United States Court of Appeals
FOR THE DISTRICT OF COLUMBIA CIRCUIT
Argued November 12, 1999 Decided January 18, 2000
No. 99-7028
Tri County Industries, Inc.,
Appellant
v.
District of Columbia, et al.,
Appellees
Appeal from the United States District Court
for the District of Columbia
(No. 94cv02014)
Frank J. Emig argued the cause for the appellant.
Donna M. Murasky, Assistant Corporation Counsel, Office
of the Corporation Counsel, argued the cause for the appel-
lees. Robert R. Rigsby, Interim Corporation Counsel, and
Charles L. Reischel, Deputy Corporation Counsel, Office of
the Corporation Counsel, were on brief for the appellees.
Before: Edwards, Chief Judge, Silberman and Henderson,
Circuit Judges.
Opinion for the court filed by Circuit Judge Henderson.
Karen LeCraft Henderson, Circuit Judge: This appeal
arises from proceedings determining what damages, if any,
appellant Tri County Industries, Inc. (Tri County) should be
awarded to compensate for what this court previously deter-
mined to be the District of Columbia's (District) violation of
its fifth amendment right to procedural due process. See Tri
County Indus., Inc. v. District of Columbia, 104 F.3d 455,
460-62 (D.C. Cir. 1997). Following the first of two trials, the
jury awarded $5,000,000. The trial court then granted a new
trial, nisi remittitur to $1,000,000, which was refused. At the
second trial, the district court admitted evidence excluded
from the first and the jury returned nominal damages of
$100. Tri County challenges the court's order granting the
District's alternative motion for a new trial as well as several
evidentiary rulings in the second trial and requests reinstate-
ment of the first award or, in the alternative, a new trial due
to allegedly erroneous evidentiary rulings during the second
trial. For the reasons set forth below, we reverse the district
court's order of July 23, 1998 and reinstate the original jury
verdict of $5,000,000.
I.
On February 26, 1993 Tri County obtained a building
permit from the District authorizing conversion of an empty
warehouse into a facility for its business of decontaminating
soil tainted with oil and other hazardous materials. While
securing the permit, Tri County also obtained an air quality
permit as well as a waiver of the required environmental
impact statement. Even several months after it obtained the
necessary permits, however, it had not begun operating due
to equipment delivery delays. On September 7 it received a
District citation for storing soil at the facility without the
required certificate of occupancy.1 Tri County neither re-
moved the soil nor paid the fine; consequently, the District
issued a stop-work order on September 22. Tri County did
not challenge the citation or order. Its failure to respond led
to an order by the District Department of Consumer and
Regulatory Affairs (DCRA) dated October 13, 1993 purport-
ing to suspend Tri County's building permit.
The building permit had already been suspended on Sep-
tember 20, however, when, prompted by a groundswell of
community opposition to the project, Hampton Cross, acting
DCRA director, summarily suspended Tri County's building
permit. The DCRA sent Tri County a letter requesting
further information on October 15, 1993 to which Tri County
did not respond. On December 6 the DCRA sent another
letter, this time rescinding the environmental impact state-
ment waiver and threatening imminent revocation proceed-
ings on the building permit. Tri County's only response was
to remove the soil that had caused the initial citation. Tri
County's counsel advised it that an appeal likely would be
influenced by politics given the strong community opposition
and that he could not guarantee when such an appeal would
be heard. Given the high rental cost of the property in
question and the necessity of purchasing, without delay,
costly equipment in high demand, Tri County estimated the
costs of an appeal at nearly $1,000,000. With no assurance of
a prompt hearing and the prospect of a politically influenced
review process, Tri County abandoned its project.
Tri County brought suit under 42 U.S.C. s 1983 and suc-
ceeded in its challenge to the September 20 suspension of its
building permit when this court reversed the district court's
dismissal, holding that the suspension violated Tri County's
right to procedural due process. See Tri County Indus., 104
F.3d at 460-62. We remanded for consideration of damages.
__________
1 A certificate of occupancy is issued when renovation of a struc-
ture has been completed in conformity with the earlier application
for a building permit and the building is found to be in compliance
with applicable zoning regulations and the building code. See 12
DCMR s 118, 39 DCR 8711-12.
See id. at 462. The subsequent proceedings in the district
court are at issue in this appeal.
