United States Court of Appeals
FOR THE EIGHTH CIRCUIT
________________________
Nos. 98-1484SD, 98-1577SD
________________________
Turn Key Gaming, Inc., *
*
Appellant/Cross-Appellee, *
* On Appeal from the United
v. * States District Court
* for the District of South
* Dakota.
Oglala Sioux Tribe, *
*
Appellee/Cross-Appellant. *
___________
Submitted: October 19, 1998
Filed: January 4, 1999
___________
Before BOWMAN, Chief Judge, RICHARD S. ARNOLD and MORRIS SHEPPARD
ARNOLD, Circuit Judges.
___________
RICHARD S. ARNOLD, Circuit Judge.
The plaintiff, Turn Key Gaming, Inc., appeals from several rulings made by the
District Court on two motions for partial summary judgment. In both rulings the Court
resolved various legal issues concerning the meaning and effect of a management
contract between the parties. At the close of its second Memorandum Opinion, the
District Court entered a “judgment of dismissal, together with costs” against Turn Key,
leaving only the Tribe’s counterclaims remaining. Subsequently, the District Court
certified its ruling as final under Rule 54(b).1 Although we agree with the Court’s
conclusions, we hold that Turn Key’s entire complaint should not have been dismissed,
and remand for further proceedings.
At the center of this case is a Management Agreement executed by Turn Key
and the Oglala Sioux Tribe on November 30, 1994, and approved by the Chairman of
the National Indian Gaming Commission (NIGC) on December 7, 1995. Under the
terms of this Agreement, Turn Key was to develop, finance, construct, and manage a
gaming facility on Oglala Sioux tribal lands to be known as the Prairie Wind Casino.
All costs of constructing and equipping the project were to be advanced by Turn Key,
and repaid by the Tribe out of revenues from operations according to a set formula.
According to Turn Key, the project experienced significant cost overruns because of
the protracted process of receiving NIGC approval, inflation, and the added expenses
of opening temporary facilities. Turn Key insists that these overruns were discussed
with Tribe officials, and that in order to avoid the risk of further delays, it was orally
agreed that the parties would modify the Agreement after receiving NIGC approval.
By the time the Agreement finally received NIGC approval on December 7, 1995,
Turn Key had already spent a considerable amount of money, about $2.7 million, on
the project. In June of 1996, Turn Key sent a change order to the Tribe requesting that
it approve an increase in construction costs. The Tribe refused, and Turn Key ceased
work on the project. The Tribe then declared Turn Key in default, and, after a time,
terminated the Agreement. Turn Key filed suit alleging breach of contract and unjust
enrichment. The Tribe counterclaimed for breach of contract and breach of fiduciary
duty.
The Indian Gaming Regulatory Act of 1988 provided a statutory basis for the
operation and regulation of Indian gaming, and established the National Indian Gaming
Commission (NIGC) to oversee Indian gaming. 25 U.S.C. §§ 2701-21. Among other
things, the Act permits tribes to enter into management contracts for the operation and
1
It is this ruling which forms the basis of the Tribe’s cross-appeal.
-2-
management of gaming facilities, subject to the approval of such contracts by the
Chairman of the NIGC. 25 U.S.C. § 2711. A contract cannot receive approval from
the Chairman unless it provides certain minimal protections for the tribe. Id. Some
requirements are codified in the Act itself, and others are set out in the accompanying
regulations. See id.; 25 C.F.R. §§ 531.1-533.7. A few of those requirements are
relevant here. First, the contract must provide for an “agreed ceiling for the repayment
of development and construction costs.” 25 U.S.C. § 2711(b)(4); see 25 C.F.R.
§ 531.1(g). Second, the contract must contain a “representation that the contract as
submitted . . . is the entirety of the agreement among the parties.” 25 C.F.R.
§ 533.3(a)(2). In addition, the regulations mandate that any management contract that
does not receive approval is void, and that any attempted modification of an approved
contract that does not comply with the regulations and does not receive approval, is
also void. 25 C.F.R. §§ 533.7, 535.1(f).
In keeping with these requirements, the management contract (hereinafter
“Agreement”) in this case stated that it encompassed the entire agreement between the
parties with respect to the subject matter thereof and that there were no other collateral
agreements or understandings except those contained therein. The Agreement
provided that it could not be changed orally, but only by an instrument in writing
signed by both parties and submitted by the Tribe for written approval to the NIGC.
The Agreement also provided that “the maximum agreed ceiling for development and
construction cost of all construction and equipping of the Project shall not exceed the
aggregate sum of $4,000,000.”
While awaiting final NIGC approval of the Agreement, the parties entered into
several “interim agreements” which allowed gaming operations to begin in temporary
facilities erected on the site. There was a Rental Agreement, whereby Turn Key agreed
to provide the Tribe certain gaming equipment and other personal property, as well as
an Employee Agreement between Wayne Barber, a tribe member and officer of Turn
Key, and the Tribe, in which the Tribe employed Barber to manage the temporary
-3-
gaming facility until the Agreement received NIGC approval. Both interim agreements
stated that they would end upon approval of the main Agreement by the NIGC, and
that thereafter the main Agreement would govern all rights and obligations of the
parties. Turn Key also asserts that there was an oral agreement with Tribe officials to
modify the $4,000,000 construction cost ceiling after it became obvious that this
amount would not adequately cover the full cost of construction.
