UNITED STATES DISTRICT COURT
FOR THE DISTRICT OF COLUMBIA
_________________________________________
)
UNITED STATES OF AMERICA, for the use )
and benefit of AMERICAN CIVIL )
CONSTRUCTION, LLC, )
)
Plaintiff, )
)
v. ) Case No. 14-cv-00745 (APM)
)
HIRANI ENGINEERING & LAND )
SURVEYING, P.C., et al., )
)
Defendants. )
_________________________________________ )
MEMORANDUM OPINION
Plaintiff American Civil Construction, LLC, has filed suit against Defendants Hirani
Engineering & Land Surveying, PC (“Hirani”), and Colonial Surety Company (“Colonial”) in
connection with its work as a subcontractor on a federal government project. Plaintiff brings a
state law claim against Hirani for breach of contract and, separately, seeks relief in the name of the
United States against Colonial under the terms of the Miller Act, 40 U.S.C. § 3133, for Hirani’s
failure to pay Plaintiff. Plaintiff alleges that it is entitled to recover more than $2 million in
damages. Colonial has filed multiple counterclaims in response. Now before the court are
Defendants’ motions for summary judgment and to strike Plaintiff’s jury demand.
After thorough review of the record, the court denies Defendants’ Motion for Summary
Judgment but grants Defendants’ Motion to Strike Plaintiff’s Jury Demand.
I. BACKGROUND
A. The Prime Contract and Subcontract
On or about September 16, 2010, Defendant Hirani Engineering & Land Surveying, PC
(“Hirani”), entered into Contract No. W912DR-10-C-0093 (the “Prime Contract”) with the United
States of America, through the United States Army Corps of Engineers (“the USACE”), to
construct the “Washington D.C. Local Flood Protection Project, 17th Street Closure Structure,
Washington D.C.” (“the Project”). See Defs.’ Mot. for Summ. J., ECF No. 44 [hereinafter Defs.’
Mot. for Summ. J.], Defs.’ Stmt. of Material Facts, ECF No. 44-1 [hereinafter Defs.’ Stmt. of
Facts], ¶ 1 (citing Pl.’s Second Am. Compl., ECF No. 26 [hereinafter Second Am. Compl.], ¶ 5).
To fulfill its obligations under the Prime Contract, Hirani entered into a written contract on April
4, 2011, (“the Subcontract”) with Plaintiff American Civil Construction, LLC, under which
Plaintiff would perform specified work (“the Work”) on the Project. See Defs.’ Mot. for Summ.
J., Attach. 3, ECF No. 44-3 [hereinafter Moldovan Decl.], at 7–17 (Ex. B) [hereinafter
Subcontract]. 1 Consistent with the requirements of the Miller Act, Hirani obtained a payment
bond from Defendant Colonial Surety Company (“Colonial”) to secure payment to Plaintiff under
the Subcontract. See 40 U.S.C. § 3131(b)(2); Moldovan Decl. at 4–6 (Ex. A).
The Subcontract outlines each party’s obligations under the agreement, including, but not
limited to, a description of the Work; when the Work should begin; and the amount owed Plaintiff
for completing the Work. The first clause of the Subcontract states that Plaintiff
shall provide the entire scope of work to construct and manage the
17th Street closure structure except for the Project Manager and the
misc. metal structures/panels as required by Hirani under the base
bid to the USACE and related work required (hereinafter the
“Work”) for the Local Flood Protection Project @ 17th Street
1
All pin citations to Defendants’ Exhibits reference the original pagination of each Exhibit.
2
Closure Structure (hereinafter the “Project”) located at 17th Street
(hereinafter the “Premises”).
