to present sufficient
evidence. Id. at 1243-48, 1260-61. Further, because the jury returned a general
verdict, this court was unable to determine whether any parts of the jury award
were allowable categories of damages supported by sufficient evidence. Id. at
1254-55. We thus vacated the judgment and remanded for a new trial limited to
the issue of damages. Id. at 1255.
-4-
The issue of damages was retried in May 2006. The jury awarded GIT over
fifteen million dollars in costs and equitable adjustments. 2 Following post-verdict
motions culminating in an August 16, 2006 hearing, the district court entered
judgment in favor of GIT in the amount of $15,644,582. The district court ruled
MK and Federal were jointly and severally liable for the judgment, up to the
amount of the bond. Prejudgment interest was awarded at the federal rate of
5.09% accruing from the date of termination. The district court also awarded
post-judgment interest to accrue at a rate of five percent per annum. These
appeals followed.
III. SUPERSEDEAS BOND
Following the first trial, a judgment of $5.6 million was awarded to GIT.
This judgment was ultimately amended to $6,132,837.70 to include prejudgment
interest and costs. On December 11, 1996, MK filed a motion to stay the
execution of the judgment pending appeal. The district court granted the motion,
conditioned on MK tendering a supersedeas bond with a penal sum of seven
million dollars. Thereafter, MK as principal and Federal as surety tendered
Supersedeas Bond No. 8131-18-24 (“Supersedeas Bond”) to the court for the
2
An equitable adjustment is a real or constructive change in contract price.
It compensates a contractor for increased costs reasonably incurred because the
government increased the amount or difficulty of work required by the contract or
delayed or accelerated that work. Morrison Knudsen Corp. v. Fireman Fund Ins.
Co. (Morrison Knudsen I), 175 F.3d 1221, 1243-44 (10th Cir. 1999).
-5-
purpose of ensuring the judgment would be collectible during the stay. On May
13, 1999, the court ordered the bond to be increased by $75,000.
The Supersedeas Bond states:
[T]he condition of this obligation is that if the appellant shall
prosecute this appeal to effect and shall satisfy the judgment in full,
together with costs, interest, and damages for delay if the appeal is
finally dismissed or if the judgment is affirmed or shall satisfy in full
such judgment as modified together with such costs, interest, and
damages as the Court of Appeals may adjudge and award, this
obligation shall be void; otherwise it shall remain in full force and
effect.
Following the second trial, GIT submitted its suggested “Modified
Amended Judgment” requesting judgment against Federal and MK jointly and
severally for the amount of the bond. Federal filed a brief in opposition to the
entry of a modified judgment and a motion for an order discharging the
Supersedeas Bond, arguing the bond became void when Morrison Knudsen I was
issued on May 11, 1999. MK joined Federal’s motion. The district court
concluded Federal’s obligations had not been discharged, characterizing Morrison
Knudsen I as remanding for a quantification of amounts due to GIT. On appeal,
MK and Federal ask this court to hold the bond was discharged. Cross-appealing,
GIT seeks a ruling that Federal is jointly and severally liable for the entire
judgment, an amount far in excess of the $7,075,000 penal sum of the bond. We
hold Morrison Knudsen I did not discharge the Supersedeas Bond and it is still in
effect. Federal’s liability, however, is limited to the penal sum of the bond.
-6-
A. Effect of Morrison Knudsen I on Supersedeas Bond
The question we must answer is whether Morrison Knudsen I, affirming
MK’s liability, but vacating the judgment and remanding for a new damages trial,
resulted in MK prosecuting the appeal “to effect.” If so, Federal cannot be held
liable for the judgment against MK and its obligations are void. The proper
standard of review of the district court’s interpretation of a bond depends on
whether the bond is unambiguous. Where, as here, the contract is unambiguous,
“a trial court’s interpretation of a contract presents an issue of law which is
reviewed de novo on appeal.” Milk ‘N’ More, Inc. v. Beavert, 963 F.2d 1342,
1345 (10th Cir. 1992) (quotation and alteration omitted); see also Grubb v. Fed.
Deposit Ins. Corp., 833 F.2d 222, 224 (10th Cir. 1987) (explaining question of
whether supersedeas bond should be exonerated is a question of law). 3
This court has not had occasion to interpret the “prosecute this appeal to
effect” language contained in the Supersedeas Bond. The Supreme Court,
interpreting similar language in 1879, explained “[i]f, on the final disposition of a
writ of error on appeal, the judgment or decree . . . is not substantially reversed
. . . [the] appeal has not been prosecuted with effect.” Gay v. Parpart, 101 U.S.
3
When a district court relies on extrinsic evidence to interpret an ambiguous
contract, this court reviews for clear error. Valley Nat’l Bank v. Abdnor, 918 F.2d
128, 130 (10th Cir. 1990). The question of whether a contract is ambiguous is a
question of law that is reviewed de novo. King v. PA Consulting Group, Inc., 485
F.3d 577, 589 (10th Cir. 2007). Neither party argues the Supersedeas Bond is
ambiguous. After our review, we conclude the bond is only susceptible to one
interpretation and is thus unambiguous.
-7-
391, 392 (1879); see also Crane v. Buckley, 203 U.S. 441, 447 (1906) (explaining
“prosecuting to effect” means “prosecuting his appeal with success; to make
substantial and prevailing his attempt to reverse the decree or judgment awarded
against him”).
Thus, our task is to determine if MK “substantially prevailed” in Morrison
Knudsen I. In Beatrice Foods v. New England Printing, the Federal Circuit
explained:
when an appellee has proven that damages are due, and the remand is
merely to determine the proper quantum of injury, then it is not
unreasonable that the bond remain effective during this recalculation
period. Put another way, when an appellant has merely succeeded in
having the case remanded for recomputation of damages, it would be
a stretch to say that the appeal was ‘substantially’ successful, or that
the judgment was ‘substantially’ reversed.
930 F.2d 1572, 1576 (Fed. Cir. 1991); see also Franklinville Realty Co. v. Arnold
Constr. Co., 132 F.2d 828, 829 (5th Cir. 1943) (surety remained liable where
remand was to determine whether the judgment “should be for the same or a less
sum”). Where, however, the damage award is reversed and the plaintiff must
prove damages, courts have held the surety’s obligations are discharged. Neeley
v. Bankers Trust Co. of Texas, 848 F.2d 658, 659-60 (5th Cir. 1988) (holding
appellant prosecuted appeal to effect where court of appeals ordered retrial
because plaintiff failed to prove damages).
Summarizing the approach taken by the regional circuits, the Beatrice
Foods court explained:
-8-
[T]he surety remains liable when the question on remand is not
whether a party will receive damages, but merely how the damages
will be calculated. . . . If, after an appeal, there remains a question
of whether any compensable harm was done, then the bond may be
allowed to lapse. When the plaintiff has yet to prove any damages, it
is unnecessary and unfair to ask the defendant to continue to provide
a bond to ensure that money will be available should damages be
proven. An appeal has been prosecuted to effect, then, when
appellee must still prove on remand that he suffered a compensable
harm.
