ARMED SERVICES BOARD OF CONTRACT APPEALS
Appeals of-- )
)
DayDanyon Corporation ) ASBCA Nos. 57611,57681,57717
)
Under Contract No. SPM8ED-09-D-0001 )
APPEARANCE FOR THE APPELLANT: Mr. JosephS. Jankowski
President
APPEARANCES FOR THE GOVERNMENT: Daniel K. Poling, Esq.
DLA Chief Trial Attorney
Joseph R. Weidenburner, Esq.
Assistant Counsel
Kristin K. Bray, Esq.
Assistant Trial Attorney
DLA Troop Support
Philadelphia, PA
OPINION BY ADMINISTRATIVE JUDGE JAMES
ON PARTIES' MOTIONS FOR SUMMARY JUDGMENT
These appeals arise from the DLA Troop Support (DLATS) contracting
officer's (CO) decisions which relate to DayDanyon Corporation's (DayDanyon) 6 April
2011, $720,700 claim (ASBCANo. 57611), appellant's claim dated 18 May 2011
(ASBCA No. 57717), and the government's claim of20 April2011 which terminated the
contract and its Delivery Order Nos. 0002 and 0003 for default (ASBCA No. 57681).
The Board has jurisdiction of the appeals under the Contract Disputes Act of 197 8
(CDA), 41 U.S.C. §§ 7101-7109. On 1 November 2013, the government moved for
summary judgment on the three appeals. On 12 November 2013, appellant moved for
summary judgment on ASBCA Nos. 57611 and 57717. On 27 November 2013, the
government responded to appellant's motion. Appellant opposed respondent's motion on
6 December 20 13.
STATEMENT OF FACTS (SOF) FOR PURPOSES OF THE MOTIONS
1. On 23 April 2009, the Defense Supply Center Philadelphia, whose name was
changed to DLA Troop Support, awarded Contract No. SPM8ED-09-D-0001 (the
contract) to DayDanyon for Collapsible Joint Modular Intermodal Containers (JMIC)
(R4, tab 4 at 1-2 of21).
2. The contract had four contract line item numbers (CLINs). CLINs 0001-0003
each stated an estimated quantity of 500 JMICs. CLIN 0001 JMICs were to be painted
green, CLIN 0002 tan, and CLIN 0003 not painted. CLIN 9906 was for first article test.
(R4, tab 4 at 1-3 of21, 12 of21)
3. The contract stated:
This is a[ n] Indefinite Quantity Contract. Orders may be
issued on this contract for a period of TWO YEARS.
First Article Test quantities of 2 each are due to the
government test facility ... on or before 150 days after date of
award ....
After First Article Test approval, the required delivery for
production quantities under this contract is 120 days after the
date of the resulting delivery orders.
The Guaranteed Minimum is a total of 500 containers,
whether placed for a single CLIN, or combination of CLINS
that collectively total 500 containers. The guaranteed
minimum is 500 containers per year. Since this is a two year
base contract the minimum quantity is multiplied by 2.
(R4, tab 4 at 2 of21)
4. The contract incorporated, inter alia, the FAR 52.209-4, FIRST ARTICLE
APPROVAL- GOVERNMENT TESTING (SEP 1989); FAR 52.216-18, ORDERING (OCT 1995);
FAR 52.216-19, ORDER LIMITATIONS (OCT 1995); FAR 52.216-22, INDEFINITE QUANTITY
(OCT 1995); FAR 52.249-2, TERMINATION FOR CONVENIENCE OF THE GOVERNMENT
(FIXED-PRICE) (MAY 2004); and FAR 52.249-8, DEFAULT (FIXED-PRICE SUPPLY AND
SERVICE)(APR 1984) clauses (R4, tab 4 at 16-17 of21, 21 of21).
