The action is brought upon a building contract for the balance due, and also for extra work. It was a *Page 90 condition of the contract that the building should be complete and perfect in every respect by the 1st of May, 1882, "to the satisfaction of N. LeBrun Son, architects," "and that no payment should be made until a certificate of the architects that the payment is due has been presented to the owner, nor the last payment be required until the building is complete and perfect, nor unless the architects shall also certify that the contract has been fully performed, and the work finished, complete and perfect in every respect, and to his satisfaction." It was also provided that any dispute concerning the construction, or meaning of the plans, "shall be decided by the architects," and their decision be final and conclusive, and that any other difference between the parties shall be submitted to the arbitration of two competent and disinterested persons selected in a manner prescribed by the contract. The contract also provides for penalties to be imposed upon the builder for delay in the completion of the work. It appears by the evidence that the work was not completed at the time specified in the contract; that from time to time fault was found by the owner with the slow progress of the work, and its character, but it was also in evidence that afterward he moved into and continued to occupy the house, and two questions were submitted to the jury: First, did the defendant accept the house as a complete building under the contract; second, if it was so accepted, was the delay in its completion occasioned by the defendant's own fault.
It cannot be doubted that under the terms of this contract no claim could be made for payment for any work or services, unless accompanied by a certificate of the architects. This provision is repeatedly inserted in the contract, and it was the obvious intention of the owner to be protected at all points by the judgment, skill and opinion of the architect to whom had been intrusted the supervision of the building. The certificates were not given, but as it was in the power of the owner to impose as condition of liability that the certificates should be procured, so it was in his power to waive their production, and if, by any act of his, he prevented the *Page 91 architect from certifying, or interfered with him in a conclusion which might justify and require a certificate, he cannot complain if the builder is permitted to recover without its production.
In the case before us it appeared that the builder applied to the architect for his certificate in regard to the character and cost of the extra work, but he refused to give it, and this refusal was put upon the ground that the owner had instructed him to give no more certificates. This evidence was received without objection, and it was not controverted. It also appears by the evidence of the plaintiff that he finished the house about the first of July, and by the evidence of the defendant that the plaintiff called upon him, and requested payment, and at that time he said, "Mr. Smith, the work is not done yet. Go on and finish the work; your money is ready whenever the house is done." The builder replied, "Well, what do you want me to do?" The defendant said, "Finish the doors, look at the trimming of the house, where the plastering is, look at the cracks." The plaintiff replied, "Well, I will attend to that." It was put off from time to time. The defendant then adds: "The last time Mr. Smith called upon me for settlement I told Mr. Smith, `I am ready to settle with you, but I have a claim against you; under your contract you are under a penalty for stipulated damages for every day after the first day of May that you have delayed me in having my building;' he asked me what is that? I replied, `You can calculate, you called Mr. LeBrun to make a final inspection of the building on the thirtieth of August, by that you admit that the building was not completed until that time; now you can calculate from that time, I will charge you nothing after that, and fix the amount. I will give you a check for it.'"
Now the jury might well find from that evidence that the work was considered as completed and finished to the satisfaction of the owner, at any rate as early as the thirtieth of August. That is the admission of the owner. The only question raised by him was as to the penalty for delay in the completion of the building. Upon this evidence, therefore, the judge was justified *Page 92 in leaving it to the jury, saying as he did, that if this was accepted as a completed contract, the only remaining question was whether the delay after the first of May was occasioned by the defendant's own fault, or whether the claim based upon it was waived by him, at the same time stating the amount of the plaintiff's claim as established, to be $5,368.57, provided he was not at fault, or if the defendant waived the condition as to its completion within the specified time; otherwise, he said, you will deduct from that amount the sum of $2,950, being the aggregate penalty for delay from the first of May to the thirtieth of August.
On the other hand it was contended on the trial by defendant's counsel that in no event, no matter how complete the satisfaction of the defendant, a recovery could not be had without the production of the architect's certificate and refusal on defendant's part to pay according to its terms; without that, he claimed, there could be no breach, consequently no right of action. The view of the court was to the contrary. It held, and so instructed the jury, that the defendant could waive the stipulations he had introduced into the contract for his own benefit, and that if he accepted the house as under a complete contract, the plaintiff would be entitled to recover although no certificate had been given, and even if the architect was not satisfied. This was the principal question presented; it was, we think, rightly decided, and the verdict of the jury was a complete answer, not only to the matter of defense, but also to the counter-claim.
Some other points are made by the appellant: First, that the trial judge improperly denied the defendant's application to postpone, or put off the trial. This fact was proper for consideration upon motion for a new trial, and by the General Term upon appeal from the order denying it, but is not the subject of exception, or available upon appeal in this court.Second, that the difference between the parties should have been submitted to arbitrators under the clause in the contract relating to arbitration. No evidence was given that the defendant took any steps for their selection. It was not more *Page 93 the duty of the plaintiff than that of the defendant to do so. We need not inquire, therefore, how far, if at all, such defense would have availed.
We think the judgment should be affirmed.
All concur.
Judgment affirmed.