The first trial began on April 14, 1998. Tri County pre-
sented evidence of its costs already incurred, evidence of lost
profits through the testimony of a mechanical engineer and
the report of an economist and evidence as to the local
market demand for a soil treatment facility through the
testimony of a geologist at an environmental consulting firm.
The District largely accepted the testimony, often failing to
object or seriously cross-examine. Instead, the District re-
lied on its argument that Tri County failed to mitigate its
damages when it refused to provide the information the
DCRA requested and when it declined to challenge the stop-
work and suspension orders. The District also sought to
demonstrate that Tri County might not have been allowed to
operate its facility because community opposition, arising
largely out of concern over the facility's effect on the health
and safety of the community, would derail the regulatory
procedures. Hindering its argument was the trial court's
exclusion or striking of evidence relating to health and safety
concerns. See Joint Appendix (JA) 186-89. The court found
the District's permitting process had resolved the issues as a
matter of law. See id. at 182-83, 189. In the end, the jury
awarded $5,000,000.
The trial court denied the District's post-trial motion for
judgment as a matter of law but granted the alternative
motion for a new trial, nisi remittitur to $1,000,000. Ad-
dressing the District's primary argument, the court ruled that
the District had to establish both the standard for reasonable
mitigation under the circumstances and that Tri County failed
to meet it. The District failed to sustain that burden, particu-
larly in light of Tri County's evidence that it would have to
spend nearly $1,000,000 to recoup its expenses of $536,421.
The court reversed field, however, in reviewing the award for
future damages which, assuming the $536,421 in costs were
awarded, constituted $4,463,579 of the $11,628,174 figure Tri
County presented to the jury. Emphasizing that Tri County
did not "invest[ ] a penny to seek reinstatement of the
unlawfully suspended building permit," the court ruled that
the District need not have established a reasonableness stan-
dard because Tri County's failure to mitigate was unreason-
able per se. District Court's Memorandum Order filed July
23, 1998 (Memorandum Order), at 2. The court also found
the lost profits evidence should not have been considered by
the jury without the District having the chance to prove that
the facility might not have been allowed to operate. Accord-
ingly, the court found the estimate of lost profits "too specula-
tive and remote" and, in any event, found the award "grossly
excessive." Id.
Tri County declined the $1,000,000 remittitur and a second
trial commenced on January 29, 1999. In this trial, the
district court allowed the District to admit the health and
safety evidence originally excluded. This time the District
challenged Tri County's experts and offered the testimony of
three new witnesses, one of whom refuted Tri County's
estimate of future profits. Another witness discussed a po-
tential zoning bar to the facility and the third discussed
health and safety hazards associated with soil remediation.
The second jury awarded Tri County nominal damages of
$100.
II.
We review the district court's grant of a new trial for abuse
of discretion. See Langevine v. District of Columbia, 106
F.3d 1018, 1023 (D.C. Cir. 1997) (citing Hutchinson v. Stuck-
ey, 952 F.2d 1418, 1420-21 (D.C. Cir. 1992)). "[A] more
searching inquiry is required" if the new trial is granted than
if denied, however, because of "the concern that a judge's
nullification of the jury's verdict may encroach on the jury's
important fact-finding function." Id. at 1023 (quoting Vander
Zee v. Karabatsos, 589 F.2d 723, 729 (D.C. Cir. 1978)).
In its post trial order, the trial court stated three reasons
for granting a new trial: (1) Tri County's failure to mitigate;
(2) the speculativeness in Tri County's projections of future
profits; and (3) the "grossly excessive" jury verdict. Memo-
randum Order at 2. The court also thought it had erred in its
evidentiary rulings excluding evidence related to community
opposition to the project. See Memorandum Order at 2
(plaintiff's expert testimony should not have been received
"without allowing [the District] to adduce proof that plaintiff's
soil remediation facility would never have been permitted to
operate"). Tri County challenges each ground.