5. As relevant to these disputes: (a) the FAR 52.216-18, ORDERING (OCT 1995)
clause provided in pertinent part:
(a) Any supplies and services to be furnished under this
contract shall be ordered by issuance of delivery orders or
task orders by the individuals or activities designated in the
Schedule. Such orders may be issued -
2
FROM: DATE OF CONTRACT AWARD
THROUGH: TWO (2) YEARS
(b) All delivery orders or task orders are subject to the
terms and conditions of this contract. In the event of conflict
between a delivery order or task order and this contract, the
contract shall control.
and (b) the FAR 52.216-22, INDEFINITE QUANTITY (OCT 1995) clause provided:
(a) This is an indefinite-quantity contract for the
supplies or services specified, and effective for the period
stated, in the Schedule. The quantities of supplies and
services specified in the Schedule are estimates only and are
not purchased by this contract.
(b) Delivery or performance shall be made only as
authorized by orders issued in accordance with the Ordering
clause. The Contractor shall furnish to the Government,
when and if ordered, the supplies or services specified in the
Schedule up to and including the quantity designated in the
Schedule as the "maximum." The Government shall order at
least the quantity of supplies or services designated in the
Schedule as the "minimum."
(c) Except for any limitations on quantities in the
Order Limitations clause or in the Schedule, there is no limit
on the number of orders that may be issued. The Government
may issue orders requiring delivery to multiple destinations or
performance at multiple locations.
(d) Any order issued during the effective period of
this contract and not completed within that period shall be
completed by the Contractor within the time specified in the
order. The contract shall govern the Contractor's and
Government's rights and obligations with respect to that order
to the same extent as if the order were completed during the
contract's effective period; provided, that the Contractor shall
not be required to make any deliveries under this contract
after Two Years[.]
3
(R4, tab 4 at 16-17 of21) The record contains no evidence that DayDanyon sought from
the CO clarification of the term "Two Years" in the above-quoted contract provisions.
6. On 4 June 2009, DLATS issued a Stop-Work Order on the contract. Bilateral
Contract Modification No. POOOOI, executed on 2 July 2009, authorized resumption of
contract work. (R4, tab 11 at 1-2 of 4)
7. On 16 December 2009, DayDanyon shipped two JMICs for government first
article testing (R4, tab 34 at 1), with respect to which the test center found 27 major and
15 minor defects as reported on 13 January 2010 (R4, tab 38 at 1-8).
8. On 3 March 2010, DayDanyon submitted two JMICs, with respect to which the
test center found 2 major and 5 minor defects as reported on 30 March 2010 (R4, tab 43
at 1-9).
9. DLA TS' 6 April 2010 letter to DayDanyon noted conditional acceptance of the
first article, provided that DayDanyon submit a corrective action plan addressing such
deficiencies, which plan DayDanyon submitted on or about 7 April 2010 and DLATS
approved on or about 9 April 2010 (R4, tabs 46, 4 7, 49). DLATS authorized DayDanyon
to begin production on 29 April2010 (R4, tab 51).
10. On 3 May 2010, DLATS issued Delivery Order No. 0002 (DO 2) for 100 units
NSN- 5795 (tan), and Delivery Order No. 0003 (DO 3) for 400 units NSN- 5311
(unpainted); these two DOs were ordered under CLIN "000 1" (NSN - 5802, green)
notwithstanding the color discrepancy. Both DOs had a delivery date of29 March 2010,
later corrected to 31 August 2010, 120 days from receipt of order. (R4, tabs 53-56)
11. On 5 August 2010, the CO issued unilateral DO 2 Modification No. 000203
extending the delivery date for 100 tan painted JMICs from 31 August 2010 to 15 October
2010, and unilateral DO 3 Modification No. 000302 extending the delivery date for
300 unpainted JMICs from 31 August 2010 to 30 September 2010 and for the 100 balance
of unpainted JMICs from 31 August 2010 to 15 October 2010 (R4, tabs 73-74).
