The plaintiff brings this action against the principals and surety upon a bond given for the faithful performance by the principals, Robbins Potter, of a contract entered into by them for the construction of a dam and reservoir. Due performance of the terms of the contract on the part of the plaintiff, and its breach by the contractors, are alleged. The breach is alleged to have resulted from a notice from the contractors of their refusal to continue the work then in progress, an abandonment of it, and such unwarranted and unnecessary delay in the prosecution of the work as resulted in an order of discontinuance from the engineer in charge, agreeable to the provisions of the contract.
The defendants Robbins Potter, in connection with certain special denials, set up, by way of special defense *Page 632 and counterclaim, that the plaintiff was guilty of a fraud upon them, in that they were induced, by certain fraudulent representations made and contained in notices issued for the guidance and information of prospective bidders, and in other antecedent statements and negotiations, all relating to the character and amounts of the various kinds of work to be required to be done within the proposed contract, and within the contract as presented for signature, to sign the same; and in that, notwithstanding said representations, and in fraudulent disregard thereof, advantage was taken of the terms of said contract to require of the defendants a quantity of work of certain kinds grossly in excess of the amounts represented, so that the proportionate amounts of the different kinds of work were radically changed, and so that, by reason of this change and the increased difficulty and cost per unit which resulted, the burden thus wrongfully attempted to be imposed upon them was greatly augmented over what it would have been had the work been as represented; and also that they were, while engaged upon the work, unlawfully compelled to discontinue the further prosecution of it by the wrongful and bad-faith action of the plaintiff's agent, superintendent and engineer in charge, in taking advantage of a provision in the contract to compel such discontinuance, when no just reason therefor existed, as he well knew.
It will be observed from this analysis that while both the defense and counterclaim are in form single each is essentially double. Each contains allegations which, entirely apart from others with which they are associated in the same pleading, constitute two entirely independent and complete defenses, or counterclaims, as the case may be. Those which bear upon the fraud which, it is claimed, gathers about the creation of the contract and its enforcement, form an independent group of facts, whose essence is deceit, upon which the defendants rely as a complete ground of defense and counterclaim, quite irrespective of *Page 633 other allegations dealing with another disassociated matter. And the same is true of those averments which relate to the alleged unlawful termination of the contractors' connection with the enterprise. As it will be necessary to distinguish these two defenses and counterclaims in our discussion, we shall, for brevity's sake, refer to them as the first and second, respectively, adopting the order in which they have been outlined.
The defendant surety company filed an answer containing defenses identical in all respects with those of Robbins Potter, but no counterclaim. As all the defenses and counterclaims of each group, determined by their subject-matter, rest upon precisely the same facts and involve precisely the same legal principles and considerations, we shall, for convenience sake, confine our discussion for the most part to the questions presented as bearing upon the counterclaims.
The reasons of appeal are numerous. They involve the action of the court in overruling the demurrer to the answer and counterclaim, its refusal to charge as requested, various portions of the charges as made, and the denial of a motion for a new trial for a verdict against evidence.
The plaintiff demurred to both the special defense and counterclaim, and numerous grounds of demurrer were assigned. Some of them ran to each pleading in its entirety, while others were addressed to paragraphs only. All those of the former class were properly overruled, if for no other reason than that none of them reached more than one of the two defenses or grounds of action embodied in the pleading, thus leaving a second defense or cause of action to support the pleading taken as a whole. These reasons, however, are all, save one possessing no importance, repeated as to certain paragraphs as a group, which paragraphs relate to the first defense and counterclaim. It was the apparent intention of the pleader to thus segregate the averments pertinent to the first special defense and counterclaim, and *Page 634 to call in question their sufficiency as stating a valid defense or counterclaim. The segregation of averments as related to this purpose is by no means an accurate or complete one. There are allegations, not comprehended in the matter thus indicated as the subject of demurrer, which have a distinct bearing upon the question of the sufficiency of the entire pleading as having included within it a good defense and counterclaim of the character described. If we give effect to this branch of the demurrer just as it is framed, it must therefore fail for technical reasons. If, on the contrary, we give the plaintiff the benefit of that which was apparently intended, as we perhaps fairly may, we have presented the question whether sound reasons are advanced for holding that there are not sufficient allegations to support a good counterclaim and incidentally, therefore, a good defense.