First, the court found Tri County's failure to expend any
resources to seek reinstatement of its building permit per se
unreasonable in light of the $11,628,174 it claimed in lost
profits. See id. Tri County contends that the determination
of whether a party satisfied its duty to mitigate, a question
that turns on what action was reasonable under the circum-
stances, see, e.g., Berger v. Iron Workers Reinforced Rodmen,
Local 201, 170 F.3d 1111 (D.C. Cir. 1999); Lennon v. United
States Theatre Corp., 920 F.2d 996 (D.C. Cir. 1990), is a jury
question. Here, we agree with Tri County that its alleged
failure to mitigate was an issue properly submitted to the
jury. See Hilord Chem. Corp. v. Ricoh Elecs., Inc., 875 F.2d
32, 38-39 (2d Cir. 1989); Waldorf v. Shuta, 142 F.3d 601, 623-
24 (3d Cir. 1998). Moreover, failure to mitigate is an affirma-
tive defense and the party asserting it bears the burden of
demonstrating the opposing party's failure to act reasonably
under the circumstances. See Lennon, 920 F.2d at 1000; see
also Mark Keshishian & Sons, Inc. v. Washington Square,
Inc., 414 A.2d 834, 842 n.19 (D.C. 1980) (burden of showing
mitigation is on party raising issue) (citing Camalier &
Buckley-Madison, Inc. v. Madison Hotel, Inc., 513 F.2d 407,
419-20 n.92 (D.C. Cir. 1975)).
Tri County created a jury issue when it offered an explana-
tion for its failure to challenge the DCRA's suspension order
or otherwise pursue administrative remedies. Its explanation
included evidence that it believed suggested the reviewing
body, the District's Board of Appeals and Review, might not
have acted impartially due to political influence and that an
appeal would have been indefinitely slow and expensive.2
__________
2 Tri County's lawyer (in 1993) testified that Cross told him that
the Board of Appeals and Review would act at the direction of the
District's Mayor and the Mayor's chief of staff. Tri County intro-
duced Cross's deposition testimony indicating he had met with the
Moreover, a jury justifiably could have found it reasonable for
Tri County not to contest the September 22 stop-work order
and subsequent suspension resulting from the failure to pay
the fine given the pre-existing September 20 suspension.
The District argues simply that the evidence it presented
regarding Tri County's failure to mitigate "was firmer by
far." Brief of Appellee at 30. Tri County responds that it is
improper to now assess the relative strength of the parties'
showings. Indeed, the trial court properly gave the failure to
mitigate issue to the jury and properly instructed the jury on
that issue:
[T]he law requires that an injured party take all the
reasonable steps it can to avoid further injury and reduce
its loss. Tri County may not recover damages for any
portion of its injury which it could have avoided through
the exercise of reasonable care and prudence.... The
District asserts that Tri County by failing to pay the
$500 fine ... and by failing to appeal the stop work
order, is not entitled to any damages.
JA 193. Thus, to the extent the district court based its new
trial decision on the mitigation issue, it abused its discretion
in declaring ex post that Tri County's failure to pursue
administrative remedies to reinstate its permit was per se
unreasonable, thereby withdrawing the mitigation issue from
the jury. See generally Tatum v. Morton, 562 F.2d 1279,
1283 (D.C. Cir. 1977) ("[T]he district court's per se approach
of imposing an absolute duty to mitigate was not sound.").
The trial court also found that Tri County's evidence of lost
profits was "too speculative and remote" and that the award
of less than half of the amount Tri County estimated was
"grossly excessive." Memorandum Order at 2. Where, as
here, the fact of injury has been established and the defen-
dant's action (suspension of the building permit) affected the
plaintiff's ability to present actual revenue and cost figures to
__________
Mayor and members of the community opposition following the
suspension of the permit. Tri County's lawyer also testified that it
would have taken eight to twelve months to resolve the matter
administratively. JA 76-77.
support a lost profits projection, the applicable standard for
proving lost profits damages is the one this court enunciated
in Samaritan Inns, Inc. v. District of Columbia, 114 F.3d
1227 (D.C. Cir. 1997):
Where the tort itself is of such a nature as to preclude
the ascertainment of the amount of damages with cer-
tainty, it would be a perversion of fundamental principles
of justice to deny all relief to the injured person.... In
such case, while the damages may not be determined by
mere speculation or guess, it will be enough if the
evidence show the extent of the damages as a matter of
just and reasonable inference, although the result be only
approximate. Thus, while a plaintiff seeking to recover
lost profits must ordinarily prove the fact of injury with
reasonable certainty, proof of the amount of damages
may be based on a reasonable estimate. Although a
court will not permit a plaintiff to recover damages based
on "mere speculation or guess," the fact that an estimate
is uncertain or inexact will not defeat recovery....
114 F.3d at 1234-35 (quoting Story Parchment Co. v. Pater-
son Parchment Paper Co., 282 U.S. 555, 563 (1931)) (citations
omitted).