930 F.2d at 1576.
The parties, not surprisingly, interpret differently the effect of Morrison
Knudsen I. MK and Federal argue this court’s decision substantially reversed the
district court because the judgment was entirely vacated. They contend that on
remand, this court required damages to be proven, not just recalculated. GIT, on
the other hand, submits MK lost the major battle on appeal when this court
affirmed liability. Although the judgment was vacated, MK remained liable for
undisputed obligations covered by the Supersedeas Bond. Had the jury used a
special verdict form in the first trial, this court would have upheld any jury award
for contract sums never paid.
MK and Federal rely heavily on Neeley and its progeny. In that case, the
Fifth Circuit affirmed liability but reversed on the issue of damages. 848 F.2d at
659. The case was remanded for a new trial on damages. Id. The court
explained because the entire award of damages had been vacated by the appellate
court, no liability remained on the supersedeas bond. Id. at 660. “The retrial on
-9-
damages results in an entirely new judgment. The bond is limited to any decree
of the court of appeals; it does not include an entirely new judgment of the
district court.” Id. Neeley explained the language of the bond at issue in that
case limited liability to amounts affirmed in an appellate decree. 4 Id.; see also
Aetna Cas. & Sur. Co. v. LaSalle Pump & Supply Co., 804 F.2d 315, 317-18 (5th
Cir. 1986) (holding surety’s liability discharged when original judgment
reversed). As there was no decree to enforce, the surety could not remain liable.
Id.
We do not read the language of the Supersedeas Bond to limit liability to
amounts explicitly affirmed on appeal. The purpose of a supersedeas bond “is to
secure the judgment throughout the appeal process against the possibility of the
judgment debtor’s insolvency.” Grubb, 833 F.2d at 226. Although this court
remanded for a retrial on the issue of damages, we affirmed the judgment finding
MK’s termination of GIT was wrongful. Morrison Knudsen I, 175 F.3d at 1261.
We held, however, that GIT failed to prove entitlement to specific categories of
damages. GIT claimed roughly $11.35 million in damages at the first trial. Id. at
1242. The categories of damages included equitable adjustments ($3 million),
4
The supersedeas bond in Neeley stated, “Appellants shall prosecute their
appeal with effect; and in case the Judgment of the United States Court of
Appeals or the United States Supreme Court shall be against them, they shall
perform its judgment, sentence or decree, and pay all such damages as said Court
may award against them.” Neeley v. Bankers Trust Co. of Texas, 848 F.2d 658,
659 (5th Cir. 1988).
-10-
lower-tier subcontractor claims ($3.7 million), attorney’s fees ($1.35 million),
unpaid contract work and post-termination equipment expenses and work ($1.9
million), and other ($1.4 million). Id. This court held GIT failed to offer
sufficient evidence to support its claims for the equitable adjustments, attorney’s
fees, and most of the damages claimed on behalf of the sub-contractors. Id. at
1242-54. We explained that because the district court failed to use a special
verdict form, it was impossible to untangle the categories of damages for which
there was sufficient evidence as compared to those which needed a retrial. Id. at
1254. Had a special verdict form been used, “[w]e could then vacate any award
of damages on the attorney’s-fees, equitable-adjustment, and subcontractor
claims, while letting stand any amounts the jury had awarded on GIT’s other
claims.” Id.
Unlike Neeley, this court recognized GIT was entitled to some form of
damages. It was prevented, however, from affirming those portions of the
judgment based solely on the district court’s failure to use a special-verdict form.5
In the first trial, GIT successfully proved certain damages were due. Morrison
Knudsen I, 175 F.3d at 1243 n.28 (“The parties do not seem to dispute GIT’s right
to damages for work that the contract required, and that GIT performed, but for
which MK did not pay.”); Id. at 1242 n.25 (“MK does not specifically challenge
5
Although the judgment with respect to damages was vacated in Morrison
Knudsen I, this alone is not the touchstone of prosecuting an appeal “to effect.”
Beatrice Foods, 930 F.2d at 1573 (original damage award vacated).
-11-
the sufficiency of the evidence supporting GIT’s claimed damages, totaling
roughly $1.9 million, for work performed under the contract for which MK
withheld payment; for work MK required it to perform after the termination; and
for equipment MK required it to leave on site after the termination.”). Thus, we
cannot say that MK “substantially prevailed” on its first appeal. This case’s
unique procedural history reflects that MK’s liability was affirmed and several
categories of damages, although not affirmed, were vacated merely because of a
procedural error. This case lies somewhere between a remand for mere
recalculation of damages, i.e., Beatrice Foods, 903 F.2d at 1576, and one in
which no sum of damages was properly proved and the entire judgment was
vacated, i.e., Neeley, 848 F.2d at 660. Because GIT proved entitlement to some
damages in the first trial, this case is more like Beatrice Foods and less like
Neeley. See, e.g., Beatrice Foods, 930 F.2d at 1576 (explaining surety is released
only when there remains a question of whether any compensable harm was done).
We hold, therefore, that the Supersedeas Bond is still enforceable because MK
failed to prosecute its appeal “to effect.”
B. Joint and Several Liability
In its cross-appeal, GIT argues MK and Federal are jointly and severally
liable for any and all amounts awarded in this litigation. The terms of the bond
include coverage for “such judgment as modified together with such costs,
interest, and damages as the Court of Appeals may adjudge and award.” GIT
-12-
interprets this language to bind Federal for any and all amounts awarded in this
matter. This argument ignores one of the most fundamental rules of suretyship:
except in limited circumstances, a surety’s liability cannot extend beyond the
penal sum announced in the bond. 6 See Maryland Cas. Co. v. Alford, 111 F.2d
388, 390 (10th Cir. 1940) (“Under the great weight of authority, a surety’s
liability is limited by the penal sum named in the bond . . . .”); see also Houston
Fire & Cas. Ins. Co. v. E.E. Cloer Gen. Contractor, Inc., 217 F.2d 906, 912 (5th
Cir. 1954) (“The surety’s obligation is of course limited to the penal sum named
in the bond.”); Mass. Bonding & Ins. Co. v. United States, 97 F.2d 879, 881 (9th
Cir. 1938) (“It is fundamental in the law of suretyship that a bondsman cannot be
held for any default of his principal in an amount greater than the penal sum of
the bond.”). The penal sum of the bond was $7,075,000 and Federal’s obligations
are thus capped at that amount. 7
6
Such limited circumstances include, for example, when a bond is legally
mandated and the statute provides that any bond issued in furtherance of the law
is deemed to contain the statutorily mandated terms. In such cases, the surety
will be bound to the minimum coverage provided by law. Restatement (Third) of
Suretyship & Guaranty § 71(2) (1996). Further, as a matter of contract
interpretation, if the parties modify their agreement to include liability in excess
of the penal sum, courts will honor that bargained-for agreement. See, e.g.,
Eichhorn v. Brewer, 755 P.2d 660, 662 (Okla. 1998) (allowing recovery in excess
of penal sum where supersedeas bond was amended to provide coverage for “all
court costs incurred in connection with said appeal or any judgment entered in the
lower court” (emphasis omitted)). Such circumstances do not arise in this case.
7
As Federal concedes, pursuant to 28 U.S.C. § 1961(a), it is also obligated
to pay post-judgment interest on this sum.
-13-
GIT urges this court to ignore substantial precedent limiting a surety’s
liability to the penal sum and hold Federal liable for the entire judgment. GIT’s
proposed interpretation of the bond would wholly abrogate the need to specify a
penal sum. The first paragraph of the bond states, “[w]e . . . Federal Insurance
Company, surety, are held and firmly bound to the appellee in the sum of Seven
Million [Dollars] . . . to be paid to appellee . . . .” This represents an express
agreement between the parties to provide security for the judgment in the sum of a
certain amount.
