Pelco Construction Company v. Chambers County, Texas, Kurt Amundson, and Amundson Consulting, Inc.

Opinion issued September 3, 2015

In The

Court of Appeals
For The

First District of Texas
————————————
NO. 01-14-00317-CV
———————————
PELCO CONSTRUCTION COMPANY, Appellant
V.
CHAMBERS COUNTY, TEXAS, KURT AMUNDSON, AND AMUNDSON
CONSULTING, INC., Appellees

On Appeal from the 344th District Court
Chambers County, Texas
Trial Court Case No. CV-26356

OPINION

Pelco Construction Company filed suit against Chambers County, Texas,

Kurt Amundson, and Amundson Consulting, Inc. over a construction contract.

Chambers County counter-sued. The trial court granted summary judgment on

liability in favor of Chambers County and Amundson Consulting on all claims in
the suit. The parties then proceeded to trial on Chambers County’s damages for its

breach of contract claim. The jury awarded Chambers County $151,879.50. The

trial court granted Chambers County’s motion for judgment notwithstanding the

verdict and rendered a verdict of $404,179.31 in damages. In five issues on

appeal, Pelco argues the trial court erred by (1) granting summary judgment in

favor of Chambers County on both parties’ breach of contract claims, (2) granting

the judgment notwithstanding the verdict, (3) refusing to include a proper

mitigation question in the jury charge, (4) granting summary judgment on Pelco’s

claims against Amundson Consulting, and (5) awarding attorneys’ fees.

We reverse and remand for a new trial.

Background

In 2008, Hurricane Ike landed on the Texas coast. Among the damage, the

Oak Island firehouse was destroyed. Chambers County developed plans to rebuild

the firehouse based on funding from the Federal Emergency Management Agency

(“FEMA”). Chambers County solicited bids. As a part of that process, officials

from Chambers County along with representatives of its architect, Dannenbaum

Engineering Corp., and representatives of Amundson Consulting met with

representatives of Pelco to discuss the project. Pelco alleges that, during that

meeting, Amundson represented that FEMA had approved funding for the

construction project.

2
 Pelco bid on the project and was awarded the contract. During construction

of the firehouse, Pelco submitted two applications for payment based on money it

had already expended and earned. More than two months after Pelco submitted the

first application for payment, Dannenbaum certified 90% of the application for

payment. Chambers County paid the certified amount three days before

certification. Over one month after Pelco submitted the second application for

payment, Dannenbaum certified 90% of the application for payment. Chambers

County paid the certified amount seven days after certification.

On October 28, 2010, Amundson called Pelco, instructing them to stop work

on the project. According to Pelco, Amundson stated that FEMA had ordered the

work to stop due to the project plans not being approved for funding. That same

day, Dannenbaum sent a letter to Pelco instructing Pelco to stop work on the

project. Dannenbaum explained in the letter that “[t]he ceasing of the construction

operation is required while required administrative paper work for the construction

of the project is reviewed and approved by FEMA.” Dannenbaum said it would

inform Pelco when work could resume.

Forty days later, Dannenbaum sent Pelco a letter instructing it to resume

construction on the project. Pelco sent Dannenbaum a letter in response giving

notice of its termination of the contract based on a certain provision of the contract.

3
 Pelco subsequently filed suit against Chambers County, Dannenbaum,

Amundson Consulting, and Amundson. The trial court dismissed Dannenbaum

from the suit based on Pelco’s failure to file a certificate of merit, and we

affirmed. 1 Pelco asserted, among other things, a breach of contract claim against

Chambers County. Pelco asserted fraudulent misrepresentation and negligent

misrepresentation claims against Amundson and Amundson Consulting.

Chambers County asserted a breach of contract counter-claim against Pelco.

In the course of litigation, the parties filed multiple motions for summary

judgment. Ultimately, the trial court granted summary judgment against Pelco on

its breach of contract claim. It also granted summary judgment on liability in favor

of Chambers County on its breach of contract claim. Subsequently, the trial court

granted summary judgment in favor of Amundson and Amundson Consulting on

Pelco’s fraudulent misrepresentation and negligent misrepresentation claims.

After all of the motions for summary judgment, the only issue remaining

was Chambers County’s damages on its breach of contract claim. After a jury

trial, the trial court granted a motion notwithstanding the verdict and awarded

Chambers County its full claim for damages and attorneys’ fees.

1
See Pelco Constr., Inc. v. Dannenbaum Eng’g Corp., 404 S.W.3d 48, 57 (Tex.
App.—Houston [1st Dist.] 2013, no pet.).

4
 Summary Judgment

In its first issue, Pelco asserts that the trial court erred by granting summary

judgment on liability against Pelco and in favor of Chambers County on both

parties’ breach of contract claims. In its fourth issue, Pelco asserts that the trial

court erred by granting summary judgment against Pelco on its fraudulent

misrepresentation and negligent misrepresentation claims against Amundson and

Amundson Consulting.