12. Effective 23 November 2010, bilateral DO 2 Modification No. 000204
extended the delivery date for 100 tan JMI Cs to 15 March 20 11, and bilateral DO 3
Modification No. 000303 extended the delivery date for 400 unpainted JMICs to 8 March
2011 (R4, tabs 84-86). These modifications clarified the foregoing discrepancies
between CLIN and NSN numbers (see SOF ~ 10) on the DOs and provided:
INCONSIDERATION OF THIS REVISED DELIVERY
SCHEDULE, CONTRACTOR HEREBY
UNCONDITIONALLY RELEASES AND WAlVES ALL
CLAIMS AGAINST THE GOVERNMENT BY REASON
4
OF DELAYS ATTRIBUTABLE TO EXCUSABLE
CAUSES WHICH HAVE OR MAY HAVE OCCURRED IN
THIS CONTRACT AND FOR ALL OTHER CAUSES,
CONDITIONS AND HAPPENINGS WHICH HAVE
OCCURRED UNDER THIS CONTRACT TO DATE.
(R4, tab 84 at 2)
13. DayDanyon stated in response to government interrogatories that due to
exceptional weather events on 15-16 December 2010, 25-26 December 2010 and
9-10 January 2011, "DayDanyon was closed and directly lost five days of production."
We take judicial notice that DayDanyon's plant is located in Hart County, Georgia. The
accompanying National Weather Service reports showed neither the historic normal
weather nor any unusually severe weather for Hart County on such dates. DayDanyon
also stated that-
[D]elays in delivering of JMICS were partially caused by the
inability of two suppliers/subcontractors to guarantee delivery
dates of certain automated production set-ups by mid-January
2011 for early February 2011 delivery. This resulted in
DayDanyon having to develop alternative methods and
processes utilizing components it had available in-house or
were readily available off the shelf, over the course of late
January and through February 20 11.
These actions/inactions occurred [during] the latter part of
December, 2010 until mid-January, 2011.
(App. supp. R4, tab 46 at 5-21, 23, 25)
14. After several DCMA visits to DayDanyon's facility and DayDanyon reports
of deliveries of contract materials, on 22 February 2011, the CO sent DayDanyon a cure
notice stating that contract performance was endangered by lack of progress, noting the
impending DO 2 and DO 3 delivery dates and giving DayDanyon 10 days to cure such
conditions (R4, tab 106 at 2-3).
15. On 2 March 2011, DayDanyon told the CO that, "we can begin shipments
soon" (R4, tab 110), "a major portion of the performance has been completed, and the
remainder will be finished shortly" (R4, tab 111 ), and on 4 March 2011 stated that "[t]he
first three shipments of JMICs, comprised of 100 - 200 units per shipment, have been
5
loaded into the DCMA SIR System. These will occur beginning later this month." (R4,
tab 112)
16. From 11 March 2011 to 15 April 2011, DayDanyon and DLATS had several
email exchanges regarding: (a) CO's status of progress inquiries and DayDanyon replies
that JMICs components were arriving and side and access panel sheets were being
assembled on 16 March 2011 (R4, tabs 117, 123-24; app. supp. R4, tabs 9-12);
(b) DayDanyon's order of"[seven] custom designed ... process stations for high
production of JMICs" (R4, tab 114) of which two stations were received and operating on
about 22-23 March 2011 (R4, tabs 119-20); (c) DCMA's 28 March 2011 email to
DayDanyon inquiring whether DLA had indicated if it would extend the contract
performance period, and advising of a new QAR, Mr. Robert Strain (app. supp. R4, tab
10) and (d) DayDanyon's JMIC shipment projections for 30 March 2011, 14 April2011
and 22 April2011 {app. supp. R4, tab 16). DayDanyon did not receive all the JMIC parts
before the 8 and 15 March 2011 delivery dates (R4, tabs 114-15). DayDanyon began
JMIC assembly on 22 March 2011, but did not tender any JMICs for inspection by
DCMA, and delivered no JMICs to DLATS (R4, tabs 120, 125 at 5).