The district court did not err in its judgment limiting Federal’s liability to
the penal sum. Even assuming error, however, that error was invited. Not only
did GIT fail to raise this issue below, it filed a “Proposed Modified Amended
Judgment” in the district court that was limited to the penal sum of the bond. The
district court ultimately adopted GIT’s proposal and entered a written judgment
limiting Federal’s liability to the penal sum. This constitutes invited error. See
United States v. Shaffer, 472 F.3d 1219, 1227 (10th Cir. 2007) (holding in the
event the district court erred, it was invited); United States v. Deberry, 430 F.3d
1294, 1302 (10th Cir. 2005) (“[T]he invited-error doctrine precludes a party from
arguing that the district court erred in adopting a proposition that the party had
urged the district court to adopt.”). Therefore, Federal’s liability is limited to the
penal sum of the bond.
IV. PREJUDGMENT INTEREST
-14-
The district court ordered prejudgment interest to accrue on the total award
amount of $15,644,582 from September 29, 1995, to August 16, 2006, at the
applicable federal rate of 5.09%. MK appeals this ruling, contending that (1) the
contract and federal law prohibit prejudgment interest in this case; or (2) in the
alternative, the district court based its calculation on an incorrect accrual date. In
its cross-appeal, GIT argues the district court incorrectly used the federal rate
instead of Colorado’s interest rate.
“An award of prejudgment interest is within the district court’s discretion.”
Resolution Trust v. Fed. Sav. & Loan Ins. Corp., 25 F.3d 1493, 1506 (10th Cir.
1994). Where, however, the prejudgment award rests on an interpretation of
federal law, we review the district court’s interpretation de novo. Frymire v.
Ampex Corp., 61 F.3d 757, 772 (10th Cir. 1995). In order to determine whether
prejudgment interest is appropriate, this court first explores whether the federal
law in question expressly allows or expressly forbids prejudgment interest. Id.
“In the absence of an unequivocal prohibition of interest, we must test whether
such interest should be included by appraising the congressional purpose in
imposing the obligation in light of general principles we deem relevant.” Id. at
772-73 (quotations and alteration omitted); see also Rodgers v. United States, 332
U.S. 371, 373 (1947).
A. The Federal Acquisition Regulation System and Prejudgment
Interest
-15-
“Prejudgment interest is an element of complete compensation . . . .” West
Virginia v. United States, 479 U.S. 305, 310 (1987). It “serves to compensate for
the loss of use of money due as damages from the time the claim accrues until
judgment is entered, thereby achieving full compensation for the injury those
damages are intended to redress.” Id. at 311 n.2.
The contract’s default-termination clause incorporated verbatim the
standard federal default clause for fix-price construction contracts. 48 C.F.R.
§ 52.249-10(a), (c). That clause is part of the Federal Acquisition Regulation
System (“FAR”). See Title 48 C.F.R. (2008). As incorporated into the contract,
the clause allowed MK to terminate GIT if the work was delayed by GIT’s
inexcusable lack of diligence. Id. § 52.249-10. The clause further provided that a
wrongful termination would be treated as a termination for convenience:
If, after termination . . ., it is determinated that [GIT] was not in
default, or that the delay was excusable, the rights and obligations of
the parties will be the same as if the termination had been issued for
the convenience of the Government. 8
J.A. Vol. 10 at 2659; 48 C.F.R. § 52.249.10(c). The contract’s dispute clause
provides that “[a]ny substantive issue of law in [litigation concerning the
contract] shall be determined in accordance with the body of law applicable to
procurement of goods and services by the Government.” J.A. Vol. 10 at 2650.
8
As this court recognized in Morrison Knudsen I, the contract provides that
the FAR governs the parties’ substantive rights under the contract. 175 F.3d at
1230. MK is considered the “government” for the limited purpose of applying the
FAR provisions.
-16-
The disputes clause and the contract must be interpreted in light of the regulations
controlling the interpretation of federal contracts. Morrison Knudsen I, 175 F.3d
at 1230. The controlling regulations since 1984 have been the FAR. Id.
In Morrison Knudsen I, this court held MK’s termination of GIT was
wrongful. 175 F.3d at 1261. Under the terms of the contract and the FAR,
therefore, the rights and obligations of the parties are treated under a termination-
for-convenience paradigm. MK argues under this paradigm, the district court
erred by awarding GIT prejudgment interest. The FAR prohibits the government
from paying “interest on the amount due under a settlement agreement or a
settlement by determination. The Government may, however, pay interest on a
successful contractor appeal from a contracting officer’s determination . . . .”
48 C.F.R. § 49.112-2(d). MK argues the retrial of this lawsuit constitutes a
“settlement by determination” and therefore precludes the assessment of
prejudgment interest.
This argument is without merit. Although the termination of GIT must be
treated as a termination for convenience, MK wholly failed to act under a
termination-for-convenience paradigm and therefore waived its claims to the
prohibition on prejudgment interest benefit set out in the FAR. “Settlement by
determination” is not the legal equivalent of settlement through protracted
litigation in the federal courts. Instead, it is a term of art encompassing exact
procedures through which a government contractor may settle its claims. See 48
-17-
C.F.R. § 49.109-7. The “primary objective” under the termination-for-
convenience protocol is “to negotiate a settlement by agreement.” Id. §
49.201(b). If, however, the government and contractor cannot agree, the
government may “determine” an appropriate settlement fully compensating the
contractor, and the contractor may appeal. See id. § 49.109-7(a), (f). Had MK
proceeded under this paradigm, the federal regulations would have required MK
to provide notice and effect a no-cost settlement if GIT was willing to accept one.
Id. §§ 49.109-7(b), 49.101(b). Instead, MK sued GIT for damages. There is thus
no prohibition on prejudgment interest.
Although there is no prohibition on prejudgment interest, neither does the
FAR expressly provide for prejudgment interest. As recognized by the district
court, the provision allowing for prejudgment interest in the Contracts Dispute
Act (“CDA”) does not apply to this case. 9 See US W. Commc’n Serv., Inc. v.
United States, 940 F.2d 622, 627 (Fed. Cir. 1991) (“A government contractor’s
dispute with its subcontractor [is] by definition specifically excluded from CDA
coverage.”). The district court, however, analogized to this provision, concluding
9
“Generally, the United States is immune from interest on claims against it
unless it has waived immunity or is operating as a private commercial enterprise.”
Resolution Trust Corp. v. Fed. Sav. & Loan Ins. Corp., 25 F.3d 1493, 1506 (10th
Cir. 1994); see also Library of Congress v. Shaw, 478 U.S. 310, 317-18 & n.5
(1986) (applying strict construction of statutory waivers); Loeffler v. Frank, 486
U.S. 549, 555 (1988) (applying liberal construction to agency commercial
enterprises). The CDA acts to waive the government’s sovereign immunity on
contract claims when the party appeals a settlement determination.
-18-
MK forced GIT to appeal its “determination” that GIT was not entitled to money
for work completed under the contract. This analogy is insightful in showing that
even where the government is a party to the contract, Congress intended
prejudgment interest to be available when the injured party is delayed in
obtaining compensation. See, e.g., Frymire, 61 F.3d at 772-73.