A. Standard of Review

The summary-judgment movant must conclusively establish its right to

judgment as a matter of law. See MMP, Ltd. v. Jones, 710 S.W.2d 59, 60 (Tex.

1986). Because summary judgment is a question of law, we review a trial court’s

summary judgment decision de novo. See Mann Frankfort Stein & Lipp Advisors,

Inc. v. Fielding, 289 S.W.3d 844, 848 (Tex. 2009).

To prevail on a “traditional” summary-judgment motion asserted under Rule

166a(c), a movant must prove that there is no genuine issue regarding any material

fact and that it is entitled to judgment as a matter of law. See TEX. R. CIV. P.

166a(c); Little v. Tex. Dep’t of Criminal Justice, 148 S.W.3d 374, 381 (Tex. 2004).

A matter is conclusively established if reasonable people could not differ as to the

conclusion to be drawn from the evidence. See City of Keller v. Wilson, 168

S.W.3d 802, 816 (Tex. 2005).

5
 When it moves for summary judgment on a claim for which it bears the

burden of proof, a party must show that it is entitled to prevail on each element of

its cause of action. See Parker v. Dodge, 98 S.W.3d 297, 299 (Tex. App.—

Houston [1st Dist.] 2003, no pet.). The party meets this burden if it produces

evidence that would be sufficient to support an instructed verdict at trial. Id.

In contrast, a party moving for traditional summary judgment on a claim for

which it does not bear the burden of proof must either (1) disprove at least one

element of the plaintiff’s cause of action or (2) plead and conclusively establish

each essential element of an affirmative defense to rebut the plaintiff’s cause. See

Am. Tobacco Co., Inc. v. Grinnell, 951 S.W.2d 420, 425 (Tex. 1997). If the

movant meets its burden, the burden then shifts to the nonmovant to raise a

genuine issue of material fact precluding summary judgment. See Centeq Realty,

Inc. v. Siegler, 899 S.W.2d 195, 197 (Tex. 1995).

After an adequate time for discovery, the party without the burden of proof

may move for a no-evidence summary judgment on the basis that there is no

evidence to support an essential element of the non-moving party’s claim. TEX. R.

CIV. P. 166a(i); Hamilton v. Wilson, 249 S.W.3d 425, 426 (Tex. 2008). Summary

judgment must be granted unless the non-movant produces competent summary

judgment evidence raising a genuine issue of material fact on the challenged

elements. TEX. R. CIV. P. 166a(i); Hamilton, 249 S.W.3d at 426. A non-moving

6
party is “not required to marshal its proof; its response need only point out

evidence that raises a fact issue on the challenged elements.” TEX. R. CIV. P. 166a

(Notes & Comments 1997).

A no-evidence summary judgment motion is essentially a motion for a

pretrial directed verdict. Mack Trucks, Inc. v. Tamez, 206 S.W.3d 572, 581 (Tex.

2006). Accordingly, we apply the same legal-sufficiency standard of review that

we apply when reviewing a directed verdict. City of Keller, 168 S.W.3d at 823.

Applying that standard, a no-evidence point will be sustained when (1) there is a

complete absence of evidence of a vital fact, (2) the court is barred by rules of law

or evidence from giving weight to the only evidence offered to prove a vital fact,

(3) the evidence offered to prove a vital fact is no more than a mere scintilla, or (4)

the evidence conclusively establishes the opposite of a vital fact. King Ranch, Inc.

v. Chapman, 118 S.W.3d 742, 751 (Tex. 2003); see City of Keller, 168 S.W.3d at

810.

To determine whether there is a fact issue in a motion for summary

judgment, we review the evidence in the light most favorable to the non-movant,

crediting favorable evidence if reasonable jurors could do so, and disregarding

contrary evidence unless reasonable jurors could not. See Fielding, 289 S.W.3d at

848 (citing City of Keller, 168 S.W.3d at 827). We indulge every reasonable

7
inference and resolve any doubts in the non-movant’s favor. Sw. Elec. Power Co.

v. Grant, 73 S.W.3d 211, 215 (Tex. 2002).

B. Pelco’s Breach of Contract Claims

It is undisputed that Pelco’s December 14, 2010 letter terminating the

construction contract would constitute a material breach of the contract. If there

was a prior material breach by Chambers County, however, then the December 14

breach was excused. See Mustang Pipeline Co., Inc. v. Driver Pipeline Co., Inc.,

134 S.W.3d 195, 196 (Tex. 2004) (holding prior material breach by one party

excuses further performance of other party). Our inquiry is limited, then, to events

before December 14, 2010.