Tri County produced evidence indicating it sustained lost
profits of $11,628,174. The evidence included the testimony
of eight witnesses3 and ranged from projections of tons of
contaminated soil the facility would treat per hour and the
number of hours it would operate per day to estimates of
equipment and labor costs. With expert testimony regarding
the accessible market for soil remediation and a comparison
of service rates for similar operations, an economist projected
the profitability of Tri County's facility. Their respective
opinions were left largely unchallenged by the District. Re-
gardless whether the estimates were on the high end, that is,
__________
3 The witnesses included its President, Glenn Selzer, its Vice
President and its CPA. In addition, a chemical engineer, a remedi-
ation expert, a financial economist, a mechanical engineer and an
expert in soil remediation testified as to Tri County's costs and lost
profits.
"uncertain or inexact," Samaritan Inns, 114 F.3d at 1235,
they were sufficiently well-founded to avoid characterization
as "mere speculation or guess." Id.
Moreover, we question the trial court's finding that the
award "shock[ed] the judicial conscience." Memorandum Or-
der at 2. Tri County presented evidence that its costs
amounted to $536,421 and its lost profits amounted to
$11,628,174. The jury awarded $5,000,000, less than half of
the total amount claimed and, for that matter, less than half
of the future profits estimate standing alone. The award was
within the "reasonable range within which the jury may
properly operate." Langevine, 106 F.3d at 1024.
As demonstrated above, the trial court tried to cover all
bases in its order granting a new trial but the order reveals
that the court's real concern was its exclusion of evidence
regarding health and safety issues which may have led to
community resistance and, perhaps, regulatory barriers to Tri
County's project. For example, while declaring the award
grossly excessive, the district court expressed its dissatisfac-
tion with its original evidentiary rulings:
[T]he jury's award ... shocks the judicial conscience,
particularly in view of the realistic prospect, which I did
not permit defendants to prove at trial, that there would
be continued community resistance to increased dump
truck traffic ... and a very real likelihood that the
District of Columbia would have closed down the remedi-
ation facility ... or that it never would have been
permitted to commence operations at all.
Memorandum Order at 2-3; see also id. at 2 (plaintiff's
expert testimony should not have been received "without
allowing [the District] to adduce proof that plaintiff's soil
remediation facility would never have been permitted to
operate").
In the excerpt above, the district court alluded to the
District's argument under Carey v. Piphus, 435 U.S. 247,
266-67 (1978), that a plaintiff who suffers a procedural due
process violation is entitled only to nominal damages if he
would have suffered the same "injury" absent the violation.
Thus, the District argues that here the procedural violation
caused no compensable injury because the action taken, sus-
pension of the permit, was justified even if improperly execut-
ed. The District claimed that Tri County's damages were
minimal because the facility either would not have become
operational or would not have been operational for long due
to community resistance.
The trial court excluded the District's health and safety
evidence under Rule 403 and determined that the permitting
process disposed of these issues as a matter of law. See JA
178, 189. The District argues that the evidentiary rulings
practically negated its argument under Carey that the project
would have been halted anyway. Despite its reliance on this
argument, the District never met the trial court's repeated
injunction to show how the health and safety issue would have
triggered additional regulatory procedures or otherwise al-
lowed the District to rescind its earlier approval. See JA 172;
see also id. at 168-69, 172-75, 186-87. In short, the District
failed to show that community concern would be brought to
bear on Tri County's operation, specifically through the regu-
latory process. Accordingly, the district court did not abuse
its discretion in excluding the evidence. In light of our
findings that Tri County's evidence was properly before the
jury and the District's evidence was properly excluded, we
conclude that the district court, in granting a new trial based
on a revised view of its original rulings, did abuse its discre-
tion.4 See Langevine, 106 F.3d at 1023 (a "more searching
inquiry" is particularly necessary "when the motion [for new
trial] is granted on the ground that the verdict is against the
weight of the evidence").
For the foregoing reasons, we reverse the district court's
order of July 23, 1998 and reinstate the original jury verdict of
$5,000,000, with interest pursuant to 28 U.S.C. s 1961. The interest shall be
calculated at a rate of 5.391% per annum, beginning on April 20,
1998, and computed daily until the date of payment. See 28 U.S.C.A. s 1961
(West 1994 & Supp. 2000). We vacate the verdict and judgment resulting
from the second trial.
So ordered.
__________
4 In light of our holding, we need not reach Tri County's alterna-
tive grounds for reversal based on the second trial.