Subcontract at 1 (Art. I, § 1.1). Schedules A and B of the Subcontract define the Work more
specifically. See id. (Art. I, §§ 1.2, 1.3). For example, Schedule B states that Plaintiff must
“[p]rovide project supervision (Superintendent, Site Safety Officer, Traffic Control Officer) except
for a project manager to act on behalf of [Hirani]”; “[p]rovide an on-site field office as per the
specifications for the USACE”; and “remove, store[,] and reinstall pedestrian light poles
throughout construction.” Id. at 9 (Sch. B, Pts. 2, 6, 16). Hirani retained the right to change, add,
or eliminate portions of the Work “at any time whatsoever, whether the Work or any part thereof
shall or shall not have been completed,” by written order submitted to Plaintiff, and Plaintiff agreed
not to seek “extra or additional compensation on account of any such work, unless same [sic] shall
have been done pursuant to a written order signed by” a designated Hirani representative. Id. at 2
(Art. IV, § 4.1). The Subcontract also specifies that:
The scheduling of all construction operations at the Project,
including the Schedule, shall be as mutually agreed with [Hirani],
and [Plaintiff] shall, if requested, furnish all scheduling information
in such form and detail as required by [Hirani], to the satisfaction
[Hirani] [sic], and [Plaintiff] shall furnish such information within
seven (7) days of request. [Plaintiff] shall also update and/or revise
such information as requested by [Hirani] at any time, either prior
to or during the performance of its Work.
Id. at 1–2 (Art. II, § 2.2). Additionally, of relevance here, the Subcontract requires Plaintiff, at
Plaintiff’s own expense, to clean up the worksite. Plaintiff agreed to
[o]n a daily basis or less frequently, and at [Plaintiff’s] own cost and
expense, (1) keep the area of the premises in which the Work is
being performed free at all times from all waste materials, packaging
materials[,] and other rubbish accumulated in connection with the
execution of the Work by collecting and depositing daily said
material and rubbish into dumpsters provided on grade by [Hirani],
(2) clean and remove from its own work and from all contiguous
work of others any soiling, staining, mortar, plaster, concrete or dirt
3
caused by the execution of the Work and make good all defects
resulting therefrom, (3) at the completion of its work in each area,
perform such cleaning as may be required to leave the area “broom
clean” and (4) upon the completion of the Work, remove all of its
tools, equipment, scaffolds, shanties, trailers, and surplus materials.
Id. at 3 (Art. VII, § 7.1).
Hirani and Plaintiff’s agreement also set out explicit terms for payment and what to do in
the event of a dispute concerning the agreement. The Subcontract states Plaintiff will be paid a
fixed sum of $2,845,600.00 for “all labor services, materials, equipment or other items acquired,
performed, furnished or used with respect to the Work,” which includes all applicable federal,
state, and local taxes. Id. at 2 (Art. III, § 3.1). Additionally, Plaintiff agreed not to stop or delay
performance of the Work or delivery of labor or materials simply because a “dispute,
controversy[,] or question” arose in the interpretation of the Subcontract, but rather, to continue
working “pending the determination of such dispute or controversy.” Id. at 6 (Art. XIV, § 14.1).
Lastly, the parties contemplated the grounds for contract termination. The Subcontract
calls for a different outcome when the agreement is terminated for default than when it is
terminated for convenience.
Termination for Default: Should [Plaintiff] fail to timely provide
labor, services, and/or materials for the Project in accordance with
the terms of this Subcontract, then Hirani shall have the right at any
time upon 7 days written cure notice to [Plaintiff] to terminate this
Subcontract and require [Plaintiff] to cease work hereunder.
Termination for Convenience: Should the [Government] choose to
terminate Hirani for the convenience of the [Government], then
[Plaintiff] shall be similarly terminated, and the obligations and
rights of the parties shall be in accordance with the provisions of the
prime contract for such termination for convenience.
Id. at 6 (Art. XV, § 15.1).
4
B. Events Arising in the Course of Plaintiff’s Performance
The Project was plagued with delays and disputes, the timeline and substance of which
underlie the present litigation. The record begins, for all intents and purposes, when the USACE,
by letter dated February 12, 2013, first gave Hirani notice of its intent to terminate the Prime
Contract in light of Hirani’s purported failure to perform in the agreed upon timeframe and
required Hirani to show cause why the Prime Contract should not be terminated. See Defs.’ Stmt.
of Facts ¶ 7; Moldovan Decl. at 18–19 (Ex. C).