At trial, Pelco identified a number of actions taken by Chambers County that

it claimed constituted a prior material breach by Chambers County. On appeal,

Pelco limits its argument to Chambers County’s failure to pay the full amount

invoiced in Pelco’s first two requests for payment. Accordingly, we further limit

our review to whether Chambers County’s failure to pay the full amounts invoiced

constitutes a prior material breach. See Walling v. Metcalfe, 863 S.W.2d 56, 58

(Tex. 1993) (“We have held repeatedly that the courts of appeals may not reverse

the judgment of a trial court for a reason not raised in a point of error.”); In re

E.A.F., 424 S.W.3d 742, 749 (Tex. App.—Houston [14th Dist.] 2014, pet. denied)

(same).

8
 As an initial matter, Chambers County argues that the trial court resolved

this issue as part of a no-evidence motion for summary judgment to which Pelco

did not respond. Accordingly, Chambers County argues, the trial court’s order on

this motion presents an independent basis for upholding the trial court’s ruling on

liability. We disagree that this motion asserted a no-evidence motion for summary

judgment on Pelco’s breach of contract claim.

The no-evidence motion does not indicate it sought summary judgment on

Pelco’s breach of contract claim. For example, it is entitled “Defendant Chambers

County, Texas’ No Evidence and Traditional Partial Motion for Summary

Judgment as to Plaintiff’s Contract Termination Rights and Defendant’s Breach of

Contract Claim.” While the title references Pelco’s rights to terminate the contract,

it only claims summary judgment on Chamber County’s breach of contract claim.

More significantly, the substance of the no-evidence motion establishes that

Chambers County did not move for summary judgment on Pelco’s breach of

contract claim. For a no-evidence motion for summary judgment, the movant must

“state the elements as to which there is no evidence.” TEX. R. CIV. P. 166a(i). This

rule “does not authorize conclusory motions or general no-evidence challenges to

an opponent’s case.” TEX. R. CIV. P. 166a (Notes & Comments 1997); accord

Timpte Indus., Inc. v. Gish, 286 S.W.3d 306, 310 (Tex. 2009). In the motion,

Chambers County asserted in its paragraph establishing the law relevant to no-

9
evidence motions that “Pelco still has presented no evidence that it was entitled to

terminate the Contract under its terms.” For its breach of contract claim, however,

Pelco carried no burden of showing that it was entitled to terminate the contract.

Instead, it was required to prove that Chambers County breached the contract. See

Bank of Tex. v. VR Electric, Inc., 276 S.W.3d 671, 677 (Tex. App.—Houston [1st

Dist.] 2008, pet. denied) (holding elements for breach of contract include showing

plaintiff performed or tendered performance and defendant breached contract).

Similarly, in its request for relief, Chambers County asked the trial court to

“enter judgment in favor of Chambers County on its breach of contract claim

against Pelco holding that Pelco breached its Contract with Chambers County by

terminating the Contract and refusing to perform.” (Emphasis added.) Chambers

County makes no mention of Pelco’s breach of contract claim and does not ask for

relief on it.

Furthermore, shortly after it filed the no-evidence motion in question,

Chambers County filed a traditional and no-evidence motion for summary

judgment on Pelco’s breach of contract claim. Pelco responded to that motion.

Before it ruled on the no-evidence motion in question, the trial court had already

granted Chambers County’s motion for summary judgment on Pelco’s breach of

contract claim. Chambers County would have us hold, then, that the trial court’s

ruling on its motion for summary judgment on its breach of contract claim

10
constitutes a reconsideration of the claims that the court had already disposed of

and that had been presented by the party that had already prevailed. The record

does not support such a conclusion.

Turning to the traditional and no-evidence motion for summary judgment on

Pelco’s breach of contract claim, we must first consider whether Pelco carried its

burden on Chambers County’s no-evidence portion of the motion. See Merriman

v. XTO Energy, Inc., 407 S.W.3d 244, 248 (Tex. 2013) (holding, when party

moves for summary judgment on both traditional and no-evidence grounds,

appellate courts first address no-evidence grounds).

One of the grounds presented by Pelco for why it could proceed on its

breach of contract claim was “Chambers County breached the contract by

withholding the retainage funds owed to Pelco.” All parties acknowledge that

Peclo submitted three requests for payment to Chambers County, that Chambers

County withheld 10% of the amount owed on the first two requests for payment,

and that Chambers County has not paid any of the third invoice. The

determination of whether timely performance—in this case, timely payment of full

amounts of the invoices submitted—is a material term of the contract is typically a

fact question for the jury. Breof BNK Texas, L.P. v. D.H. Hill Advisors, Inc., 370

S.W.3d 58, 64 (Tex. App.—Houston [14th Dist.] 2012, no pet.); Deep Nines, Inc.

v. McAfee, Inc., 246 S.W.3d 842, 846 (Tex. App.—Dallas 2008, no pet.); see also

11
N.Y. Party Shuttle, LLC v. Bilello, 414 S.W.3d 206, 215 n.1 (Tex. App.—Houston

[1st Dist.] 2013, pet. denied) (“The failure to make a complete payment when due

under a contract may constitute a material breach.”).