Thus, we must determine whether prejudgment interest is supported under
“compensatory principles” and “fundamental considerations of fairness.” Anixter
v. Home-Stake Prod. Co., 977 F.2d 1549, 1554 (10th Cir. 1992). This court has
explained that under federal law, prejudgment interest is generally available. Id.;
see also Royal Indem. Co. v. United States, 313 U.S. 289, 296 (1941) (“In the
absence of an applicable federal statute, it is for the federal courts to determine,
according to their own criteria, the appropriate measure of damage, expressed in
terms of interest, for non-payment of the amount found to be due.”). Under both
compensatory principles and considerations of fairness, the award of prejudgment
interest was proper. When GIT was wrongfully terminated, MK withheld
payment under the contract. For more than thirteen years GIT has been deprived
of the time-value of monies owed to it. Prejudgment interest was proper as a
measure of compensatory damages and is not precluded by the equities. See
Anixter, 977 F.2d at 1554. The district court did not abuse its discretion by
awarding GIT prejudgment interest.
B. Accrual Dates
-19-
The district court awarded GIT prejudgment interest on its entire claim
from the date of termination: September 29, 1995. MK argues GIT had not
incurred many of their costs at this point. It therefore submits prejudgment
interest must be recalculated based on the various accrual dates of GIT’s
damages. GIT counters with MK’s stipulation in the first trial that prejudgment
interest should be calculated on all damages from the date of termination. In the
second trial, the district court granted GIT’s motion to enforce the stipulation.
Stipulations “cannot be disregarded or set aside at will.” Wheeler v. John
Deere Co., 935 F.2d 1090, 1097 (10th Cir. 1991) (quotation omitted).
Stipulations, however, are not absolute and will be set aside to prevent manifest
injustice. United States v. Montgomery, 620 F.2d 753, 757 (10th Cir. 1980). The
district court has broad discretion to determine whether a party should be held to
a stipulation or whether justice requires the stipulation be set aside. Wheeler, 935
F.2d at 1098. Whether a stipulation made in the first trial should remain binding
during the retrial is determined by “the nature of the stipulation and the
circumstances underlying its formulation.” Id. Formal stipulations made for the
purpose of relieving a party from proving facts can generally be substituted as
proof of the stipulated fact in a subsequent trial of the same action. Id. Where,
however, “a stipulation is limited expressly to a single trial and phrased in terms
of conclusory, rather than evidentiary, facts, district courts may on retrial free a
party from the stipulation.” Id.
-20-
Before the district court in the first trial, the following colloquy occurred:
THE COURT: . . . [T]he question I have for all of you is: Will
you stipulate that the date from which interest will
run if GIT prevails is the date of termination?
MR. KELLY: GIT would stipulate, Your Honor.
MR. FROST: MK would stipulate.
J.A. Vol. 5 at 1320.
Unlike Wheeler, a products-liability case involving a formal stipulation to
the feasibility of designing a safer product, this stipulation was “phrased in terms
of conclusory, rather than evidentiary, facts.” Wheeler, 935 F.2d at 1098. MK
argues it would be manifestly unjust to hold it to this stipulation when many
categories of damages in the first trial were not known at the time of the
stipulation or had not yet occurred. We agree, in part.
The district court did not abuse its discretion in holding MK to its
stipulation for damages of the kind awarded in the first trial. Although the
stipulation was not formal, district courts are vested with broad discretion in
determining whether to hold a party to its prior stipulation. Where, however,
damages were not incurred or known until after the first trial, the district court
abused its discretion by holding MK to its 1996 stipulation. As this court
explained in Reed v. Mineta, “prejudgment interest does not accrue until the
victim actually sustains the monetary injury.” 438 F.3d 1063, 1066 (10th Cir.
2006). Although a party may stipulate to paying prejudgment interest on a
-21-
damage award sustained before the monetary injury, to hold that stipulation
binding for damages not contemplated or knowable in the first trial would
constitute manifest injustice.
Many of GIT’s damages were sustained on the date of termination. This
includes the jury awards for work performed under the contract, the reasonable
profit for work performed, and equitable adjustments. Post-termination costs,
although technically incurred after the date of termination, were a central aspect
of the first trial. When MK stipulated to the date from which interest would run,
it fully understood post-termination costs would be included in this sum. It is
thus not manifestly unjust to hold MK to its stipulation as to these awards.
Prejudgment interest on these sums should run from the stipulated date of
termination.
GIT, however, did not incur a recoverable injury with respect to its
subcontractors until it settled with them. 10 See Morrison Knudsen I, 175 F.3d at
1249-54 (explaining settlements with subs are not a recoverable injury under the
contract until settlement is reached). Nor could MK foresee the amount the subs
would recover from GIT. Thus, prejudgment interest should run from the dates of
settlement. GIT settled with Bogue Construction, Inc. on February 27, 1997
10
The contract obligated MK to pay GIT for, inter alia, “[t]he cost of
settling and paying termination settlement proposals under terminated
subcontracts that are properly chargeable to the terminated portion of the
[contact].”
-22-
($243,126); G.A. Western Construction Co. on September 29, 1997 ($22,597);
and Keers Environmental on August 15, 1996 ($28,137). A jury awarded
Robinson damages based on GIT’s breach of the subcontract on December 27,
1999 ($5,831,485). The costs associated with these settlements, like the
settlements themselves, were not recoverable until the date of settlement. 11 See
Morrison Knudsen I, 175 F.3d at 1250 (quotations omitted) (explaining costs are
not recoverable until they are incurred). GIT had not yet settled with its subs
(save Keers Environmental) prior to the first trial. Any attempt to enforce the
stipulation against MK as to costs not yet incurred as of the date of trial, and
therefore completely speculative, is manifestly unjust. See Montgomery, 620 F.2d
at 757. Prejudgment interest relating to the Bogue Construction, G.A. Western,
and Robinson settlements must run from the dates on which GIT settled with
them.
Despite the great discretion district courts have in calculating prejudgment
interest, the district court abused its discretion by calculating prejudgment interest
on the entire damage award from the date of termination. We therefore remand
11
This also includes the costs GIT incurred settling with its surety,
Fireman’s Fund, for legal fees Fireman’s Fund incurred vis-a-vis GIT’s settlement
with its subcontractors. A settlement agreement was reached between Fireman’s
Fund and GIT on August 12, 1998, almost two years after the first trial in this
matter. Thus, prejudgment interest on the $51,719 Fireman’s Fund award must
run from August 12, 1998.
-23-
for recalculation of prejudgment interest on GIT’s damage award in accordance
with this opinion.
C. Federal or State Interest Rate
In its cross-appeal, GIT argues the trial court erred by failing to apply the
Colorado interest rate instead of the federal interest rate to its award of
prejudgment interest. Prejudgment interest is an element of compensatory
damages and is part of the actual damages sought. Johnson v. Cont’l Airlines
Corp., 964 F.2d 1059, 1063-64 (10th Cir. 1992); see also Monessen Sw. Ry. Co. v.
Morgan, 486 U.S. 330, 335 (1988). Prejudgment interest, as an integral element
of compensatory damages “is not subject to an independent choice of law
analysis.” Johnson, 964 F.2d at 1064. As a result, “the law governing
compensatory damages also governs prejudgment interest.” Id. (rejecting
“smorgasbord approach” created by allowing parties to pick and choose
prejudgment interest law).