After receiving the Show Cause Notice, Hirani wrote to Plaintiff. 2 By letter dated February
18, 2013, Hirani informed Plaintiff of the USACE’s intent to terminate the Prime Contract,
requested Plaintiff submit any facts assisting Hirani in demonstrating why the Prime Contract
should not be terminated, and stated that “[t]he USACE[’s] contention is that [Plaintiff] has
delayed or simultaneously delayed this project and if you believe other wise [sic] you should have
been submitting delay schedules and information showing the delay.” Moldovan Decl. at 23–26
(Ex. E), at 1 [hereinafter Defs.’ Ex. E]. The letter identified several perceived deficiencies in the
timeliness and substance of the Work Plaintiff owed under the Subcontract, including that Plaintiff
had failed to send Hirani project scheduling information. Id. at 2. Hirani demanded Plaintiff
provide a detailed schedule on or before February 22, 2013; cure its deficient performance; and
identify any material facts regarding those deficiencies by close of business that day. Id.
2
The record reflects that Hirani also wrote to Plaintiff prior to receiving the USACE’s first Show Cause Notice. By
letter dated February 13, 2013, Hirani chastised Plaintiff for harassing one of Hirani’s field representatives, causing
him to quit; stated that the “items preventing timely completion [of the Subcontract are] within [Plaintiff’s] scope of
work and the current status of these items (caisson 12 repairs and project Stone work) are only due to [Plaintiff’s]
actions or inaction regarding submittals and the execution and completion of the work”; and requested “a proper
schedule to show how you plan to complete your contract work by April 19th, 2013.” Moldovan Decl. at 20–22 (Ex.
D).
5
Plaintiff responded to Hirani’s letter on February 22, 2013, and disputed that the Work was
behind schedule. Plaintiff noted that there is “no contractually required completion date for this
project” and “there is not and never has been any mutually agreed upon schedule for any work to
be done regarding [Caisson 12] or any other work at the project.” Moldovan Decl. at 27–36 (Ex.
F), at 1. Additionally, Plaintiff provided an itemized list of 27 causes for the Project’s delay that
were outside Plaintiff’s control. See id. at 3–9. Amongst these, Plaintiff cited the Government’s
failure to obtain necessary permits and coordinate neighboring projects; weather delays; “change
order work . . . in excess of $500,000 . . . increasing the project scope by more than 20%”; Hirani
and the USACE’s failure to provide field management on site; and Hirani and the USACE’s failure
to “timely process Payment Requisitions for the project and make complete and proper payments
to [Plaintiff], from which necessary cash flow to [Plaintiff] could be properly maintained.” Id. As
part of its response to the USACE’s Show Cause Notice, by letter dated February 25, 2013, Hirani
parroted Plaintiff’s reasons for delay attributable to the Government and outlined a plan for future
progress. See Moldovan Decl. at 37–46 (Ex. G) [hereinafter Defs.’ Ex. G].
Substantial progress on the Project remained elusive, however, and the record reflects that
Plaintiff and Hirani’s relationship fractured in spring 2013. By letter dated March 12, 2013,
Plaintiff informed Hirani that it would be out of productive work on the Project within the
following three days due to Plaintiff and Hirani’s inability to agree on the scope and price of
additional work Hirani had demanded, Hirani’s failure to provide written direction on other aspects
of the Project in light of changed or unanticipated circumstances, and outstanding engineering and
architectural layout problems with the original plans for certain portions of the Project. See
Moldovan Decl. at 47–54 (Ex. H). As a result, Plaintiff explained, it would be “forced to
significantly reduce [its] work force at the project site . . . . [and its] heavy and light equipment
6
complement at the work site,” and would be “demobilizing specific or all pieces of heavy
equipment accordingly,” as well as “other tools and equipment during the upcoming period” so as
“to mitigate damages and costs associated with the temporary shutdown of field operations due to
no fault of [Plaintiff].” Id. at 6. On-site supervision also posed a problem. The record indicates
that there was “no on-site supervision from September 29, 2012 through February 18, 2013.” See
Pl.’s Opp’n to Defs.’ Mot. for Summ. J., ECF No. 46 [hereinafter Pl.’s Opp’n to Summ. J.], Attach.