In its reply to Pelco’s response to the motion for summary judgment,

Chambers County asserts that it was only required to pay the amount certified by

Dannenbaum. Because Dannenbaum only certified payment of 90% of the first

two applications and because Dannenbaum never certified the third payment,

Chambers County argues that it has not breached the contract. The contract

provides, however, that [Dannenbaum] would “provide administration of the

Contract as described in the Contract Documents and will be the Owner’s

representative (1) during construction [and] (2) until final payment is due . . . .”

(Emphasis added.) It further provides that Dannenbaum, “as a representative of”

Chambers County was required to periodically visit the site “to endeavor to guard

[Chambers County] against defects and deficiencies in the Work.” (Emphasis

added.) Dannenbaum’s authority under the contract to certify less than the full

amount of the applications for payment is based on deficiencies in the work or

monetary claims from other parties. Certification of payment constituted a

representation by Dannenbaum to Chambers County “that the Work has progressed

to the point indicated and that . . . the evaluation of the Work is in accordance with

the Contract Documents.” Certification of payment, then, is part of Dannenbaum’s

12
administration of the contract, which Dannenbaum performed as Chambers

County’s representative. Accordingly, the responsibility to pay Pelco rests fully on

Chambers County and any actions taken or recommendations made by

Dannenbaum were performed as Chambers County’s representative.

In its brief on appeal, Chambers County argues Pelco cannot prevail because

it claims the breach was not material. For purposes of Pelco’s breach of contract

claim, we do not need to resolve this issue. The significance of a breach

constituting a material breach is that it excuses the non-breaching party from

continuing to perform the contract. Mustang Pipeline, 134 S.W.3d at 196. By

contrast, if a breach is determined to be immaterial, “the non-breaching party is not

excused from future performance but may sue for the damages caused by the

breach.” Levine v. Steve Scharn Custom Homes, Inc., 448 S.W.3d 637, 654 (Tex.

App.—Houston [1st Dist.] 2014, pet. filed); see also Allied Capital Partners, LP v.

Proceed Technical Res., Inc., 313 S.W.3d 460, 465 (Tex. App.—Dallas 2010, no

pet.) (holding material breach does not excuse prior, partial breach). Proof that

Chambers County’s failure to pay the full amounts of the invoices is not a material

breach, then, would not defeat Pelco’s claim for breach of contract.

Finally, for its traditional motion for summary judgment on Pelco’s breach

of contract claim, Chambers County argued that, as a matter of law, it did not

breach the portion of the contract requiring provision of reasonable evidence of

13
financial arrangements. Pelco’s complaint on appeal concerns breach of contract

based on Chambers County’s failure to fully pay Pelco’s invoices. This argument

does not implicate any requirement to provide reasonable evidence of financial

arrangements. Accordingly, this other argument does not defeat Pelco’s breach of

contract claim based on failure to pay the invoices.

We hold the trial court erred by granting summary judgment on Pelco’s

breach of contract claim. We sustain Pelco’s first issue as it relates to Pelco’s

breach of contract claim.

C. Chambers County’s Breach of Contract Claims

In a separate motion, Chambers County filed a traditional motion for

summary judgment on its own breach of contract claim. The motion identifies

Pelco’s termination of the contract as the basis for Chambers County’s breach of

contract claim. The motion asserts Chambers County was entitled to summary

judgment as to liability on this claim by purporting to defeat Pelco’s bases for prior

material breach.

Chambers County presented a number of arguments in its motion for why its

failure to pay the full amount of any of the applications for payment does not

constitute a material breach of the contract. First, Chambers County argues that

the third application for payment was submitted to Chambers County with Pelco’s

termination letter. We agree—and Pelco does not dispute—that, because the third

14
application was submitted along with Pelco’s termination letter, any failure by

Chambers County to pay any validly incurred costs included in the application

cannot constitute a prior material breach by Chambers County. See Mustang

Pipeline, 134 S.W.3d at 196 (holding prior material breach by one party excuses

further performance of other party). Our inquiry is limited, then, to Chambers

County’s withholding 10% from the first two payments.

Chambers County’s primary argument for why it has not breached the

contract based on withholding 10% from the payments to Pelco is that it was only

obligated under the contract to pay what Dannenbaum certified for payment. As

we have held, however, the contract established that Dannenbaum acted as

Chambers County’s representative when it certified the payable portion of Pelco’s

applications for payment. Accordingly, Chambers County bears the responsibility

for any error in certifying less than the entire amount of the applications.

Chambers County presents two further arguments for why withholding 10%

from the first two payments was not a breach: the contract permitted withholding a

“retainage fund” from each payment and Pelco’s work was defective, warranting

withholding certain payments. We hold that neither of these claims has been

established as a matter of law.

