This action was brought by the George A. Fuller Company, a foreign corporation, upon a bond executed by the Southern Construction Company of Baltimore, Maryland, as principal, and by the Aetna Indemnity Company of Hartford, Connecticut, as surety, in the penalty of fifty thousand dollars. These parties will be hereinafter designated briefly as the Fuller Company, the Southern Company and the Aetna Company. The Fuller Company had entered into a contract for the erection complete of a certain building in Baltimore City, known as the Friedenwald Building, and had sublet all the reinforced concrete and cement work thereof to the Southern Company, under a written agreement between them, dated May 26th, 1906. Under this agreement the Southern Company was required to furnished "a surety bond" in the amount of $50,000 for the faithful performance of the contract. The contract price to be paid the Southern Company for work and materials thereunder was $66,067, and $6.50 per cubic yard for all additional concrete work, and such sum was "to be paid by the contractor (the Fuller Company) *Page 334 to the sub-contractor (the Southern Company) in instalments as the work progresses."
The fifth and thirteenth clauses of this agreement are the important clauses in this case, and the essential parts thereof are therefore transcribed as follows: "Fifth. Should the sub-contractor at any time refuse or neglect to supply a sufficient number of properly skilled workmen, or sufficient materials of the proper quality, or fail in any respect to prosecute the work with promptness and diligence, or fail in the performance of any of the agreements herein contained, the contractor shall be at liberty, after three days' written notice to the sub-contractor, to provide any such labor or materials, and to deduct the cost thereof from any money then due, or thereafter to become due, to the sub-contractor under this contract; and the contractor shall also be at liberty to terminate the employment of the sub-contractor for the said work, and to enter upon the premises and take possession, for the purpose of completing the work comprehended under this contract, of all materials, tools and appliances thereon, and to employ any other person or persons to finish the work and to provide the materials therefor, and in case of such discontinuance of the employment, the sub-contractor shall not be entitled to receive any further payment under this contract until the said work shall be wholly finished, at which time, if the unpaid balance to be paid under this contract, shall exceed the expense incurred by the contractor in finishing the work, such excess shall be paid to the sub-contractor, but if such expense shall exceed such unpaid balance, the sub-contractor shall pay the difference to the contractor. The expense incurred by the contractor as herein provided, either for furnishing the materials or for finishing the work, and any damage incurred through such default, shall be audited and certified by the architect, whose certificate thereof shall be conclusive upon the parties."
Thirteenth. "Any material purchased by the contractor for the sub-contractor, or any money advanced by the contractor to the sub-contractor for pay rolls, etc., shall be charged *Page 335 to the account of the sub-contractor, and shall be considered as part payment on this contract. Payments to the sub-contractor may be thus made to within five per cent. of the total amount of this contract, the remaining five per cent. to be held back until time for the final payment arrives." The contract required the entire work, except the tooling of the exterior walls, to be completed Sept. 1st, 1906.
In compliance with this agreement the Southern Company furnished the bond sued on and hereinbefore mentioned, which was signed and sealed by the Southern Company, and by the Aetna Company May 26th, 1906.
The condition of that bond is as follows:
"The condition of the foregoing obligation is such that if the said principal shall conform to and comply with all the terms and covenants of a certain contract between said principal and said contractor, dated May 26th, 1906, relating to concrete work on Friedenwald Building as per contract, on the part of said principal to be performed and complied with, according to the tenor of said contract, then this obligation to be null and void, otherwise to be and remain in full force and effect."
It was further provided in said bond as follows: "This bond is executed by the surety and received by the contractor upon the following express conditions:" Here follow eight separate conditions of which it is only necessary to set out parts of the third and seventh.