It is urged in support of the demurrer that the alleged fraudulent representations antecedent to the execution of the contract are not averred to have related to material matters, that they concerned matters of opinion and judgment only, and purported to be mere estimates and approximations. The materiality of the matters concerning which the alleged representations were made is apparent. It is equally clear that they concerned matters susceptible of some measure of information on the part of those who made them, and that in form and substance they embodied an assertion of the possession of such information superior to that enjoyed by those to whom they were made. Upon the allegations, they were made as embodying the results of competent, expert engineering investigation, and stated to be approximately correct. Such representations are to be regarded as representations of fact, rather than of opinion.Hedin v. Minneapolis M. S. Institute, 35 L.R.A. (Minn.) 417, note 430, 439; Cowley v. Smyth, 46 N.J.L. 380, 388. They were, in substance, assertions importing knowledge, and conveying information of fact. 20 Cyc. 17. It does *Page 635 appear that the figures which expressed the alleged misrepresentation were furnished as estimates and approximations. But it is at the same time alleged that they were represented to be the result of expert engineering examination, and at least approximately accurate, whereas they did not, in fact, even remotely approach approximate correctness in the most liberal meaning of that term, were known to be false, inaccurate, and misleading, and were given to the defendant contractors with the intent that they should make use of them, as being approximately correct, in formulating their proposal, and in entering into a contract.
It is also contended that, as it is alleged that the instrument signed was not the contract between the parties, it is immaterial that Robbins Potter were induced by deceit to execute it. We are unable to discover in the defendants' allegations any foundation for this claim. Furthermore, the conclusion stated would not follow, even if the statement of fact was correct. An attempt to avoid the obligation of the contract sued upon in one way does not preclude an attempt to accomplish that result in another.
There remain other grounds of demurrer, to the general effect that the defendants' case, in so far as it relies upon the alleged fraud now in question, must fail for the reason that it is not alleged that Robbins Potter, upon discovering the deceit practiced upon them, rescinded the contract and abandoned the work, and that, on the contrary, it appears that they never ceased work under the contract until required to do so by the action of the engineer in charge. The question thus presented reappeared upon the trial, and it will be more convenient to discuss it in that connection. Suffice it now to say that the contention is not well made.
The demurrer also points out certain separate paragraphs of the special defense and counterclaim as containing either irrelevant or evidential matter only. If the objection was well taken, the plaintiff's proper remedy was by motion. *Page 636 But the allegations of these paragraphs have a proper place in the defendants' story.
It is also charged that the fact that all prior agreements, proposals, negotiations and bids, became merged in the contract executed, furnishes a ground of demurrer. Such a merger would not prevent these, or any other matters antecedent to the execution of the contract, from becoming the foundation of a claim of fraud growing out of them.
Complaint is made in the appeal that each of fourteen requests to charge the jury, elaborately drawn and for the most part extended, were not complied with. It was not the duty of the court to incorporate these requests into its instructions, however correct the propositions of law or discriminating the observations of fact embodied therein. It pursued the proper course of framing its instructions in its own language, uncolored by partisanship. McGarry v.Healey, 78 Conn. 365, 367, 62 A. 671. Its duty was to give the jury such instructions as were correct in law, adapted to the issues, and sufficient for its guidance in the determination of these issues upon the evidence, and upon the ultimate facts as they might reasonably be found to be established by the evidence. Hartford v. Champion,58 Conn. 268, 276, 20 A. 471; McGarry v. Healey, 78 Conn. 365,367, 62 A. 671. If this was done, the court's duty was sufficiently performed, although it might be possible to suggest, and although counsel may have suggested, other observations which might with propriety have been addressed to the jury as entirely appropriate to the issues. We have, then, only to examine the requests to discover if there is contained in them any proposition of law which it was necessary to give to the jury, in order that the requirements of a sufficient charge might be met, concerning which proper and adequate instructions were not given.