The only authority Chambers County cites to support its claims that the

contract authorized it to withhold 10% of each payment as a retainage fund is

15
contained in the provisions concerning “final completion and final payment.”

Under those provisions, “[n]either final payment nor any remaining retained

percentage shall become due until [Pelco] submits to” Dannenbaum certain

documentation. The same provisions require consent of the surety when “the

remaining balance for Work not fully completed or corrected is less than retainage

stipulated in the Contract Documents.” Similarly, the provision concerning the

application for payment requires the application to “reflect[] retainage if provided

for in the Contract Documents.” All of these provisions concern the effects if

retainage is permitted. They do not, themselves, permit retainage. Accordingly,

this does not establish as a matter of law that Chambers County was authorized to

withhold 10% on all requests for payment submitted by Pelco.

For its claim that the contract permitted withholding payment based on

defective work, the contract provides that, after Pelco submitted an application for

payment, Dannenbaum could “withhold a Certificate for Payment in whole or in

part, to the extent reasonably necessary to protect [Chambers County], if in

[Dannenbaum]’s opinion” certain contractually required representations could not

be made to Chambers County. In this circumstance, Dannenbaum was required to

notify Pelco and Chambers County of the problems “within seven days after

receipt of [Pelco]’s Application for Payment.” It is undisputed that Dannenbaum

never sent any notice of any problems, even beyond the seven-day limitation.

16
 Moreover, Chambers County’s proof in its motion for summary judgment

that Pelco had performed defective work comes from seven lines in Amundson’s

deposition. In that portion of his affidavit, Amundson asserted that “[t]here were

[three] construction issues early on in the project.” Amundson described, “One of

them was the piers that supported the structure, they were too high. There wasn’t

the right amount of rebar in the piers. And the actual orientation was off in the

spacing.” Even assuming this testimony is sufficient to establish as a matter of law

that Pelco’s work was deficient, it does not establish the significance of the

deficiency or that the deficiency would warrant withholding at least 10% of each

application for payment.

Finally, Chambers County argues that its withholding 10% of the

applications for payment cannot defeat its breach of contract claim because

withholding 10% was not a material breach. “The materiality of a breach—the

question of whether a party’s breach of a contract will render the contract

unenforceable—generally presents a dispute for resolution by the trier of fact.”

Henry v. Masson, 333 S.W.3d 825, 835 (Tex. App.—Houston [1st Dist.] 2010, no

pet.); see also Mustang Pipeline, 134 S.W.3d at 199 (identifying seven-factor test

weighed in considering whether breach is material). Nevertheless, materiality can

be established as a matter of law in certain circumstances. See Mustang Pipeline,

134 S.W.3d at 199–200 (holding contract “time is of the essence” provision

17
established as a matter of law that party’s failure to meet deadline was material).

Chambers County asserts it established immateriality as a matter of law.

Chambers County asserts that the withholding was immaterial because the

amount withheld was so small, characterizing it as “2.6% of the Contract price for

which 23% had already been paid.” It asserts this is a nominal amount. See id. at

199 (identifying one factor for determining materiality as extent to which injured

party will be deprived of benefit it reasonably expected). Regardless of how little

the amount withheld is compared to the entire amount that eventually would have

been paid, it nevertheless remains 10% of the amount that Pelco identified as

money it had already expended and earned. Nothing in the case law supports

Chambers County’s claim that, as a matter of law, withholding 10% owed to a

contracting party is a nominal amount.

The Utah Court of Appeals case that Chambers County relies on does not

support its claim that it proved immateriality as a matter of law. In Pack, a dispute

arose over the re-shingling of a roof. Pack v. Case, 30 P.3d 436, 439 (Utah Ct.

App. 2001). After the work was done, the owner withheld $675 of the $8,775

billed. Id. The parties went to trial, and the owner prevailed. Id. at 439–40. On

appeal, the roofer claimed that withholding $675 was a prior material breach that

excused enforcement of the warranty provision of the contract. See id. at 440. The

18
Utah Court of Appeals upheld the trial court’s determination that withholding 7.7%

of the contract price did not constitute a prior material breach. Id. at 441–42.

Nowhere in Pack does the court hold that, as a matter of law, withholding

7.7% of the contract price is immaterial. Instead, the court of appeal reviewed the

factual determinations of the trial court after a full trial and upheld that factual

determination. See id. Accordingly, Pack has no bearing on whether withholding

10% from two applications for payment is immaterial as a matter of law.

Chambers County also argues that the amounts withheld were not material

because they were never permanent. Instead, the amounts would be paid once the

corrections to the work had been performed. This argument is premised on

Chambers County’s claim that there were, in fact, problems with Pelco’s work that

warranted withholding 10% of the applications for payment. This has not been

established as a matter of law.