"Third. If the said principal abandon said contract, or fail to comply with any or all of the conditions of said contract to such an extent that the same shall be forfeited, then said surety, upon the notice above stated (prompt notice after default by personal delivery or registered mail) shall have the right and privilege to sublet or complete said contract, whichever said surety may elect to do, provided it be done in accordance with said contract." * * *
"Seventh. If, after default and notice of such default to the surety the principal shall continue to proceed with the performance of the contract, the contractor may pay the principal *Page 336 for work done and material supplied without affecting the liability of the surety hereunder, unless the surety shall serve a notice upon the contractor directing it to withhold such payments, in which event the contractor may only pay for the work and labor performed subsequent to the default, less the reserve provided for in the contract, and must withhold the balance of the payments to secure the performance of the contract."
There seems to be no question upon the evidence, that the bond was executed on the day it bears date, May 26th, 1906. Witherspoon, plaintiff's manager, was not able to say whether either the bond or contract was executed May 26th or June 5th, but Hunter, the Baltimore agent of the Aetna Company, said he had seen no written contract when the bond was executed, and Purnell, secretary of the Southern Company, who signed the bond, swore positively that the contract was not executed and was not in existence, on May 26th, and that he knew it was executed on June 5th. Witherspoon testified positively that he showed Hunter either the contract or an exact copy before delivery of the bond, though he could not fix the exact date of delivery, and Hunter admitted that he was "furnished a precise copy of the written agreement offerred in evidence, on June 5th, 1906, and that on July 26th, 1906, his company accepted payment of the premium on this bond from the Fuller Company, through the office of the Southern Company." Work under the contract was begun as nearly as appears from the evidence, about June 7th, 1906, before the delivery of the bond according to Witherspoon's recollection of the fact.
The Southern Company stopped work August 23, 1906, and never resumed it. On August 23, 1906, the Fuller Company wrote the Aetna Company that a bill for a receiver had been filed against the Southern Company alleging its insolvency, and that while work had not then actually stopped, they were advised the Southern would probably consent to the appointment of a receiver, and they asked the advice of the Aetna Company for the protection of their mutual interests. *Page 337 On August 24th they again wrote, stating that the Southern had actually stopped work, and that while a receiver had not then been appointed, they were advised the Southern would consent, and they should therefore look to the Aetna's bond. They also enclosed carbon copy of their letter of same date to the Southern that unless work was resumed at once its employment would be terminated, and the Fuller Company would look to the bond. On August 29th, the plaintiff again wrote the Aetna Company, stating that a receiver had been appointed on the 28th, the Southern consenting thereto, and admitting its insolvency. They also stated they had terminated the employment and had entered upon the premises and taken possession "for the purpose of completingor having completed the work comprehended under the contract," and they enclosed carbon copy of letter of same date to the Southern Company, and also to Mr. Geo. R. Willis, its receiver, conveying the same notice as that given the Aetna Company. The receipt of all these letters was admitted. On September 1st, they again wrote the Aetna Company calling their attention to their previous letters and saying, "not having heard from you, we assume that you do not deem it to your advantage to go ahead andsublet or complete said contract, and accordingly this company will on next Tuesday, September 4th, 1906, in order to keep thedamages down to as low a figure as possible, make a start for the completion of the work comprehended under the contract, holding your bond responsible for any loss we sustain in the premises."
On September 4th, the Aetna Company briefly acknowledged the letter of August 29th, stating that they had been waiting for a communication from their indemnitors, and on the same day also acknowledged their letter of September 1st, stating their surprise that the plaintiff should have chosen to go ahead with the contract on the fourth, when they knew their letter of first inst. could not possibly reach the Aetna Company in New York before the fourth inst, and saying: "You seem to overlook the fact we have indemnitors from any *Page 338 loss on account of the insurance of the above bond, and that it is quite necessary for us to obtain their acquiescence in whatever action this company might take as surety." It may be observed here that no testimony was offered to show the time required for transmission and delivery of a letter from Baltimore to New York, but in the absence of some evidence of actual delay, it is common knowledge that a letter written during business hours in Baltimore on any day except Saturday, would be delivered in New York in the early morning delivery of the next day, and if written on Saturday afternoon, would be delivered on Monday morning. It is quite impossible to conceive that a letter mailed in Baltimore on Saturday, September 1st, could not be delivered in New York until Tuesday the fourth. It is also to be observed that the Aetna Company in this letter characterizes the bond very properly as a contract of insurance.