On appeal, Turn Key first argues that it was error for the District Court to refuse
to consider the content and effect of these interim agreements. Turn Key claims that
the common law of South Dakota should control the issue of whether it is proper for
the Court to look to these other agreements in order to determine the intent of the
parties. Although this may be the correct approach in ordinary contract disputes, in the
context of Indian gaming the directives of Congress, when made apparent, must
control. As the Court below pointed out, the integration clause, which is required by
the Act and regulations, prevents consideration of any prior or contemporaneous
agreements; and the no-oral-modification clause and the regulation’s requirements for
modifying management contracts preclude consideration of any subsequent agreements
not approved by the Chairman of NIGC. Accordingly, these other agreements can
have no effect with respect to any of the subject matter encompassed by the
Management Agreement.
Turn Key next argues that it was error for the District Court to conclude that the
ceiling on construction costs applied only to the amount the Tribe is required to repay,
and not to the amount Turn Key is required to invest in the project. Turn Key claims
that this ruling improperly shifts the risk of cost overruns to it and is contrary to the
plain language of the Agreement and the intention of the parties.
As noted above, the Act and regulations require that before the Chairman of the
NIGC may approve a management contract, it must include an “agreed ceiling for the
repayment of development and construction costs.” 25 U.S.C. § 2711(b)(4); see 25
-4-
C.F.R. § 531.1(g). The ceiling provision in this case is mentioned several times in the
Agreement. First, section 3.3 states:
No Agreement; Reimbursement of Manager. If an Agreement is not
approved, the Tribe specifically agrees to reimburse the Manager for the
costs of construction of any building and related costs . . . to the extent as
provided by § 11.2 herein. An amount of $4,000,000 is the ceiling
agreed upon in § 4.1(a)(1) for development costs for the Project. The
parties acknowledge that $4,000,000 is the maximum amount that will be
invested in the Project and to maximize financial returns to the Tribe,
Manager will endeavor to spend less on development.
The provision is also mentioned in § 4.1(a), which provides in part:
The costs of all such construction and equipping of the Project shall be
advanced by Manager as its investment in the project, and repaid as a
Construction and Asset Acquisition Payment as contemplated in § 6.4(f).
The parties agree that the maximum agreed ceiling for development and
construction cost of all construction and equipping of the Project shall not
exceed the aggregate sum of $4,000,000.
The third reference to the construction ceiling is found in § 6.4(f), which provides for
the creation of an “Construction and Asset Acquisition Account” to include all of the
expenditures by Turn Key in constructing, furnishing, and equipping the project. This
section goes on to direct that the balance of this account “as specified and limited in
§ 4, . . . shall be repaid to Manager . . . from the Manager’s fee and the Tribe’s share
as provided at § 6.5(b), and in the proportions set forth therein.”
Turn Key insists that the clear import of these clauses indicates that the ceiling
was meant to apply both to the amount the Tribe would be required to repay and the
amount Turn Key would be required to invest. We do not agree. Such a construction
-5-
is contrary both to the reason the Act requires a ceiling provision -- for the protection
of the Tribe -- and the obvious reason for placing a “limit” on Turn Key’s
“investment.” In our view, to the extent that the above clauses can be read as limiting
Turn Key’s investment, it is still a limit that is imposed for the protection of the Tribe.
As each clause indicates, the more Turn Key “invested” in the project, the more the
Tribe would have to pay back. This is why § 3.3 of the Agreement states that in order
to “maximize financial returns to the Tribe,” Turn Key “would endeavor to spend less”
on the project. Turn Key has not pointed to any other portions of the Agreement,
besides those discussed above, which would support its position, and we refuse to
convolute the Agreement to provide a protection to Turn Key that was not bargained
for.
Turn Key also appeals the dismissal of its complaint at the conclusion of the
District Court’s Memorandum Opinion granting the Tribe’s second motion for partial
summary judgment. Turn Key argues that its claims under Section 11.2(a) of the
Agreement, as well as its claims for unjust enrichment, should have survived. Section
11.2(a) of the Agreement provides, “if termination of this Agreement occurs for any
reason prior to the end of the Term, all costs which were incurred by [Turn Key] in the
performance of this Agreement and which have not been repaid as provided in [the
formula] shall be repaid to [Turn Key].” Turn Key’s Sixth Claim for Relief avers that
the Tribe owes it approximately $2.3 million for costs incurred prior to termination.
In the alternative, Turn Key has also claimed unjust enrichment under its Fourteenth
Claim for Relief, based on the enhanced value of the Tribe’s property due to the
expenditures made by Turn Key on the project. These claims were not addressed in
the District Court’s Memorandum Opinion, and none of the legal conclusions reached
in that opinion would necessarily prevent these claims from going forward. We
therefore reverse the dismissal of Turn Key’s claims under Section 11.2(a) of the
Agreement and for unjust enrichment.
Finally, we hold that the District Court did not abuse its discretion in certifying
-6-
its judgment as final under Rule 54(b), and we therefore affirm on the Tribe’s cross-
appeal on this issue.
On remand, the case should go forward on Turn Key’s remaining claims, as well
as on the Tribe’s counterclaim.
It is so ordered.
A true copy.
Attest:
CLERK, U.S. COURT OF APPEALS, EIGHTH CIRCUIT.
-7-