Lastly, Chambers County argues that Pelco’s failure to follow the procedure

under the contract for resolution of payment disputes prevents Pelco from claiming

the withholding is a material breach. Section 4.3 of the contract establishes the

procedure for certain disputes between the parties. The section defines a claim as

“a demand or assertion by one of the parties seeking . . . payment of money . . . .”

As an initial matter, it is not clear that this provision applies in this circumstance.

The section provides more specifically that “[i]f [Pelco] believes additional costs is

19
involved . . . [the] Claim shall be filed in accordance with this Section 4.3.” This

suggests that other claims for payment of money do not fall under this provision.

Otherwise, this requirement would be superfluous language. Seagull Energy E &

P, Inc. v. Eland Energy, Inc., 207 S.W.3d 342, 345 (Tex. 2006) (holding courts

construe contract so that no provision is rendered meaningless).

Similarly, other provisions in the contract require resolution of disputes

pursuant to section 4.3. For example, section 8.3 of the contract concerns “delays

and extensions of time.” That section explicitly provides, “Claims relating to time

shall be made in accordance with applicable provisions of Section 4.3.” The

portion of the contract concerning applications for payment is article 9. No section

of article 9 requires disputes to be resolved pursuant to section 4.3. See Gilbert

Tex. Const., L.P. v. Underwriters at Lloyd’s London, 327 S.W.3d 118, 126 (Tex.

2010) (“Courts strive to honor the parties’ agreement and not remake their contract

by reading additional provisions into it.”). Instead, Article 9 contains its own

dispute resolution provision for any failure by Dannenbaum to timely issue a

certificate of payment or for any failure by Chambers County to timely pay the

amount certified.2

2
Although Pelco has raised complaints about Dannenbaum’s failure to timely issue
a certificate of payment, this appeal is concerned with Dannenbaum’s
certification—and Chambers County’s payment—of less than the entire amount
requested by Pelco without any notice of problems with Pelco’s work.

20
 Even assuming section 4.3 applies to the parties’ dispute, however, this does

not establish that any failure by Pelco to follow its procedures establishes that any

breach by Chambers County is immaterial. Section 9.4.1 provides that, if it

determined that there was a reason for withholding certification in whole or in part,

Dannenbaum was required to provide Pelco with notice of its reasons. Section

9.5.1 provides that, after notice of deficiencies was provided, Pelco and

Dannenbaum would discuss the matter to determine if they could agree on a

revised amount. If the parties cannot agree on a revised amount, Dannenbaum then

issues a certificate of payment for the lesser amount.

It is undisputed that Dannenbaum did not provide any notice to Pelco of any

deficiencies in Pelco’s work. Instead, Dannenbaum issued certificates of payment

for less than the entire amount without attempting to see if the matter could be

remedied by Pelco or if Pelco would agree that a lesser payment was warranted. In

order to determine immateriality under this argument, then, we would have to hold

that Dannenbaum’s failure to provide notice and to give Pelco a chance to correct

any mistakes was not material but that Pelco’s failure to follow the claims

procedure was material. Nothing in Chambers County’s motion for summary

judgment establishes this as a matter of law.

Accordingly, this dispute resolution provision is not applicable to the dispute at
issue.

21
 We hold that Chambers County did not establish liability as a matter of law

on its breach of contract claim. We sustain Pelco’s first issue as it relates to

Chambers County’s breach of contract claim.

D. Pelco’s Claims against Amundson & Amundson Consulting

In its fourth issue, Pelco asserts that the trial court erred by granting

summary judgment in favor of Amundson and Amundson Consulting 3 on Pelco’s

claims against them. After the trial court granted summary judgment on Pelco’s

and Chambers County’s motions for summary judgment, Amundson Consulting

filed a motion for summary judgment on Pelco’s claims against it for fraudulent

inducement and negligent misrepresentation.

The elements for fraudulent inducement are

(1) the defendant made a false material misrepresentation with
knowledge that it was false when made or that the defendant asserted
without knowledge of its truth or falsity, (2) the defendant intended
the misrepresentation to be acted on, (3) the plaintiff relied on the
misrepresentation, and (4) the misrepresentation caused injury.

Anglo-Dutch Petroleum Int’l., Inc. v. Case Funding Network, LP, 441 S.W.3d 612,

627 (Tex. App.—Houston [1st Dist.] 2014, pet. denied) (citing Formosa Plastics

Corp. USA v. Presidio Eng’rs & Contractors, Inc., 960 S.W.2d 41, 47 (Tex.

1998)).

3
For purpose of their motion for summary judgment, no distinction is created
between Amundson and Amundson Consulting. Accordingly, we will refer to
both parties collectively as Amundson Consulting.

22
 The elements for negligent misrepresentation are

(1) the representation was made by a defendant in the course of his
business, or in a transaction in which he had a pecuniary interest; (2)
the defendant supplied false information for the guidance of others in
their business; (3) the defendant did not exercise reasonable care or
competence in obtaining or communicating the information; and (4)
the plaintiff suffered pecuniary loss by justifiably relying on the
representation.