It appears from the testimony of both sides that when the work was stopped on August 23rd, from 50 per cent. to 60 per cent. of the work on this contract had been done, while the plaintiff had paid the Southern Company before its actual failure on the 28th of August, about $60,000 on their $68,000 contract.
The declaration contains three counts of a simple character. The first count sets out the condition of the bond, and charges as a breach, the abandonment of the contract long before its completion, alleging that the plaintiff was damaged by being compelled to complete the unfinished work, and to pay out large sums of money in doing so.
The second count sets out the condition of the bond, and the insolvency of the Southern Company, and charges as a breach the stopping of the work long before its completion; it alleges the giving of due notice and termination of the contract, the completion of the work by the plaintiff, the provision for auditing the cost of completion by the architect and damage sustained by the default, the certificate of such audit and the plaintiff's demand for the amount thereof, and the defendant's refusal to pay the same. The third *Page 339 count set out the condition of the bond and the entire fifth clause of the contract; alleged as a breach that before completing the contract the Southern became insolvent, consented to the appointment of a receiver and stopped work, and further alleged in like manner the termination of the employment, the completion of the work by the plaintiff, the certificate and award of the architects, the demand of the plaintiff for the amount of the award, and the defendant's refusal to pay the same.
The subsequent pleadings are voluminous. The Aetna Company first filed fourteen pleas to the whole declaration, the 13th and 14th being the same as the 8th and 9th, but filed on equitable grounds. The substance of these pleas may be condensed as follows: 1st. That the plaintiff is not a corporation. 2nd. Plaintiff not a corporation legally entitled to sue. 3rd. Nonest factum as to the bond sued on. 4th. That the paper filed with the declaration purporting to be a certificate of the architects, was not a certificate. 5th. That said alleged certificate was obtained by the plaintiff by fraud. 6th. That the contract was, before the time for its fulfillment, without defendant's consent, so materially altered as to release defendant from all liability on the bond. 7th. That all liability, if any, of defendant on the bond had been released. 8th. That plaintiff, before May 26th, agreed with the Southern Company to supply it with all necessary money to complete said contract, and to finance all its requirements thereunder; that plaintiff failed and refused to comply with this agreement, with the fraudulent purpose of causing the Southern Company to make default, and thereby to enable the architects to assess damages against that company; and the plea further alleged that said architects were the creatures and tools of the plaintiff, absolutely dependent upon it for employment, and that they could not, and did not, fairly assess any damages that might have accrued in the matter. 9th. That the alleged architects' certificate was not their bona fide finding, but was the result of a fraudulent design to mulct the two defendant companies in damages. 10th. *Page 340 That under the contract the plaintiff was indebted to the Southern Company in an amount equal to, and greater than, the damages claimed by plaintiff. 11th. That the bond sued on was obtained by the fraud and misrepresentation of the plaintiff. 12th. That the alleged architects' certificate was obtained by fraud. The 13th and 14th as we have said are the same as the 8th and 9th except that they were filed on equitable grounds.
The plaintiff moved to strike out the 1st and 3rd pleas, and this motion was correctly overruled. The plaintiff then joined issue on the 1st and 3rd pleas, demurred to the 2d 4th, 5th, 6th, 7th, 8th, 9th, 12th 13th and 14th, and demanded a bill of particulars as to the 10th plea and replied to the 11th plea that the bond was not obtained by fraud. The demurrer was sustained as to the 2d 4th, 5th, 7th, 9th, 12th, 13th and 14th pleas, and was overruled as to the 6th and 8th. The defendant failed to furnish a bill of particulars as to the 10th plea, and it was thus eliminated, and the defendant did not plead over as to any pleas to which the demurrer was sustained. The plaintiff replied to the sixth plea that the contract was not materially altered so as to release the defendant from liability on the bond, and replied to the eighth plea that it did not agree to supply the Southern Company with money to perform the contract nor to finance any of its requirements, and denied all the other allegations of that plea relating to said architects. Subsequently, by leave of Court, the Aetna Company filed two additional pleas; the substance of the first was that the Southern Company did abandon the contract, by reason of which the Aetna Company acquired the right to sub-let or complete the contract, and the plaintiff wrongfully entered upon and completed the contract and thereby deprived the Aetna Company of said right and privilege.