3, ECF No. 46-3 [hereinafter Pls.’ Opp’n Attach. 3], at 1–10 [hereinafter Stephen Decl.], ¶ 9.
Although a new supervisor began work on February 19, 2013, he quit on April 10, 2013. Id. ¶ 10.
The USACE informed Hirani on March 15, 2013, that it had failed to satisfy the Show
Cause Notice, see Moldovan Decl. at 55–61 (Ex. I), at 1, exacerbating tensions between the
USACE and Hirani, as well as between Hirani and Plaintiff. The USACE rejected each of the 24
reasons Hirani had outlined as cause for the Project’s delay and set forth 11 “key milestone dates”
that Hirani had to meet in order to avoid termination of the Prime Contract. See id. at 1–5. This
led Hirani, in turn, to write Plaintiff and state that “[Plaintiff’s] show cause response was not
acceptable.” See Moldovan Decl. at 64–71 (Ex. K), at 1. The letter rejected Plaintiff’s prior
statement that there “has never been a mutually agreed schedule” because “[Plaintiff] was always
responsible for providing the scheduling information required to complete the . . . [Work].” Id.
Additionally, Hirani stated it “always timely processed pay requisitions and made proper payments
to [Plaintiff],” but Plaintiff “refused to provide proper invoices or a schedule of values which sums
to their contract total.” Id. at 6. The invoices that had been submitted, Hirani claimed, were
“inflated and intentionally attempt[ed] to exceed [Plaintiff’s] subcontract value.” Id. At its close,
Hirani’s letter laid out the 11 “key milestone dates” Hirani had received from the USACE and
stated that Plaintiff had to meet those deadlines to avoid termination of the Subcontract. Id. at 7.
7
Hirani noted that because certain deadlines had already passed, Plaintiff needed to provide a
revised schedule for completing the Work. Id.
Throughout this period, Plaintiff kept Colonial and the USACE informed of Hirani’s failure
to pay Plaintiff amounts it believed were owed under the Subcontract. On March 18, 2013—prior
to receiving Hirani’s rejection of its efforts to show cause—Plaintiff e-mailed Colonial to give
notice that it would be out of work as of the following day, March 19, 2013, and to seek help in
securing payment for its performance thus far. See Moldovan Decl. at 62–63 (Ex. J). Plaintiff
claimed that Hirani had “flatly refused to honor their payment commitments and chosen to commit
payment fraud,” causing Plaintiff to be “about out of operating money.” Id. Plaintiff’s e-mail
further stated that it had conferred with the USACE, which had told Plaintiff that if it is “not able
to continue work for those two specific reasons . . . . i.e. non-payment and not able to proceed due
to Hirani’s not authorizing the CO work properly . . . . . then Hirani will probably be terminated at
once. . . . . .” Id. (alterations in original). Plaintiff sent another e-mail to Colonial on March 26,
2013—after receiving Hirani’s rejection of its efforts to show cause—stating that Hirani had not
paid Plaintiff, Plaintiff was “out of money, and the crews ha[d] been off since Friday afternoon.
. . . . . Without money and mutually agreed change orders to the subcontract, [Plaintiff is] not able
to proceed with any work at site [sic].” Moldovan Decl. at 72–74 (Ex. L) [hereinafter Defs.’ Ex.
L], at 1 (alterations in original). Plaintiff estimated that it was owed approximately $221,000 for
the pay period that ended on March 24, 2013. Id. Plaintiff’s letter stated that Plaintiff had
conveyed this information to the USACE, see id. at 2, and Plaintiff followed up with another e-
mail to Colonial two days later, on which the USACE was copied, repeating that Plaintiff remained
out of productive work due to Hirani’s failure to pay, see Moldovan Decl. at 75–76 (Ex. M).