The first of these requests was to the effect that Robbins Potter would be precluded from claiming that the contract was terminated by reason of the bad-faith action of *Page 637 the engineer if, within a reasonable time after they discovered that he was so prejudiced against them that he could not reasonably be depended upon to fairly decide any question which, under the contract, might be reserved for his opinion or judgment as an arbiter, they failed to inform the plaintiff of that fact, and the plaintiff was in ignorance of the fact. There is nothing in the statement of what the defendants claimed to have proved which called for such instructions. What they sought to establish was that the final act was one done in bad faith, and that is the only charge in the pleadings. There is nothing in either the pleadings or statement of facts claimed to have been proven which suggests that the contractors entertained a belief or suspicion that they could not trust the engineer to deal fairly with them as an arbiter, however exacting he, as the plaintiff's representative, may have been, or they have thought him to have been, in his demands as to what the contract called for, or however dilatory and annoying he may have been, or seemed to them to have been, in the performance of his duties as engineer, in supplying them with maps, drawings, and data, as it is claimed that he was.
Another request sought from the court instructions, in substance, that if the board obtained the services of a reputable engineer to prepare the notice to contractors, proposals, plans, specifications, and form of contract, and in good faith used them, when so prepared, in the manner in which they are ordinarily used in the execution of similar work, and no member of the board had any knowledge superior to that which the contractors would have obtained by a careful examination of the premises, and of the notices, proposals, plans, specifications, and form of contract, and no member of the board made any statement to the contractors implying such superior knowledge, then the action of the board in the matter of the contract would be regarded as in perfect good faith and free from fraud or misrepresentation. *Page 638 This request overlooks the important fact that Richards was a public official. By the provisions of the city's charter he became, by virtue of his appointment as the engineer and superintendent of the board, an integral part of its organization as a public agency. His acts in this official relation were therefore in a peculiar sense those of the plaintiff as a corporate entity, and his knowledge, statements, and representations, in the performance of his official duties, its knowledge, statements, and representations, so that it may not disassociate itself from him, and claim immunity from the consequences of what he did within the line of his duty. Beyond this, he was the man to whom, as the plaintiff itself asserted, the control, management, and direction of the enterprise in question, and the arrangement of all its details, were in fact entrusted. As an agent only, he, in all that he did, acted within the scope of his agency, and the plaintiff is bound by his action, including statements and representations.
The same failure to appreciate the consequences of Richards' relation to the plaintiff as a part of its official organization, enters into another ignored request, by force of which the plaintiff sought protection from the consequences of any bad faith on the part of the engineer in terminating the contract, if it should be found that the board itself acted in good faith in accepting his opinion, decision, and certificate of termination. It, apparently, also appears again in a request to the effect that there could be no recovery upon the ground of fraud in the inception of the contract if it should be found that the board itself acted in good faith in the negotiations and transactions which were preliminary to the execution of the contract.
The court was requested to tell the jury that if the contract as executed represented the real contract between the parties, as the court instructed that it did, it was immaterial whether or not the contractors were wrongfully prevented from carrying it out. The court might well have *Page 639 failed to discover any reasonable basis for this request, and been excused from paying attention to it, since the idea which it was sought to convey thereby, as the brief informs us, was that it was immaterial whether or not there had been a breach of the contract as executed, since no breach of that contract by the prevention of its completion was alleged. We are unable to thus interpret the pleadings. Their allegations are that the discontinuance of all work on the reservoir was compelled by the wrongful act of the engineer.