The second additional plea set up the same defence as the first, but set out in full the conditions 2 and 3 recited in the bond under which said right and privilege was claimed, and then alleged as in the first additional plea the facts which *Page 341 it claimed operated to defeat its right and privilege. The plaintiff demurred to these two additional pleas, and the demurrers were sustained. The case thus went to the jury, as to the Aetna Company, upon the issues raised by the first, third, sixth, eighth and eleventh pleas, viz, nul tiel corporation;non est factum as to the bond sued on; material alteration of the contract, releasing the Aetna Company from liability on the bond; the question of agreement by plaintiff to finance all requirements of the Southern Company under the contract, and the fraudulent breach of such agreement; and the obtaining of the bond by fraud.
The second and seventh pleas of the Aetna Company were clearly demurrable because they both stated merely conclusions or matter of law. Code, Art. 75, § 2. Gent v. Cole, 38 Md. 110. For the same reason it is at least open to question whether the sixth plea was not also demurrable, though the trial Court held otherwise, and that question is not before us. The other original pleas of the Aetna Company were founded upon the architects' certificate, but as this certificate was excluded by the Court, this appellant in its brief very properly concedes, that any error in ruling upon those pleas would not constitute reversible error. The record does not disclose the ground upon which this certificate was excluded, but there is an intimation in one of the briefs that it was because the certificate showed upon its face that the auditing was made merely upon the checks and vouchers of expense produced by the plaintiff, and not upon apersonal examination and inspection of the work done in the completion of the contract. We think that is the inference which must be drawn from the language of the certificate, and as it is clearly the professional skill and personal judgment of the architects as to the character and quality of the work done by the plaintiff, to which the parties are entitled under the contract, we are of opinion the certificate was correctly excluded.
The Aetna Company earnestly contends, however, that the declaration is defective in failing to allege specifically that *Page 342 the notice of default required by condition two of the bond was given, and that a proper opportunity thereafter was given the Aetna Company to sublet or complete the contract. It contends that these were conditions precedent, which must be alleged in the declaration, as well as proved, in order to maintain the action. Whether the conditions or covenants of a contract are precedent or independent has been a fruitful subject of discussion, but we think Mr. Poe has succinctly stated the principle applicable to this case in sec. 565 of his work onPleading, 3rd Ed., in which he says: "When a right of action is once vested, any circumstance the omission of which goes to defeat it, whether called by the name of a proviso, by way of defeasance, or a condition subsequent, must in its nature be a matter of defence, and need not be stated in the declaration." For reasons which will be hereafter stated, we think it will appear that the Southern Company abandoned the contract, whereby a right of action was at once vested in the plaintiff. Damage, in greater or less degree, even if only nominal damage, was the natural and necessary consequence of such abandonment, and this damage would not be satisfied by the mere subletting or completion of the contract by the Aetna Company. Hence the deprivation of the right to sublet or complete the contract, even if established, would go only in reduction of damages to such extent as the proof would warrant, and must necessarily be a matter of defence only. The demurrer to the two additional pleas was therefore properly overruled.