-24-
By the terms of their contract, MK and GIT were bound by federal law. 12
The contract required the court to determine all substantive legal issues in accord
with the FAR. The FAR, by reference to the CDA, applies the federal interest
rate. See 48 C.F.R. §§ 49.112-2(d), 52.233-1(h). The district court properly
concluded that federal law applied to both the calculation of damages and
prejudgment interest.
V. DUPLICATION OF EQUITABLE ADJUSTMENTS
MK next argues the judgment includes GIT’s costs for equitable adjustment
claims twice, resulting in a duplication of damages. MK moved to amend the
judgment under Fed. R. Civ. P. 59(e), asking the district court to reduce the
judgment by $3,986,279, the amount of damages awarded for equitable
adjustments. The district court denied the motion. Whether an award is
duplicative is a question of fact, which we review for clear error. United
12
Despite GIT’s protestations, Colorado law does not apply to prejudgment
interest merely because this case arose under diversity jurisdiction. A federal
court sitting in diversity applies the choice of law principles of the state in which
it sits. Century 21 Real Estate Corp. v. Meraj Int’l Inv. Corp., 315 F.3d 1271,
1281 (10th Cir. 2003). Colorado has adopted the approach of the Restatement
(Second) of Conflicts of Laws resolving contract choice of law questions. Id.
“Under the Second Restatement, contracting parties may choose a particular body
of law to govern their contract.” Id. Absent a reasonable basis for the choice of
law or a violation of a fundamental state policy, the law of the contract will
govern. Id. Under the Restatement, the law chosen to govern the parties’
substantive rights also governs the measure of damages. Restatement (Second) of
Conflicts of Laws § 207 (1991).
-25-
Phosphorus, Ltd. v. Midland Fumigant, Inc., 205 F.3d 1219, 1235 (10th Cir.
2000).
The contract allowed GIT to recover equitable adjustments. 13 To collect
equitable adjustments, GIT had to show liability, causation, and injury. Morrison
Knudsen I, 175 F.3d at 1244. “The contractor must not only prove that the
government specifically caused its increased costs, but must prove that those
costs were reasonable, allowable, and allocable under the contract.” Id. In
Morrison Knudsen I, the judgment was vacated, in part, because GIT failed to
present sufficient evidence that it was entitled to equitable adjustments. Id. at
1245 (“GIT presented very little or no evidence of how MK’s actions specifically
caused GIT to incur the costs claimed in its damage exhibits” nor did they show
“that those costs were reasonable.”). Due to the district court’s failure to employ
a special-verdict form, this court was unable to affirm those awards that were
permissible and remanded for a new trial on damages. Id. at 1254-55.
At the second trial, the district court employed a special-verdict form in
which the several categories of damages were listed. The jury was asked to award
damages in Category 1 for work performed under the contract before the effective
13
The contract contained the standard federal Changes Clause for fixed-
price construction contracts. See 48 C.F.R. § 52.243-4. The clause provides that
a “written or oral order . . . from [MK] that causes a change shall be treated as a
change order” and that “[i]f any change under this article causes an increase or
decrease in [GIT]’s cost of . . . performance . . . [MK] shall make an equitable
adjustment and modify the Subcontract in writing.”
-26-
date of termination. Category 2 included the cost of storage, transportation, and
other expense items incurred that were necessary for the preservation, protection
or disposition of the termination inventory and equipment, i.e. post-termination
costs. 14 Category 3 was entitled “Equitable Adjustments” and the special-verdict
form asked the jury to identify each equitable adjustment to which GIT was
entitled and specify the award on each item.
MK argues the equitable adjustments awarded in Category 3 were already
included in the jury’s damage calculations in Categories 1 and 2. The purpose of
Category 3, MK asserts, was simply to list the equitable adjustments in order for
this court to provide meaningful appellate review and ensure each equitable
adjustment was properly awarded. Specifically, MK relies on Defense Exhibit
K7, GIT’s damage exhibit. That exhibit organized GIT’s costs by two alternative
methods. Exhibit K7 first organized GIT’s damages by pre-termination and post-
termination costs, excluding bonding, overhead, and profit. Pre-termination costs
were valued at $5,273,480. Post-termination costs were valued at $1,433,458.
These calculations included all equitable adjustments and total $6,706,938. Next,
Exhibit K7 presented an alternative way of organizing the damages by presenting
14
Categories 1 and 2 also included awards for the settlement amounts GIT
paid its subcontractors. MK does not claim any duplication occurred as to these
subcontractor awards and, thus, these awards are not discussed in the following
analysis. We include in our analysis, however, the claims associated with
subcontractor profits. GIT included this sum in its request for pre-termination
profit, and it therefore cannot be excluded.
-27-
the same costs, but categorizing the damages in terms of equitable adjustments
and non-equitable adjustments. Equitable adjustment costs, excluding bonding,
overhead, and profit, were calculated to be $3,903,771 while non-equitable
adjustment costs were valued at $2,803,166. This calculation is nearly identical,
totaling $6,706,937. GIT also sought costs for bonding, overhead, and profit 15 in
the amount of $2,046,936. 16 Out of this sum, $1,278,947 is for non-equitable
adjustment costs and profit. Thus, GIT sought $4,082,113 in non-equitable
adjustment costs, $4,671,760 in equitable adjustments, and $8,753,873 total. 17
Following closing arguments, a juror sought clarification on where specific
awards should be placed on the jury verdict form. The juror asked:
Category 1 states for GIT’s work performed under the MK-GIT
contract, I could interpret all work to be under the contract, including
[equitable adjustments], since the contract includes the notion of
[equitable adjustments.] Should or should not the number in
category 1A include the [equitable adjustments]?
R. Vol. XII at 115. MK argued to the district court that equitable adjustments
should only be placed in Category 3. Id. at 110. The district court agreed and
informed MK it would instruct the jury to place its equitable adjustment awards
15
Profit is calculated using 10%, rather than the 8.8% in Exhibit K7, as
evidence was offered to support this higher amount.
16
This sum excludes bonding and overhead costs for subcontractors.
17
This calculation uses the pre- and post-termination schedule which is one
dollar greater than the equitable adjustment and non-equitable adjustment
schedule.
-28-
only in Category 3. Id. at 111. To the jurors, the district court answered the
juror’s question, “. . . the answer is you should see instruction 3.2 and [] that’s
related to category 3.” Id. at 115. 18
The jury awarded GIT a total of $7,375,808 in pre-termination and post-
termination costs, including bonding, overhead, and profit. 19 It then awarded GIT
$3,986,279 in equitable adjustments. The district court added these sums together
in the judgment. Thus, MK argues the jury award must be an improper double
recovery that the jury reached by including equitable adjustments in the pre- and
post-termination award as well as under Category 3.
This court will only disrupt a jury verdict for duplication if the verdict
amount is not within the range of evidence. See United Phosphorus, Ltd., 205
18
Instruction 3.2 explained GIT was entitled to recover “actual” and
“recoverable” costs of work performed under the MK-GIT contract. J.A. Vol. 6 at
1735. Without specifying that equitable adjustments are a separate category, the
instruction states GIT is entitled to recover equitable adjustments “incurred by
GIT because MK increased the amount or difficulty of the work to be performed,
accelerated or sped up GIT’s performance of the work, added to or complicated
the work to be performed, or required GIT to leave materials and equipment on
site for MK to use after the contract was terminated.” Id. at 1736. A plausible
reading of Instruction 3.2 is that equitable adjustments should be awarded in
Categories 1 and 2.