The court was asked to charge that the law presumes that a person bidding upon work of the character of that covered by this contract is familiar with the kind and character of work upon which he bids, and that one contracting with him would be justified in acting upon that belief. While this might be true in a literal and limited sense, it is not true in the broader sense apparently intended for the jury's guidance. Familiarity with the kind and character of work incident to the construction of a dam and reservoir is a very different thing from such knowledge of the amount of work, or of the different kinds of work, which either the demands of the projectors as related to results satisfactory to them, or the conditions of the locality unrevealed to superficial view, might necessitate, as one might need to have in making estimates, proposals, or contracts therefor. It is idle to say that a contractor, however experienced in that business, must be presumed to know what he will be required to do in such case, beyond certain limits, without being informed, or that he is not entitled in preparing his estimates and proposals, and in entering into a contract, to rely upon information authoritatively given him to act upon, and that he accepts all such information at his peril. We have occasion to discuss this general subject more fully later on in connection with a closely related proposition. If it was the purpose of the request to convey no other information than its language, literally interpreted, *Page 640 expresses, it was without material pertinence to the case. If, on the other hand, its purpose was to convey to the jury the other impression outlined, which it was calculated to convey, it was not a proper instruction to be addressed to them.
Complaint is made because the court did not tell the jury, as requested, that fraud was never to be presumed, but must be clearly proved by the party alleging it, and that the plaintiff, being an official body charged with the performance of governmental duties, would be presumed to have acted honestly and fairly in the performance of these duties. The court gave sufficient instructions as to these points when it said that the burden was upon the defendants to prove their charges of fraud, that the existence of fraud was not to be found unless established by direct evidence, or as an inference from facts and circumstances themselves directly established, which was clear, strong, natural, and logical, and the result of an open and visible connection between it and the facts from which it was drawn; and, while speaking of the conduct of the engineer, that fraud or bad faith was not to be presumed, but must be proved.
Presumptions like that appealed to have no probative force. They perform an office in the absence of evidence, so that one who has cast upon him the burden of proof as to a given proposition may be enabled to sustain that burden upon the strength of a presumption without the presentation of proof. When such a presumption is advanced in favor of one upon whom the burden of proof does not rest, it really adds nothing to the duty or burden of the other party, since the latter is already under the obligation to present proof in support of his contention, and the presumption only reiterates that obligation. Vincent v. MutualReserve Fund Life Asso., 77 Conn. 281, 288,58 A. 963; 4 Wigm. on Ev. § 2491.
The remaining requests, save one considered later, do not *Page 641 demand attention. Some of them were in substance complied with; a consideration of others is involved in our discussion of the demurrer; and one or two are concerned with observations asked to be addressed to the jury concerning the proof presented, or concerning their obvious duty, as, for instance, that their conclusions should not be influenced by feelings of sympathy for either of the parties.
Nine passages in the charge are recited in the assignments of error as each containing error. The claimed errors are not otherwise pointed out. The recital of these passages occupies nine and one half pages of the printed record; each of five of them is a page or more in length; and each of two of them more than two pages. While each of the passages deals with related matters, most of them embody a considerable number of quite independent propositions. The record, therefore, leaves it altogether uncertain what the particular errors claimed to have been committed are. Such assignments do not satisfy the requirement of the statute (General Statutes, § 798), and we would be justified in disregarding this branch of the appeal for this reason. Griswold v. Guilford, 75 Conn. 192,193, 52 A. 742. It is in our power to waive this irregularity, however, and we will do so to the extent of considering the specific claims of error made in the brief of counsel, in so far as substantial questions, not sufficiently discussed already, are presented by them.
Most of these errors concern the charge as related to the first ground of counterclaim and defense already outlined. It is to be observed that the court defined this ground as fraud, on the part of the plaintiff or its agents, whereby the contractors were induced to enter into their contract. A closer analysis reveals that the real character of the fraud of which the contractors complain is thus too narrowly stated. That fraud is one which resulted, not only from the action of the plaintiff and its agents in inducing the contractors to execute the contract which they did execute *Page 642 by means of certain false and fraudulent representations, purporting to be based upon information, as to what its general and elastic language as related to the uncertain conditions involved in its subject-matter would require of them in the performance of the work undertaken, but also from the disregard of these representations, so falsely and fraudulently made, in subsequent action and requirements, under cover of the terms of the contract thus obtained. It is the advantage taken of the indefinite terms of the contract to exact what the contractors had been led to believe by authoritative statements and representations would not be exacted, that furnishes the real cause of complaint and fills out the measure of the alleged fraud. The plaintiff takes no exception to the court's too narrow statement, and naturally, since its cause was helped rather than harmed by it, and color was thereby given to certain of its claims which appear upon this appeal. It is, however, important to an intelligent consideration of some of the questions presented that a correct appreciation of the scope and character of the fraud which the defendants rely upon be borne in mind.