The Southern Company filed twelve pleas, misnumbering the last three as the eleventh, twelfth and thirteenth. Issue was joined on the fourth plea, which was non est factum, and all the others were demurred to. The demurrer was overruled as to the sixth, seventh and thirteenth and sustained as to all the others. The sixth plea set up an agreement to finance the contract for the Southern; the seventh charged that the plaintiff failed to pay the Southern Company certain sums as stipulated in the contract; and the *Page 343 thirteenth, as a plea on equitable grounds, charged that the plaintiff, with the fraudulent and malicious purpose of ruining the Southern Company financially, and making it impossible to comply with said contract, wrote and sent to certain creditors of the Southern Company a letter set out in said plea. The plaintiff then traversed the sixth, seventh and thirteenth pleas and issue was joined thereon. The first, second, third, ninth, and twelfth pleas all related to the architects' certificate, and as this was not admitted when offered in evidence, no injury could result from sustaining the demurrer to these pleas. The fifth plea merely charged that the plaintiff violated the terms of the contract, without stating any fact "to inform the Court, whose duty it is to declare the law arising upon the facts, and to apprise the opposite party of what is meant to be proved, in order to give him an opportunity to answer or traverse it."Gent v. Cole, supra. The eighth plea is identical in substance with the thirteenth, which was filed on equitable grounds, and the full benefit of that plea was obtained in the issue joined on the thirteenth. The eleventh plea is the same as the Aetna Company's thirteenth plea on equitable grounds, and what we have said as to the Aetna's thirteenth plea applies to the Southern's eleventh plea.
We are thus brought to the end of these voluminous pleadings.
Twenty exceptions were taken to rulings upon the evidence, and one to the ruling on the prayers.
The first and second exceptions raise the most important question in the case. The architect's certificate having been excluded, the Court permitted the plaintiff in the first exception to show by the witness Beaumont, who was plaintiff's superintendent in Baltimore at the time this work was being done, that all the work done in completing this contract was necessary for the purpose and that the prices paid for labor and material were the prevailing market prices; and in the second exception the plaintiff was permitted to show by the witness Simonson, an architect of conceded experience *Page 344 and qualification as an expert, what was the reasonable cost of completing this contract after suspension by the Southern Company. The objection to this evidence was that in the absence of the architects' certificate recovery must be limited to nominal damages. But we think this evidence was properly admitted. We have already said that we are of opinion the evidence shows that the Southern Company abandoned the contract, thus bringing this case within the decision in Smith v.Jewell, 104 Md. 269. The total suspension of work under this contract, and the consent to the appointment of a receiver, thus voluntarily putting it out of its power to continue, is, in law and in fact, an abandonment of the contract, carrying with it all the legal consequences of abandonment, chief among which is the opening of the door to the ordinary rules of evidence in estimating the damages for breach of the contract. But there is another and equally satisfactory reason for the admission of such testimony in this case. All the cases agree that where the failure to produce an architect's certificate is due to fraud or bad faith on the part of the architect, the rule requiring such certificate must give way. The evidence is undisputed in the present case that the architects, though requested and urged to give a certificate prepared by the plaintiff's counsel, refused to give any other form than that which the Court properly excluded. We are not to be understood as charging these architects with actual fraud, or with any fraudulent purpose, but it was their duty to make such a personal examination of the work done in completing the contract as would have enabled them to give a proper certificate such as would have been admitted in evidence, and when they neglected that duty, it operated as injuriously upon the rights of the plaintiff as an absolute refusal in bad faith to give any certificate whatever.
Both defendants in this case had alleged — the Aetna by its eighth plea, and the Southern by its sixth plea — that the architects were incapable of fairly and justly estimating these damages, and they ought not to be allowed, while seeking *Page 345 to exclude such estimate, to exclude also any other mode of proof.