19
These sums can be found in the jury verdict under Category I.A (pre-
termination costs, including bonding and overhead); I.C.2. (pre-termination profit,
including profit on subcontractors); and II.C (post-termination costs). This sum
excludes subcontractor settlement costs, found under Category I.B (pre-
termination); the cost of settling with MK, found under Category II.A and
supported by Exhibit M25 (post-termination); and costs associated with
subcontractor settlements, found under Category II.B and supported by Exhibit
M24 (post-termination).
-29-
F.3d at 1228; Midwest Underground Storage, Inc. v. Porter, 717 F.2d 493, 501-03
(10th Cir. 1983). “It is well settled that a verdict will not be upset on the basis of
speculation as to the manner in which the jurors arrived at it.” Midwest
Underground Storage, 717 F.2d at 501. As we explained in United Phosphorus,
even where the chance is slight that the jury arrived at the award without
erroneously duplicating, if the verdict is “within the range of the evidence” it will
be upheld. 205 F.3d at 1228 (quotation omitted).
Where, however, the jury verdict cannot be explained by evidence in the
record and duplication is apparent, “the court, either sua sponte or on motion of a
party, should reduce the judgment by the amount of the duplication,” and thereby
prevent double recovery. Mason v. Okla. Tpk. Auth., 115 F.3d 1442, 1459 (10th
Cir. 1997). GIT contends because the total jury award of $15,644,582 was less
than the $16,692,818 supported by Exhibit K7, a finding of duplication would be
purely speculative. This argument, however, fails to account for the special
verdict form used by the parties. For each category of damages, therefore, the
jury was limited to awarding a sum supported by evidence for that specific
category. The jury awarded GIT a total of $7,375,808 in pre-termination and
post-termination costs. There is no evidence, however, supporting this award
without including equitable adjustments. Based on GIT’s damage exhibits, the
maximum amount the jury could have awarded for pre- and post-termination
-30-
costs, excluding equitable adjustments, was $4,082,113. Thus, MK is
correct—the jury awarded GIT equitable adjustments in Categories 1 and 2. 20
It is clear on the face of the jury verdict form that duplication occurred, and
this court must therefore reduce the verdict by the amount duplicated. MK asks
this court to reduce the verdict by $3,986,279, the amount the jury awarded in
Category 3. There are several approaches we may take in fashioning a remedy:
(1) reduce the jury verdict by the total of all equitable adjustments awarded in
Category 3 and order a remittitur, as suggested by MK; (2) reduce the jury verdict
by the amount of damages in Categories 1 and 2 not supported by the evidence
and order a remittitur; or (3) remand for a new trial on damages.
This court concludes a remittitur is the most appropriate remedy in this
case. MK’s liability was established in Morrison Knudsen I and is not at issue in
this case. See, e.g., Malandris v. Merrill Lynch, Pierce, Fenner & Smith Inc., 703
F.2d 1152, 1168 (10th Cir. 1981) (explaining new trial unnecessary where a court
concludes no error occurred on liability). Although MK successfully proved
duplication occurred, it cannot prove every equitable adjustment awarded in
Category 3 was also present in Categories 1 and 2. We therefore will employ
approach number two and fashion a remedy based on the maximum amount of
20
GIT asserts in its brief that its damage exhibit, K7, is not the only
evidence of damages. Its citations to the record, however, do not provide any
additional evidence of non-equitable adjustment damages applicable to pre-
termination and post-termination costs. Rather, they concern costs associated
with subcontractor settlements or equitable adjustments.
-31-
damages that are reasonably supported by the evidence in the record. See K-B
Trucking Co. v. Riss Int’l Corp., 763 F.2d 1148, 1161-62 (10th Cir. 1985); see
also Dixon v. Int’l Harvester Co., 754 F.2d 573, 590 (5th Cir. 1985) (using a
“maximum recovery rule” to determine the size of the remittitur by reducing the
verdict to the maximum sum the jury could have properly awarded).
GIT established it incurred $4,082,113 in non-equitable adjustment pre-
termination and post-termination costs, $3,293,695 less than the $7,375,808
awarded by the jury. Accordingly, we remand to the district court with directions
to enter a remittur order for acceptance of a judgment reducing the award by
$3,293,695, or, if GIT chooses, a new trial on damages. See Malandris, 703 F.2d
at 1178.
VI. EQUITABLE ADJUSTMENT CLAIM FOR BOND
GIT was required to provide performance and payment bonds for the
project. Under a termination-for-convenience paradigm, the contractor is entitled
to recover only costs incurred for performance of the terminated work. See 48
C.F.R. 52.212-4(l); see also Morrison Knudsen I, 175 F.3d at 1243 n.26. The
contract does not entitle GIT to compensation for its bond payments unless it
“furnish[es] evidence of full payment to the surety company.” J.A. Vol. 10 at
2649.
In its bid, GIT quoted $245,000 for the cost of providing a performance
bond. MK argues that testimony at trial established GIT only furnished evidence
-32-
to MK of its payment of $80,996 in premiums for its bond payments. GIT,
however, sought as an equitable adjustment and was awarded an additional
$164,004. This sum represents the difference between the $80,996 that MK had
reimbursed GIT for its bond payments and the amount GIT quoted MK in its bid.
After GIT rested, MK moved for judgment as a matter of law pursuant to Fed. R.
Civ. P. 50(a) on GIT’s claim for a bond equitable adjustment. The court denied
the motion. At the close of all evidence, MK renewed its motion, which the court
denied. After the court entered its judgment, including the $164,004 sum, MK
requested the court amend the judgment to eliminate this damage award, arguing
GIT never incurred this cost or provided evidence of payment and it was therefore
not properly recoverable. The court denied the motion.
This court reviews de novo a district court’s denial of a motion for
judgment as a matter of law under Fed. R. Civ. P. 50. Marshall v. Columbia Lea
Reg’l Hosp., 474 F.3d 733, 738 (10th Cir. 2007). “Judgment as a matter of law is
appropriate only if the evidence points but one way and is susceptible to no
reasonable inferences which may support the nonmoving party’s position.” Escue
v. N. Okla. Coll., 450 F.3d 1146, 1156 (10th Cir. 2006) (quotation omitted); see
also Miller v. Auto Club of N.M., Inc., 420 F.3d 1098, 1131 (10th Cir. 2005)
(“Judgment as a matter of law is only appropriate when ‘a party has been fully
heard on an issue and there is no legally sufficient evidentiary basis for a
reasonable jury to find for that party on that issue.’” (quoting Fed. R. Civ. P.
-33-
50(a)(1))). All inferences are drawn in favor of the non-moving party. Escue,
450 F.3d at 1156.
GIT argues it is entitled to $164,004 in bond costs as an equitable
adjustment and sufficient evidence supports this award. First, it contends that the
evidence at trial proved $164,004 in costs were incurred as mobilization costs.
Second, it argues that MK’s expert witness, Thomas Caruso, testified GIT was
entitled to recover $245,000 for its bond expenses. We find neither argument
persuasive.