17. DayDanyon sent to the CO a $720,700 claim, dated and certified on 6 April
2011, alleging that DLATS had failed to place delivery orders for an additional
500 JMICs by 24 December 2010, which the contract required (R4, tab 121 at 2-3).
18. CO Joseph J. McHenry's 8 April2011 letter responding to DayDanyon's
6 April 2011 claim stated that "the two year base period for [the contract] expires on
April 23rd, 2011. Therefore, your claim is premature. If you wish, you may file your
claim after the base period has expired." (R4, tab 122 at 2) On 27 April2011,
DayDanyon appealed from that letter on the basis of a deemed denial, which the Board
docketed as ASBCA No. 57611.
19. On 20 April2011, CO McHenry issued: (a) unilateral contract Modification
No. P0004 which terminated the contract for default and advised DayDanyon of its
appeal rights (R4, tab 125); and (b) unilateral Modification Nos. 000205 and 000304
terminating DOs 2 and 3 for default (R4, tab 126} On 11 July 2011, DayDanyon
appealed from these decisions, which was docketed as ASBCA No. 57681.
20. DayDanyon sent CO McHenry a $720,700 claim, dated and certified on
18 May 2011, which aside from that date, was materially identical with its 6 April 2011
claim (R4, tab 127).
21. CO Mark L. Scott's 15 July 2011 decision denied DayDanyon's 18 May 2011
claim in its entirety and advised DayDanyon of its appeal rights (R4, tab 128).
DayDanyon appealed from that decision on 29 July 2011, which was docketed as
ASBCA No. 57717.
6
DECISION
Preliminarily, the government has not questioned the sufficiency under the CDA
ofDayDanyon's 6 April2011 certified claim or the validity of the Board's CDA
jurisdiction over ASBCA No. 57611 on a deemed denial basis, nor does the Board.
DayDanyon's 6 April2011 and 18 May 2011 claims are materially identical and differ
only as to their dates (SOF ~ 20). Accordingly, we dismiss ASBCA No. 57717 as
duplicative of ASBCA No. 57611.
A tribunal shall grant summary judgment if the movant shows that there is no
genuine issue as to any material fact and the movant is entitled to judgment as a matter of
law. FED. R. CIV. P. 56(a); Anderson v. Liberty Lobby, Inc., 477 U.S. 242, 247 (1986).
Summary judgment properly may be granted to a party when the non-moving party fails to
offer evidence on an element essential to its case and on which it bears the burden of proof
at trial. Celotex Corp. v. Catrett, 477 U.S. 317, 322-23 (1986). In considering a motion for
summary judgment, the evidence of the non-moving party is to be believed, and all
justifiable inferences are to be drawn in its favor. Liberty Lobby, 477 U.S. at 247. The
government moves for summary judgment on the default termination, ASBCA No. 57681.
The parties cross-move for summary judgment on DayDanyon's breach claim in ASBCA
No. 57611.
These appeals present the following issues: (1) in ASBCA No. 57681, whether
DLATS properly terminated the contract for default due to DayDanyon's failures to
remedy the conditions endangering contract performance and to deliver 500 JMICs
pursuant to the last extended delivery dates; (2) in ASBCA No. 57611, whether DLATS
breached the contract by not ordering the 1000 guaranteed minimum JMICs (SOF ~ 3) by
24 December 2010, as DayDanyon claims.
I. Default
Our SOF extracted the material facts proposed in the government's motion and
added some facts proposed by appellant in SOF ~~ 5, 13, 15 and 16. Neither party has
raised any genuine issue of material fact with respect to such facts (see gov't resp. at 2-6;
app. opp'n at 2-10).
The government has the burden of proof that its default termination was justified.
See Nuclear Research Corp. v. United States, 814 F.2d 647, 650 (Fed. Cir. 1987). A
contractor's failure to make timely delivery of agreed-upon goods establishes a prima
facie case of default. !d. The burden then shifts to the contractor to show that the failure
to deliver the contract goods was excusable. See DCX, Inc. v. Perry, 79 F .3d 132, 134
(Fed. Cir. 1996), cert. denied, 519 U.S. 992 (1996).