The third, seventh, eighth, ninth, tenth, eleventh, twelfth, sixteenth, seventeenth, eighteenth, nineteenth and twentieth exceptions were all taken to rulings which excluded parol testimony offered to vary the written agreement between the parties, and we can discover no error in any of these rulings. In each of these instances, the effort of the defendants was to introduce evidence as to an alleged verbal agreement antecedent to the written agreement, but differing from it. The fourth, fifth and sixth exceptions may be considered together. These all sought to introduce alleged statements made by Witherspoon, plaintiff's manager, as to the responsibility of other bidders for this contract, with a view to show that these alleged representations influenced the Aetna Company in executing the bond. If this were an action of deceit by the Aetna Company against the plaintiff, proof that such statements were made, followed by proof of the falsity of those statements, and that the Aetna Company had a right to rely upon them, a different situation would be presented. But in this case the matter inquired into was wholly irrelevant.
The thirteenth exception was taken to the refusal to allow the witness Purnell to say why the plaintiff did not pay the Southern's pay roll of August 25th, presented after the work had been stopped. The question was not whether any reason for not paying this pay roll had been given by plaintiff, but simply why it had not paid it. If the object had been to elicit a statement of plaintiff against its interest, or to lay before the jury any reason put forward by the plaintiff, it would have been a proper question; but to have allowed the question as framed would have been to permit the witness to give his mere opinion of the reason which governed the plaintiff in refusing to make that payment.
The fourteenth and fifteenth exceptions relate to the letter written by the plaintiff on August 18th, and mailed to a number of the creditors of the Southern Company, informing them that under the contract they could only pay a certain *Page 346 percentage of the total amount of the contract price, and that they, therefore, would not guarantee payment for labor or material after that date. That letter was set out in the thirteenth plea of the Southern Company, and the plea alleged that it was written and sent with the malicious and fraudulent purpose to make it impossible for that defendant to comply with the contract and issue was joined upon that plea. The evidence shows that at that time the plaintiff had advanced and paid nearly $60,000 on the contract of $68,000, while only about 55 to 60 per cent. of the work had been done. Unless the plaintiff was bound by the terms of its contract to furnish the Southern Company with all the money necessary to complete the contractat such times as it should demand, it had the right to protect itself by such a notice to the creditors of the Southern. Because it had seen fit to make advances not required by the contract so long as it felt safe in doing so, is no reason why it should continue to do so, when it was clear to any prudent person that the danger point had been reached. If they had not ceased those payments, they would in a few days have trenched upon the reserve which under the contract they were bound to maintain for the protection of the Aetna Company, in which event that company would have had a good cause of complaint and defence in this action to that extent.
In the fourteenth and fifteenth exceptions the defendants sought to show as a matter of defence that they were unable after these letters were sent out to purchase materials from the parties to whom they were sent, but if the plaintiff had complied with the terms of its contract as to payments, it was wholly immaterial to any issue in this case what effect their refusal todo more than their contract required had upon the ability of the Southern Company to perform its part of the contract.
There was no error in these rulings.
The Court granted four prayers of the plaintiff, viz, the first, second, sixth and eighth, amending the first, second and eighth before granting, and we shall request the Reporter *Page 347 to set these out in full. We approve the propositions of law embraced in these instructions, as in conformity with the views we have expressed herein in dealing with the questions of pleading and the exceptions to the rulings upon the evidence.
The plaintiff's first prayer requires the jury to find that the plaintiff had fully performed its part of the contract up to the time work was stopped; that the Southern Company abandoned the contract, and the plaintiff thereupon completed the same; and instructed the jury that upon such finding their verdict must be for the plaintiff, unless they should also find that the execution of the bond was procured by the fraud or misrepresentations of the plaintiff.
The plaintiff's second prayer as to the measure of damages correctly states the law, and is practically in accord with the defendants' contention, as set forth in its fourteenth granted prayer dealing with the measure of damages in event of recovery. There was not a particle of evidence of any malicious or fraudulent purpose to destroy the credit of the Southern Company, or to prevent its execution of the contract, either in writing and sending the letter of August 18th, set out in the Southern's thirteenth plea, or in any other act or word of the plaintiff, and it was therefore proper to instruct the jury in the plaintiff's sixth prayer that upon that issue their verdict must be for the plaintiff as against the Southern Company.