The plaintiff, in its requests, recurring to a claim presented in its demurrer, asked for instructions to the effect that the law requires the disaffirmance and repudiation of a contract, claimed to have been fraudulently induced, promptly upon discovery of the fraud, and that failure to make such disaffirmance and repudiation would result in a waiver of the fraud and a ratification of the contract. The court did not so charge, but told the jury that one who was led into a contract by fraud was privileged to repudiate the contract if, and only if, he proceeded to do so promptly upon his discovery of it, or within a reasonable time thereafter; but that he might pursue another course, to wit, continue in the execution of the contract, and seek his redress in an action to recover damages for the fraud. This statement of the law, as applicable to contracts partly executed *Page 643 at the time of the discovery of the fraud, is a familiar one, and has had the approval of this court. 2 Cooley on Torts (3d Ed.) 962; Yale Gas Stove Co. v. Wilcox, 64 Conn. 101,127, 29 A. 303; Wilson v. Nichols, 72 Conn. 173, 180,43 A. 1052. Whether it is a correct statement as applicable to situations where the contract remains wholly executory at the time the fraud is discovered, we have no occasion to inquire, since the instructions were appropriate to the situation before the court. See Kingman Co. v. Stoddard, 29 C.C.A. 413, 418. In connection with the general principle stated the court went on to say, in substance, that one might, after the discovery of the fraud, so conduct himself in affirmance of the contract that he would be held to have waived the fraud and lost his right to take advantage of it. But it was added that the court did not understand that such a situation was seriously claimed to exist in the case. The court was correct in its statement of principle, and justified, upon the facts before the jury, in dismissing that possible aspect of the case from their consideration. 2 Cooley on Torts (3d Ed.) 963; Pryor v. Foster, 130 N.Y. 171,175, 29 N.E. 123; St. John v. Hendrickson, 81 Ind. 350,352. It was its duty to submit no issue foreign to the facts in evidence, or upon which no evidence had been offered which formed a reasonable basis for more than one conclusion.State v. Kelly, 77 Conn. 266, 274, 58 A. 705.
That part of the charge wherein the jury were told what would operate as a fraud by representations, contained the following sentence: "If one, not knowing it is false, takes upon himself to make representations of fact to the other, on the faith of which the other acts, and the representations prove untrue, this would operate and be treated as a fraud, although his mistake is perfectly innocent." As a statement of a principle of general application this was not sufficiently guarded and precise. That, however, is not of consequence, if, as applied to the situation before the jury, it expressed the pertinent principle in such a way as to *Page 644 furnish them a proper guide for their present purpose, and could not have misled them. All the representations before the jury, as the basis of the claimed fraud, were those claimed to have been made in relation to the approximate amount of work comprehended in the proposed project as contained in the printed notices and statements issued by the board and its engineer, and in other verbal statements corroborative of them. They were, therefore, as we have seen, representations so made that they carried with them the assertion of being made upon some basis of superior knowledge and information. Their purpose was to supply information to persons who were expected to act upon it in a business dealing with those who made them, and who were entitled to accept and act upon it as expressing what it purported to express, to wit, information having a basis in such superior knowledge. As applicable to such representations, it is true that if one takes it upon himself to make them for the purpose of influencing another's action, and they do influence his action, and the pretense of knowledge proves to be unfounded and the representations false, the result accomplished by such means will be regarded as tainted with fraud. "In matters susceptible of actual knowledge, if the party who has and is known to have the best means of knowledge, makes an affirmation contrary to the truth, in order to secure some benefit to himself, the law will treat him as stating that he knows that whereof he affirms, and so is guilty of a fraud, although he spoke in ignorance of the facts; because he asserts that he knows what he does not know." Scholfield Gear Pulley Co. v. Scholfield, 71 Conn. 1, 19, 40 A. 1046. See also Chase's Appeal, 57 Conn. 236, 263 et seq., 18 A. 96. "This rule is based upon the principle that the speaker is conscious either that he knows or does not know the truth of what he states, and that when, conscious of his ignorance, he assumes to have knowledge, he acts in bad faith and must be held to warrant the truth of his assertion, *Page 645 and so is liable in an action of deceit." 20 Cyc. 27, note 92. The instruction criticised, even if we assume that its context did not more fully explain it, could not, therefore, have misled the jury to the plaintiff's harm.