7
The last extended delivery dates were 8 March 2011 for 400 unpainted JMICs
under DO 3 and 15 March 2011 for 100 tan JMICs under DO 2 (SOF ~ 12). By
15 March 2011 DayDanyon had delivered no JMICs to DLATS (SOF ~ 16). Thus, the
government prima facie has established that DayDanyon was in default for failure to
deliver the supplies by those March 2011 dates under paragraph (a)(l)(i) of the contract's
FAR 52.249-8, Default clause.
DayDanyon argues that DLATS was required to extend the delivery dates by five
days due to "exceptional weather events" on 15-16 December 2010, 25-26 December 2010
and 9-10 January 2011 (app. opp'n at 11; SOF ~ 13). The record contains evidence of
neither the historic normal weather nor any unusually severe weather for Hart County on
such dates (SOF ~ 13). Thus, the record contains no proof of "unusually severe weather"
under paragraph (c)(9) of the contract's FAR 52.249-8, Default clause. See All-State
Construction, Inc., ASBCA No. 50513 eta!., 04-2 BCA ~ 32,778 at 162,082-84 (number of
days of excusable weather delay determined by comparing experienced rain and snowfall
to "historic normal" rain and snowfalls). Even if, arguendo, Hart County experienced
''unusually severe weather" on those dates, that five-day delay would not excuse
DayDanyon's failure to deliver timely.
It remains to analyze DayDanyon's argument that by delaying its termination to
20 April 2011 with "full knowledge that the Contractor was continuing production and
progress," the government waived the contractor's default for failure to deliver
400 unpainted JMICs by 8 March 2011 and 100 tan JMICs by 15 March 2011
(app. opp'n at 11). To prove waiver of default, a contractor must show: (1) failure to
terminate within a reasonable time after default under circumstances indicating
forbearance; and (2) reliance by the contractor on the failure to terminate and continued
performance by him under the contract, with the Government's knowledge and implied
or express consent. DeVito v. United States, 413 F.2d 1147, 1153-54 (Ct. Cl. 1969)
(CO waived delivery date when he knew that the contractor, during the month after the
due date passed, made four deliveries, and the government accepted 420 of 1,000 units,
which activities constituted substantial reliance on the CO's failure to terminate).
We focus on whether, after the D02 and D03 delivery dates had passed, the CO's
and DCMA's inquiries about DayDanyon's production status, DCMA's identification of
a new QAR at DayDanyon 1 and DayDanyon's projection of JMIC deliveries on
1
DayDanyon asserts that DCMA's Mr. Oppedisano's reports and photos on the status of
DayDanyon's JMIC materials and assembly showed "bad faith" because they
conflict with Mr. Jankowski's views on that status (app. reply br. at 7-10). Those
views do not meet the "clear and convincing proof' of a specific intent to injure
the contractor criterion to overcome the strong presumption of good faith actions
of a government official. See Am-Pro Protective Agency, Inc. v. United States,
281 F.3d 1234, 1239-40 (Fed. Cir. 2002).
8
30 March, 14 April and 22 Apri12011 (SOF ~ 16), amounted to the CO's implied consent
to its continued performance after default. Board decisions do not provide clear guidance
with respect to our fact pattern. E.g., DCX-CHOL Enterprises, Inc., ASBCA No. 54707,
08-2 BCA ~ 33,389 at 167,730 (after contractor defaulted, even though the government
knew that the contractor was continuing performance and accepted 32 of278 delinquent
items, the 84 to 176-day period from default to notice of termination was not
unreasonable; appeal denied); cf ACR Machine, Inc., ASBCA No. 54734, 06-2 BCA
~ 33,383 at 165,504 (p.ost-default, a government industrial specialist, unbeknownst to the
CO, asked the contractor for a new realistic delivery schedule; government motion for
summary judgment denied). Mindful that the evidence of the non-moving party on the
waiver issue (here, DayDanyon) is to be believed, and all justifiable inferences are to be
drawn in its favor, Liberty Lobby, 477 U.S. at 247, we hold that the present appeal record
is insufficiently developed to grant respondent's motion on ASBCA No. 57681.