8
Hirani urged Plaintiff not to stop its work in light of the disagreement over payment. By
letter dated March 28, 2013, Hirani disputed that it owed Plaintiff for costs incurred as a result of
the delay, as Hirani attributed those costs to Plaintiff’s own fault, and that Hirani had not fully paid
Plaintiff, as Hirani believed it had not received “a proper invoice[,] as required by the subcontract
agreement.” Moldovan Decl. at 77–79 (Ex. N) [hereinafter Defs.’ Ex. N], at 1. Hirani noted that
if Plaintiff thought it had not been paid in full, then Plaintiff should “specifically detail what [it
has] not been paid and provide a full and detailed schedule of values that sums to [Plaintiff’s]
contract total.” Id. In the interim, Hirani directed Plaintiff to continue working because “[t]he
USACE was clear . . . that they will terminate Hirani’s contract if work does not continue, which
will result in [Plaintiff]’s termination as per the subcontract agreement and be directly due to
[Plaintiff]’s failure to continue work on the project.” Id. Plaintiff replied with an e-mail the
following day, in which it continued to dispute that the delays were its fault and stated it was
continuing to perform work on the Project but had “simply run out of productive work to perform”
in light of nonpayment. Moldovan Decl. at 80–84 (Ex. O), at 1–2. Plaintiff urged Hirani to make
the payments owed and provide change orders so productive work could continue. See id. at 2–3.
By this point, Plaintiff believed Hirani owed it more than half a million dollars. In a more
formal letter to Hirani, Plaintiff clarified that the last payment it had received on or “about
December 5, 2012 was for work completed through November 20, 2012,” and Plaintiff had not
been paid since, despite the USACE continuing to pay Hirani. See Pls.’ Opp’n Attach. 3 at 28–45
(Ex. A) [hereinafter Pl.’s Ex. A], at 1–2.3 With its letter, Plaintiff included an itemized list of the
3
The parties do not dispute that the USACE paid Hirani $285,947.84 in progress payments on March 4, 2013, for
work performed by Plaintiff between November 22, 2012, and February 20, 2013. Compare Pl.’s Opp’n to Summ.
J., Pl.’s Stmt. of Material Facts, ECF No. 46-2, ¶ 3, with Defs.’ Reply in Supp. of Summ. J., ECF No. 53, Defs.’ Resp.
to Pl.’s Stmt. of Material Facts, ECF No. 53-1, ¶ 3. Plaintiff’s letter alleged that, as of March 29, 2013, “Hirani ha[d]
invoiced to the [USACE] and been paid to-date $3,475,273.12 through February 12, 2013 for base contract work and
9
total payments the USACE had made to Hirani through February 20, 2013, and the total payments
that “SHOULD HAVE BEEN MADE to [Plaintiff]” through February 20, 2013, then compared
the difference to determine that Hirani owed Plaintiff $373,189.93. Id. at 3–4. This figure,
according to Plaintiff, did not account for (1) “specific extra work directed and other field charges
invoiced by [Plaintiff] to Hirani,” which exceeded the scope of the Work under the Subcontract;
(2) legal indemnification fees; or (3) “base contract ad [sic] change order monies for work
completed between February 13, 2013 and March 24, 2013.” Id. at 4. Adding in those costs and
making the bill current to March 29, 2013, Plaintiff calculated that Hirani owed it $524,907.19 and
demanded immediate payment. Id. at 4–5.
The USACE subsequently issued Hirani a second notice of its intent to terminate the Prime
Contract. See Moldovan Decl. at 85–87 (Ex. P). The notice stated that Hirani was now 549 days
behind the Project’s anticipated schedule, with 369 of those days due to “contractor-only or
inexcusable delays[,] and the remaining 180 days [due to] . . . non-compensable concurrent or
weather delays.” Id. at 1. To avoid termination of the Prime Contract, the USACE directed Hirani
to meet a new schedule of 13 “milestone dates,” under which construction would be completed
and all requisite documents submitted by June 30, 2013. Id. The USACE also warned that Hirani
had “placed completion of this project in jeopardy by disregarding” its obligations to promptly pay
its subcontractor. See id. at 2. Lastly, the USACE stated that, “in order to protect the interests of
the Government[] and due to the fact that the contractor is severely behind schedule,” it would
withhold $125,000 in payment until the Project was “substantial[ly] complet[e].” Id.
change orders[,]” but “only paid [Plaintiff] the amount of $2,515,043.56 for base contract work and change orders,
with the last payment being made to [Plaintiff] on or about December 5, 2012.” Pl.’s Ex. A at 2.