What we have said as to the alleged representations of Witherspoon to Hunter, in referring to the fourteenth and fifteenth exceptions is applicable to the plaintiff's eight prayer, which was properly granted.
The Southern Company offered three prayers, all of which were refused. They were all predicated upon the exclusion of the architects' certificate, and the contention that there could be no recovery upon any other evidence. It follows from what we have already said that these prayers were properly refused. *Page 348
The Aetna Company offered eighteen prayers, of which the Court granted the twelfth, thirteenth and fourteenth, as offered, and modified the second and sixteenth, and granted them as modified. We shall request the Reporter to set out the defendant's granted prayers also.
The second prayer, as amended by the Court, correctly interpreted the thirteenth clause of the contract as to the obligation to make payments in instalments as the work progressed, and was correctly modified by adding that such failure, even if found by the jury, would not prevent a recovery by the plaintiff.
The twelfth prayer limited the recovery in any event to the "lowest reasonable cost of completing the contract." This prayer would not have been objectionable if it had omitted the word "lowest" and had declared "the reasonable cost" to be the standard for the jury.
The thirteenth prayer was liberal to the defendants in refusing to allow the recovery of any penalty for delay under the fourteenth clause of the contract.
The fourteenth prayer, as we have said, in referring to the plaintiff's second prayer, correctly states the credit to be allowed on any damages awarded by the jury.
The sixteenth prayer of the Aetna Company was correctly amended by the Court so as to permit, instead of requiring, the verdict to be for the defendant, but was liberal in the extreme to the Aetna Company in leaving to the jury to find that the alleged representations of Witherspoon to Hunter as to the receipt of other bids, within $2,000 of the Southern's bid, were untrue. That was the pith of the prayer. There is a presumption of truth always, which should be overcome either by positive evidence of falsity, or by suspicious circumstances so strong as to warrant a reasonable mind in believing that there was falsity, and we have not discovered any evidence of that character in the record.
It is not necessary to prolong this opinion by any detailed examination of the Aetna's rejected prayers. *Page 349
The first, third, fourth, fifth and eighth prayers are based on the absence of the architects' certificate and the contention that no other character of evidence was admissible to prove the damages. The sixth, seventh, ninth and fifteenth prayers attempt to procure instructions based upon the excluded evidence offered to prove a verbal contract antecedent to and contradictory of the written agreement. These prayers were skillfully drawn so as to confuse the payments stipulated for in the written agreement with the alleged verbal undertaking to finance the contract by making advances at the demand of the Southern. The defendants received all to which they were entitled upon that score in the proviso of the plaintiff's first prayer, which instructed the jury they could not find for the plaintiff if they found the bond was procured by the fraud or misrepresentations of the plaintiff.
The tenth prayer submits to the jury to find whether the plaintiff afforded the Aetna Company a reasonable time to elect whether it would sublet or complete the contract, and was defective for that reason. No time being mentioned in the contract for that purpose, the question of reasonable time is one of law for the Court upon the facts, and the evidence does not show there was a denial of reasonable time. Wheeler v.Harrison, 94 Md. 147. The Aetna was notified of the default on the very day it occurred, August 23rd, by registered mail, and by repeated subsequent letters, and was finally, on September 1st, given till September 4th, "to go ahead or sublet the contract." This was nearly two weeks, an amply reasonable time in our opinion to make its election.
The eleventh prayer is apparently in conflict with the Aetna's fourteenth granted prayer, and was properly rejected for that reason, if no other.
The seventeenth and eighteenth prayers were properly rejected as in conflict with plaintiff's eighth prayer, by which the jury were instructed that the representations mentioned in that prayer, being the same mentioned in the Aetna's seventeenth and eighteenth prayers, were not such representations, even if made, as constitute a defense to this action. *Page 350
Being of opinion that the whole case was fairly presented upon the granted prayers, the judgment will be affirmed.
Judgment affirmed, with costs to the appellee above andbelow.
A motion for a re-argument was made, and, in disposing of the same,