Another passage dealing with the first counterclaim and defense, and concerned with the application of the doctrine of fraud, is criticised for the reason that the jury were not told that the representations must have related to a material fact; that they must have been such as were calculated to deceive a man of ordinary intelligence, and must have been believed. We have already seen that they related to matters inherently material, and that they were of such character and so made as to naturally lead to deception, if they were not what they pretended to be. The whole burden of the charge upon this point was that the representations, to be regarded as fraudulent, must have induced the execution of the contract through a reliance upon them.
In commenting upon the defendants' claim of deception arising from the representations, the court called the attention of the jury to the claim of the plaintiff that Robbins Potter could not have been misled in view of the fact that one member of the firm visited the premises. Complaint is made that the intimation of the court was that the fact of deception was one to be determined in the light of the information then obtained, whereas, as it is said, they should have been told that it was to be determined in the light of what they might have discovered by a careful examination of the site. This proposition is to the effect that if Robbins Potter, without personal investigation, acted upon the faith of the statements and representations made to them by the plaintiff, or its authorized representative, as to the kinds and the quantities of the various kinds of work comprehended in the scheme of construction as proposed, they did so at their peril, and that the plaintiff would be held to no responsibility for such statements and representations, although they were made for the express *Page 646 purpose of their being acted upon by Robbins Potter in a business dealing with it, and although they were false and misleading, if the latter fact would have been revealed by an investigation by competent men. The law sanctions no such proposition, as applicable to a situation like that before the jury. It is apparent that the facts involved in the statements and representations in question were such as not to be equally available to both parties, were not at hand or within the observation of Robbins Potter, and involved investigation of conditions, study and computations for which expert technical knowledge was required, if not also a search of the minds and purposes of the members of the board. They were made by a party in a position to have, and who assumed to have, not only a superior knowledge, but also a knowledge which had a foundation in expert examination and study, and they were made for the purpose of being acted upon, and promptly acted upon.Sherwood v. Salmon, 5 Day 439; Endsley v. Johns, 120 Ill. 469,481, 12 N.E. 247; Savage v. Stevens, 126 Mass. 207;Redding v. Wright, 49 Minn. 322, 330, 51 N.W. 1056.
Two portions of the charge, relating to the issue as to the unlawful termination of the contract by the plaintiff's engineer, are complained of, for the reason that the matter of the contractors' claimed abandonment of the work was ignored. There was no occasion for special reference to that subject in the passages referred to. The significance of a voluntary abandonment by the contractors before action taken by the engineer was not, however, by any means ignored. The entire charge proceeded upon the theory that proof of such an abandonment would establish a complete defense to the claim of unlawful termination, and in more than one place this fact was clearly brought out. It is inconceivable that the jury, after their instructions, or, for that matter, without them, could have been possessed of the notion that the contractors could be regarded as having been unlawfully prevented from continuing *Page 647 in the execution of the contract, if they had already voluntarily abandoned the work.
If the defendants established either one of their two defenses and the corresponding counterclaim, the verdict in their behalf was properly rendered. The court, therefore, could not grant the motion for a new trial, unless it was of the opinion that the jury could not have reasonably come to the conclusion, upon the evidence, that one of them was supported by proof. We cannot say that the court erred in not arriving at that opinion.
There is no error.
In this opinion the other judges concurred.