Swank v. Sverdlin, 121 S.W.3d 785, 802 (Tex. App.—Houston [1st Dist.] 2003,

pet. denied) (citing Fed. Land Bank Ass’n of Tyler v. Sloane, 825 S.W.2d 439, 442

(Tex. 1991)).

In its live pleading, Pelco identified two alleged fraudulent

misrepresentations by Amundson Consulting: that the construction project was

approved for funding by FEMA and that the order to stop working on the project

came from FEMA. Pelco’s claim for negligent misrepresentation was based only

on the alleged representation that FEMA had ordered the stop on the construction

project.

In its motion for summary judgment, Amundson Consulting argued that the

justifiable reliance and proximate cause elements of both claims failed as a matter

of law because the trial court had previously determined that Pelco was at fault for

the breach of the construction contract. Assuming without deciding that Pelco’s

claims against Amundson Consulting rely on a determination that Pelco was not at

fault for the breach of the construction contract, we have reversed the trial court’s

23
rulings on this matter. Accordingly, this can no longer apply as a basis for

summary judgment in Amundson Consulting’s favor.

For the negligent misrepresentation claim, Amundson Consulting also

argued that the claim failed based on Pelco’s live pleading. See Khan v. GBAK

Props., Inc., 371 S.W.3d 347, 357 (Tex. App.—Houston [1st Dist.] 2012, no pet.)

(holding summary judgment is appropriate when plaintiff pleads facts affirmatively

negating its cause of action). In this argument, Amundson Consulting relies on

two assertions in Pelco’s live pleading. The first assertion was that Amundson

Consulting had represented to Pelco on April 26, 2010—before Pelco entered into

the contract—that FEMA had approved funding for the project. The second

assertion was that “FEMA first disputed whether the last amendment to the design

was reimburseable” only after Pelco entered into the contract with Chambers

County. Based on this, Amundson Consulting asserts that Pelco’s pleadings

establish as a matter of law that Amundson did not know that his alleged

representation was false.

The fault with Amundson Consulting’s reasoning is that the pleading also

asserts that it was the “last amendment to the design” that Amundson Consulting

and others presented to Pelco on April 26, claiming that it had been approved by

FEMA for funding. While previous designs had been approved by FEMA at that

time, the one shown to Pelco on April 26 had not. Based on Pelco’s pleading, any

24
claim by Amundson Consulting that this amendment had been approved by FEMA

could have been false or made without knowledge of its truth or falsity. See

Anglo-Dutch Petroleum, 441 S.W.3d at 627.

Amundson Consulting further asserted in its motion for summary judgment

that “the alleged misrepresentation was not false, because the Project was

eventually constructed and reimbursed by FEMA.” Amundson Consulting cannot

establish that it did not make a false statement by claiming that the statement

became true at some point in the future. See id. (holding element of fraudulent

inducement is defendant made false material misrepresentation “with knowledge

that it was false when made” (emphasis added)).

Next, Amundson Consulting asserted that any representations it made were

on behalf of Chambers County and, accordingly, were integrated into the contract

between Pelco and Chambers County, which contains a merger clause.

“[F]raudulent inducement is almost always grounds to set aside a contract despite a

merger clause, but in certain circumstances, it may be possible for a contract’s

terms to preclude a claim for fraudulent inducement by a clear and specific

disclaimer-of-reliance clause.” Italian Cowboy Partners, Ltd. v. Prudential Ins.

Co. of Am., 341 S.W.3d 323, 332 (Tex. 2011). Standard merger clause provisions

that the contract supersedes prior representations is not sufficient to act as a bar to

a fraudulent inducement claim. Id. at 334. The merger clause in the contract

25
between Pelco and Chambers County simply provides that “[t]he Contract

represents the entire and integrated agreement . . . and supersedes prior . . .

representations . . . either written or oral.” We hold this is a standard merger

agreement and cannot defeat a fraudulent misrepresentation claim. See id.

Finally, Amundson Consulting asserted that the fraudulent inducement claim

fails because Pelco had no evidence that Amundson Consulting intended to induce

Pelco’s reliance. “Intent is a fact question within the realm of the trier of fact

because it is dependent upon the credibility of witnesses and the weight to be given

to their testimony.” Nwokedi v. Unlimited Restoration Specialists, Inc., 428

S.W.3d 191, 199 (Tex. App.—Houston [1st Dist.] 2014, pet. denied) (citing

Spoljaric v. Percival Tours, Inc., 708 S.W.2d 432, 434 (Tex. 1986)). “Since intent

to defraud is not susceptible to direct proof, it invariably must be proven by

circumstantial evidence.” Spoljaric, 708 S.W.2d at 435. The fact that Amundson

Consulting made these representations in the context of a presentation seeking

Pelco’s bid on the construction contract is some circumstantial proof that

Amundson Consulting intended for Pelco to rely on its statements and to act on the

statements.