II. Breach
As stated above, neither party has raised any issue of genuine material fact. We
tum to the issue of whether DayDanyon or the government is entitled as a matter of law
to judgment on its breach of contract claim. DayDanyon claims that DLATS failed to
place delivery orders by 24 December 2010 for 500 additional JMICs (SOF ~ 17; app.
mot. at 12-13) and thus breached the contract.
The FAR 52.216-18 Ordering and 52.216-22 Indefinite Quantity clauses have
different purposes. The FAR 52.216-18 clause defines the period for ordering supplies as
the "DATE OF CONTRACT AWARD ... THROUGH: TWO (2) YEARS" (SOF ~ 5(a)).
FAR 52.216-22(d) provides:
(d) Any order issued during the effective period of this
contract and not completed within that period shall be
completed by the Contractor within the time specified in the
order. The contract shall govern the Contractor's and
Government's rights and obligations with respect to that order
to the same extent as if the order were completed during the
contract's effective period; provided, that the Contractor shall
not be required to make any deliveries under this contract
after Two Years. [Bold added]
(SOF ~ 5(b))
DayDanyon interprets the FAR 52.216-18 period for issuing orders under this
contract "FROM: DATE OF CONTRACT A WARD THROUGH: TWO (2) YEARS"
(SOF ~ 5(a)) as the same "Two Years" specified in the proviso ofFAR 52.216-22(d), and
concludes that DLATS had to order an additional 500 JMICs by "24 December 201 0"
9
(contract award date plus 2 years less 120 days for delivery) (app. mot. at 12-13) in order
for the government to obtain delivery within 2 years of contract award, or by 23 April
2011. DayDanyon's interpretation reduces the effective period for ordering from the
specified "TWO (2) YEARS" to 20 months, and renders meaningless or superfluous the
provisions ofFAR 52.216-22(d), first, that orders issued within the effective period of the
contract but not completed within the effective period of ordering are to be completed
within the time specified by the order and second, the contract governs the parties' rights
and duties under orders not so completed to the same extent as if the orders were
completed during the contract's effective period. DayDanyon's interpretation violates
the contract interpretation rules to harmonize and give reasonable meaning to all parts of
a contract and to render no provision useless, meaningless, inoperative or superfluous.
See Precision Dynamics, Inc., ASBCA No. 50519,05-2 BCA ~ 33,071 at 163,922. We
hold that DayDanyon's interpretation is unreasonable. We therefore must deny
appellant's motion for summary judgment. Since the government did not breach the
contract by failing to order an additional 500 units by 24 December 2010, 2 we grant the
government's motion for summary judgment.
If we were to assume, arguendo, that the term "two years" appearing in the FAR
52.216-18 Ordering clause and in~ (d) ofthe FAR 52.216-22 Indefinite Quantity clause
was inconsistent or ambiguous, such ambiguity was patent. DayDanyon did not seek
clarification before contract award (SOF ~ 5), so such arguable ambiguity is resolved
against the contractor. See Triax Pacific, Inc. v. West, 130 F.3d 1469, 1475 (Fed. Cir.
1997).
CONCLUSION
We grant the government's motion for summary judgment in ASBCA No. 57611,
deny appellant's motion for summary judgment in ASBCA No. 57611 and deny that
appeal. We deny government's motion for summary judgment in ASBCA No. 57681.
We dismiss ASBCA No. 57717 as duplicative.
Dated: 22 January 2014
of Contract Appeals
(Signatures continued)
2
Once the contract was terminated by the government, the government had no further
duty to order additional units.
10
I concur I concur
~~
-MARK N. STEMPLER
Administrative Judge Administrative Judge
Acting Chairman Acting Vice Chairman
Armed Services Board Armed Services Board
of Contract Appeals of Contract Appeals
I certify that the foregoing is a true copy of the Opinion and Decision ofthe
Armed Services Board of Contract Appeals in ASBCA Nos. 57611, 57681, 57717,
Appeals ofDayDanyon Corporation, rendered in conformance with the Board's Charter.
Dated:
JEFFREY D. GARDIN
Recorder, Armed Services
Board of Contract Appeals
11