GIT never introduced evidence that it paid its surety the entire $245,000
included it its bid. In fact, the only testimony on this point establishes that GIT
did not have evidence that it paid this sum. Robert Kinghorn of GIT testified
about this specific claim:
Q: Okay. And as I understand it, your claim for bond amount was
$245,000.
A. That was the price that was included on the bid.
Q. And you were paid $80,996?
A. Yes, that’s correct.
Q. Where is your check for $245,000?
A. I don’t have a check for $245,000.
Q. Did you ever pay $245,000 to your bonding company?
A. Yes.
-34-
Q. Thank you. You don’t have a receipt for that amount, do you?
...
A. No, sir.
Q. And that payment is not reflected in your job-cost report, is it?
A. No, the payment in the job-cost report is [$]80,996.
Q. That is what you actually paid for your bond, isn’t it?
A. Yes, that’s correct.
R. Vol. VI at 422. Although this testimony is somewhat conflicting, GIT fails to
establish it provided MK with evidence that it paid its surety $164,004. In fact,
Kinghorn explicitly stated GIT only paid $80,996 for the bond.
GIT does not identify evidence anywhere else in the record supporting its
claim that it paid its surety $164,004. GIT’s reliance on Caruso’s testimony does
not alter this result. Caruso testified that GIT requested $245,000 for its bond
costs. This sum was also included in a payment request sent to MK, and Caruso
testified he believed this sum would be due to GIT. He did not, however, testify
that GIT had paid its surety the $164,004. Likewise, there is no evidence that
mobilization costs somehow increased the cost of providing the performance
bond. 21 Our task is merely to examine whether GIT offered evidence to show it
21
GIT cites to testimony by Douglas Hambleton, MK’s subcontract
administrator for the Slick Rock project, in support of its contention that the
$164,004 is somehow related to mobilization costs. Hambleton opined that once
GIT provided the bond, it was entitled to the entire amount it quoted. This
testimony explicitly differentiates between mobilization costs and bond costs and
in no way indicates how bond costs are related to mobilization costs. Hambleton
(continued...)
-35-
paid $164,004 to its surety. The undisputed evidence supports MK’s position:
GIT failed to furnish evidence that it paid its surety any more than the $80,996
which MK reimbursed. See Escue, 450 F.3d at 1156. Under the terms of the
contract, therefore, MK was entitled to judgment as a matter of law. On remand,
the district court is instructed to enter judgment as a matter of law for MK on the
bond equitable adjustment and reduce the judgment accordingly.
VII. R.N. ROBINSON & SON AND FIREMAN’S FUND
MK makes three arguments challenging the judgment against it with respect
to Robinson and Fireman’s Fund. First, it argues that GIT cannot recover any
damages for its settlement with Robinson because it never incurred those costs.
Second, it argues even if those damages were incurred, the jury improperly passed
through consequential damages to MK, which is prohibited by the FAR. Third, it
argues Fireman’s Fund is not a subcontractor and thus costs associated with the
Fireman’s Fund settlement are not recoverable. These arguments fail.
A. Cost of Settling with Robinson
The jury awarded GIT damages for the cost of settling with its
subcontractors. It also awarded damages for the accounting, legal, clerical and
21
(...continued)
also does not provide evidence that GIT paid the entire $245,000 price in the bid.
Instead, he opined that “[i]t’s 100 percent of the premium requested is what
[MK’s] obligation is.” J.A. Vol. 39 at 11737 (emphasis added). Although this
may have been Hambleton’s understanding of how reimbursements operate, it is
not evidence that GIT actually paid $245,000 for its bonding costs.
-36-
other expenses associated with these settlements. In 1999, Robinson sued GIT
and obtained a judgment in the amount of $4,699,674 (“Robinson Judgment”). 22
GIT’s surety, Fireman’s Fund, paid Robinson $3,200,000. Robinson later filed a
claim in GIT’s bankruptcy case for $3,805,866. GIT asked the jury to award
$7,005,886 plus overhead, profit, and bond costs for its settlement with Robinson.
MK filed a Rule 50(a) motion requesting judgment as a matter of law as to
GIT’s claims regarding the Robinson Judgment. The district court denied that
motion. The jury awarded $5,831,485 for the settlement with Robinson and
$715,451 for accounting, legal, and clerical expenses associated with Robinson’s
termination and settlement. Following the verdict, MK filed a Rule 50(b) motion,
or alternatively, requested a remittitur. The court denied the motion.
On appeal, MK claims as a matter of law, judgment should be entered for
MK on all claims arising out of the Robinson Judgment. MK argues GIT has no
obligation to pay Robinson or Fireman’s Fund, and thus, it cannot recover from
22
The Robinson Judgment specifically broke down the award into the
following categories:
(A) Unpaid Contract Work $1,699,812.00
(B) Business Impairment Damages $2,999,862.00
(C) Equitable Adjustment-Delay $694,800.00
Damages
(D) Equitable Adjustment-Additional $608,461.00
Work ordered by or through GIT
The district court, finding amounts (C) and (D) to be already included in
amount (A), reduced the judgment by $1,303,261 (the total of C and D).
-37-
MK any sums related to the Robinson Judgment. Further, it states GIT has not
incurred any costs associated with the Robinson Judgment. This argument
mischaracterizes the procedural history of this case and the law.
Robinson’s and Fireman’s Fund’s claims against GIT were discharged in
GIT’s bankruptcy proceedings. A bankruptcy discharge “operates as an
injunction against the commencement or continuation of an action, the
employment of process, or an act, to collect, recover, or offset any such debt as a
personal liability of the debtor whether or not discharge of such debt is waived.”
11 U.S.C. § 524(a)(2); see also 11 U.S.C. § 1141(d)(1) (providing that a Chapter
11 reorganization discharges debtor from any debt arising before the date
reorganization). As part of GIT’s reorganization, however, Robinson’s claims
against GIT were discharged in exchange for a percentage of GIT’s claim against
MK. Thus, GIT has incurred a cost and obligation to Robinson. See Morrison
Knudsen I, 175 F.3d at 1250 (explaining that payment of a settlement is not a
prerequisite to incurring a cost). This obligation is still in effect today. Although
GIT’s obligations to Robinson and Fireman’s Fund are contingent on the outcome
of this litigation, that contingency has in fact occurred. GIT was awarded
$5,831,485 for the costs associated with Robinson. Per the agreement, the
proceeds will be distributed to Fireman’s Fund to compensate it for the $3.2
million it paid to Robinson to satisfy the Robinson Judgment and to Robinson
-38-
itself for amounts it has still not been compensated. Thus, the district court did
not err in denying MK’s motion for judgment as a matter of law.
B. Consequential Damages
Next, MK argues the Robinson Judgment should be reduced, as it contains
substantial amounts representing consequential damages, which GIT cannot
recover from MK. It argues GIT was only entitled to recover from MK the “cost
of GIT’s settlements with construction subcontractors for actual work in place at
the job site as of the termination date.” This contention is without merit and GIT
was entitled to recover its costs of settlement with Robinson.