We hold Amundson Consulting failed to establish as a matter of law that

Pelco could not prevail on its fraudulent misrepresentation and negligent

26
misrepresentation claims against Amundson Consulting. We sustain Pelco’s fourth

issue.

Attorneys’ Fees

In its fifth issue, Pelco argues that, if we reverse the jury’s damage award,

we should also reverse the award of attorneys’ fees. Because we have reversed the

trial court’s determination of liability on Chambers County’s breach of contract

claim, the court’s damages award must also be reversed. 4 See TEX. R. APP. P. 44.1

(“The court may not order a separate trial solely on unliquidated damages if

liability is contested.”). Likewise, the attorneys’ fees award must also be reversed.

See TEX. CIV. PRAC. & REM. CODE ANN. § 38.001(8) (Vernon 2015) (allowing

award of attorneys’ fees for breach of contract claim); MBM Fin. Corp. v.

Woodlands Operating Co., L.P., 292 S.W.3d 660, 666 (Tex. 2009) (holding, to

recover attorneys’ fees under section 38.001, litigant must prevail on breach of

contract claim). We sustain Pelco’s fifth issue.

Response to Dissent

The dissent identifies another matter that it claims was raised by Pelco and

was adequately developed by Pelco: Pelco’s Prompt Payment Act

claims. Chambers County sought and obtained summary judgment on these claims

in the same motion that it sought and obtained summary judgment on Pelco’s

4
Because we reverse the damage award, we do not need to reach Pelco’s remaining
issues concerning error during the trial on damages. See TEX. R. APP. P. 47.1.

27
breach of contract claim. The motion, however, separately argued the grounds for

summary judgment on the breach of contract claim and on the Prompt Payment

Act claims. Likewise, Pelco responded to each claim separately and presented

different arguments for why each claim should survive.

On appeal, the entirety of Pelco’s analysis concerning this matter is a one-

sentence footnote, claiming “The trial court’s denial of Pelco’s motion for

summary judgment on its Prompt Pay claims was also error, which requires

reversal.” Rather than considering this lone passage as a side note among the

thirty-three substantive pages of the brief, the dissent would hold that the matter

has been raised and requires reversal. Even if we agreed that this sentence-long

footnote was Pelco’s attempt to challenge the trial court’s grant of summary

judgment on its Prompt Payment Act claims, we could not hold that this sentence

adequately developed the matter.

As stated, Chambers County raised grounds for granting summary judgment

on Pelco’s breach of contract claim separately from the grounds for granting

summary judgment on the Prompt Payment Act claims, and Pelco responded to the

claims separately. On appeal, Pelco does not address any of these individual

grounds for summary judgment on the Prompt Payment Act claims or any of its

individual responses. See Britton v. Texas Dep’t of Criminal Justice, 95 S.W.3d

676, 681 (Tex. App.—Houston [1st Dist.] 2002, no pet.) (holding, to obtain

28
reversal, “an appellant must attack all independent grounds supporting a

judgment”). Likewise, Pelco does not explain whether it believes Chambers

County failed to carry its initial burden on the Prompt Payment Act claims, Pelco

carried its burden after it shifted, or both.

For the citation to legal authority, Pelco’s one citation to one of the statutes

in the Prompt Payment Act is contained in its argument that the Prompt Payment

Act served as a basis to establish breach of contract. But the failure to make

payments under the Prompt Payment Act does not establish a breach of

contract. See TEX. GOV’T CODE ANN. § 2251.051(a) (Vernon 2008) (providing

remedy for failure to make payments under act is suspension of

performance). Otherwise, Pelco provides no citation to the act or any case law

applying the act.

The dissent would hold that the arguments concerning breach of contract are

sufficiently analogous, but making an analogous argument on appeal is not

sufficient to address a separate matter before the trial court. See Wohlfahrt v.

Holloway, 172 S.W.3d 630, 639–40 (Tex. App.—Houston [14th Dist.] 2005, no

pet.) (holding argument on appeal must comport with argument raised before trial

court). Accordingly, even if we agreed with the dissent that Pelco attempted to

raise the grant of summary judgment on its Prompt Payment Act claims as an issue

on appeal, we cannot agree that the one sentence devoted to the matter was

29
sufficient to develop the argument. Consequently, we express no opinion on the

merits of whether summary judgment was appropriate for the Prompt Payment Act

claims.

Conclusion

We reverse the trial court’s rendition of summary judgment on Pelco’s

breach of contract claim, Chambers County’s breach of contract claim, and Pelco’s

fraudulent misrepresentation and negligent misrepresentation claims against

Amundson and Amundson Consulting. We remand for a new trial on these claims.

Laura Carter Higley
Justice

Panel consists of Justices Jennings, Higley, and Huddle.

Justice Huddle, concurring in part and dissenting in part.

30