Consequential and anticipatory damages are not recoverable under a
termination-for-convenience paradigm. 48 C.F.R. 49.201-202; see also Century
Marine Inc. v. United States, 153 F.3d 225, 230 (5th Cir. 1998). Where a
subcontractor fails to include a termination-for-convenience clause in its contracts
with other subcontractors, he may become liable for anticipatory or consequential
damages. If a jury awards such damages, they cannot be passed through to the
government or, in this case, MK. See 48 C.F.R. § 49.108-2(b)(2) (“The failure of
a prime contractor to include an appropriate termination clause in any
subcontract, or to exercise the clause rights, shall not . . . [i]ncrease the obligation
of the Government beyond what it would have been if the subcontract had
contained an appropriate clause.”). Where, however, the contractor (here, GIT)
has made a reasonable effort to include in the subcontract a termination clause
-39-
excluding the payment of anticipatory profits and consequential damages, all
reasonable costs of settling with the subcontractor are recoverable. Id. § 49.108-
5(a)(1)-(2). In other words, GIT can pass through its costs of settling with
Robinson to MK, provided GIT included the appropriate termination clause in its
contract with Robinson.
The Robinson Judgment included $2,999,862 for “Business Impairment
Damages,” which MK claims constitute consequential damages. The evidence
shows, however, that the GIT-Robinson subcontract included a clause,
incorporating all of the GIT-MK terms and thereby complying with 48 C.F.R.
49.108-5(a)(1)-(2). 23 GIT, therefore, protected itself against consequential
damages. The jury was instructed to evaluate the Robinson Judgment for factual
compliance with the limitations of 48 C.F.R. § 49.108-2. Therefore, the jury’s
award does not violate federal regulations and is supported by the evidence.
23
Under this provision, a final judgment against GIT is considered a “cost
of settling with the contractor” so long as, (1) the prime contractor has made
reasonable efforts to include a termination clause excluding payment of
anticipatory profits or consequential damages; (2) the provisions of the
subcontract relating to the rights of the parties upon its termination are fair and
reasonable and do not increase the common law rights of the subcontractor; (3)
the contractor made reasonable efforts to settle with the subcontractor; (4) the
contractor gave prompt notice of the proceedings and did not refuse to give the
government control of the defense; and (5) the contractor diligently defended the
suit. 48 C.F.R. 49.108-5(1)-(5). GIT introduced evidence that it met all five of
these requirements.
-40-
C. Fireman’s Fund Costs
The jury awarded GIT $51,719 for its “[a]ccounting, legal, clerical costs
and other expenses associated with the termination of, and settlement with the
following lower-tier subcontractors: . . . Fireman’s Fund.” MK filed a Rule 59
motion to amend the judgment and eliminate the $51,719 award related to GIT’s
settlement with Fireman’s Fund. The district court denied the motion.
MK argues that the jury improperly classified Fireman’s Fund, GIT’s
surety, as a “subcontractor.” Although GIT is entitled to recover its reasonable
costs for settling with subcontractors, MK asserts Fireman’s Fund was a bonding
company, not a subcontractor. MK, however, fundamentally mischaracterizes this
award. Fireman’s Fund, in acting as a surety, incurred legal costs associated with
GIT’s settlement with its subcontractors, including Robinson, Keers
Environmental, and Bogue Construction. GIT was liable to Fireman’s Fund for
the cost of these legal fees. Although the jury verdict appears to classify
Fireman’s Fund as a subcontractor, the jury was in fact awarding GIT damages
incurred in settling with its subcontractors. These costs are quintessential
damages recoverable under the FAR. 48 C.F.R. § 52.249-2(g)(3)(i)-(ii) (stating
under a termination for convenience, contractor is entitled to recover the
reasonable costs of settlement, including “[a]ccounting, legal, clerical, and other
expenses reasonably necessary for the preparation of termination settlement
-41-
proposals and supporting data” and for the “termination and settlement of
subcontracts”).
MK also erroneously claims GIT’s obligations to Fireman’s Fund were
discharged in GIT’s bankruptcy. Fireman’s Fund, like Robinson, entered into an
agreement exchanging its claims against GIT for a percentage of the award in this
litigation. Thus, for the reasons stated above, MK’s challenge is without merit.
VIII. POST-JUDGMENT INTEREST
In its cross-appeal, GIT contends the district court erred by applying an
incorrect post-judgment interest rate. On August 16, 2006, the district court
entered a Modified Amended Judgment awarding post-judgment interest to
“accrue at the legal rate of 5% per annum on any and all amounts awarded herein
from the date of this Modified Amended Judgment.” GIT did not object to this
rate in the district court, but contends on appeal that the correct legal rate on
August 16, 2006, was 5.09% per annum. In response, MK claims GIT waived this
challenge by failing to object below.
Post-judgment interest is calculated from the date of entry of the judgment.
28 U.S.C. § 1961(a). It is calculated “at a rate equal to the weekly average 1-year
constant maturity Treasury yield, as published by the Board of Governors of the
Federal Reserve System.” Id. Where a district court’s award of post-judgment
interest involves statutory interpretation, we apply a de novo standard of review.
O’Tool v. Genmar Holdings, Inc., 387 F.3d 1188, 1207 (10th Cir. 2004). If,
-42-
however, the district court’s award of post-judgment interest is challenged on
some other basis—for example a clerical error—our review is for abuse of
discretion. Id. As GIT’s challenge of the post-judgment rate does not turn on a
statutory interpretation of 28 U.S.C. § 1961, we review for abuse of discretion.
First, GIT’s failure to identify the error in the district court does not
constitute waiver. Section 1961 entitles the prevailing plaintiff in a federal suit to
post-judgment interest at the rate fixed in the statute, whether or not the party
requests post-judgment interest in the complaint. Bell, Boyd & Lloyd v. Tapy, 896
F.2d 1101, 1104 (7th Cir. 1990). Further, the Seventh Circuit held that failure to
cross-appeal does not divest a court of appeals from modifying post-judgment
interest when the district court erred. Id. This is because Rule 37 of the Federal
Rules of Appellate Procedure entitles the court of appeals to award a party
whatever interest he may be entitled to under the law. Id. This court has held,
pursuant to Federal Rules of Civil Procedure Rule 60(a), 24 clerical mistakes in
judgments may be corrected by the court at any time. McNickle v. Bankers Life
and Cas. Co., 888 F.2d 678, 681-82 (10th Cir. 1989). Thus, this court has
24
Rule 60(a) states:
Corrections Based on Clerical Mistakes; Oversights and
Omissions. The court may correct a clerical mistake or a mistake
arising from oversight or omission whenever one is found in a
judgment, order, or other part of the record. The court may do so on
motion or on its own, with or without notice. But after an appeal has
been docketed in the appellate court and while it is pending, such a
mistake may be corrected only with the appellate court’s leave.
-43-
authority to remand to the district court to fix any clerical errors found in the
award of post-judgment interest. Id.
The rate set by the Board of Governors of the Federal Reserve System on
August 16, 2006, was 5.09% per annum. The district court ordered “that post-
judgment interest shall accrue at the legal rate.” Therefore, the district court
intended to award the proper amount, but due to a clerical error, stated that the
legal rate was five percent. Failure to award post-judgment interest under §
1961(a) at the appropriate statutory rate constitutes an abuse of discretion. See
Ford v. Alfaro, 785 F.2d 835, 842 (9th Cir. 1986). On remand, the district court
is instructed to amend the judgment to reflect the accurate post-judgment interest
rate of 5.09% per annum.
IX. CONCLUSION
For the foregoing reasons, this court affirms the judgment in part, reverses
the judgment in part, and remands for further proceedings consistent with this
opinion.
-44-