10
When Hirani’s on-site supervisor quit on April 10, 2013, the USACE warned Hirani that it
was in breach of the Prime Contract and directed Hirani to temporarily shut down Plaintiff’s
operations, as of April 15, 2013, in light of Hirani’s failure to provide field supervision. See
Stephen Decl. ¶¶ 10–12; Pls.’ Opp’n Attach. 3 at 50–51 (Ex. D), at 1. Plaintiff received verbal
notice from Hirani of the need to temporarily suspend its operations on the afternoon of April 12,
2013, and wrote to Hirani on April 14, 2013, to provide written confirmation of the reasons for
stopping its performance. See Moldovan Decl. at 91–93 (Ex. R).
Although Hirani hired a new site supervisor and Plaintiff resumed working on the Project
on April 23, 2013, see Stephen Decl. ¶ 13, Plaintiff’s performance shortly came to a halt once
more. The USACE sent Hirani a letter on Friday, April 26, 2013, notifying Hirani of its final
decision to terminate the Prime Contract, effective immediately. See Moldovan Decl. at 97–100
(Ex. T) [hereinafter Defs.’ Ex. T]. The USACE explained that it was terminating the contract due
to Hirani’s “failure to (1) complete the contract by the extended contract completion date; (2)
respond to the Government’s repeated requests to correct performance deficiencies; and (3)
provide adequate assurances that the contract will be completed in the near future.” Id. at 1. The
letter specifically noted that “critical work onsite has ceased since 22 March 2013 due to
subcontractor management and non-payment issues,” and Hirani had “not submitted periodic
progress schedules.” Id. Heavy rains prevented Plaintiff from performing any Work on Monday,
April 29, or Tuesday, April 30, 2013. See Pls.’ Opp’n Attach. 3 at 81–159 (Ex. J) [hereinafter
Pl.’s Ex. J]. Plaintiff learned of the USACE’s decision to terminate the Prime Contractor on April
30, 2013, but Hirani told Plaintiff on May 1, 2013, that Plaintiff was “not to stop working” because
Hirani intended to fight the termination. See id. Plaintiff’s Quality Control Reports reflect that
11
Plaintiff was on site and working on May 1, 2013, but on May 2, 2013, no Work was performed
in light of the USACE’s termination of the Prime Contract. See id.
Plaintiff’s performance did not resume. Hirani replied to the USACE’s final notice of
termination on April 30, 2013, by rejecting the purported termination for default as defective on
the grounds that Hirani never received an opportunity to cure and the USACE had caused the
delays in construction. See Pl.’s Opp’n to Summ. J., Attach. 4, ECF No. 46-4, at 145–48 (Ex. T).
At some point thereafter, Hirani terminated the Subcontract. Cf. Second Am. Compl. ¶ 28.
Colonial purportedly approached Plaintiff in June 2013 and asked Plaintiff to complete the Project.
See id. ¶ 20. Plaintiff requested that “its unpaid progress payments on the unchanged base contract
work [be] brought up to date,” but Colonial declined to pay these amounts, and Plaintiff’s work
on the Project ended. See id.
C. The Present Litigation
Plaintiff filed suit in this court on April 29, 2014. See Compl., ECF No. 1 [hereinafter
Compl.]. Neither Plaintiff’s original Complaint nor Plaintiff’s Amended Complaint demanded a
jury trial. See id.; Am. Compl., ECF No. 3 [hereinafter Am. Compl.]. In response to Plaintiff’s
Amended Complaint, Colonial filed four counterclaims. See Def. Colonial’s Answer &
Countercls., ECF No. 8 [hereinafter Colonial’s Answer & Countercls.]. Plaintiff sought leave to
file a Second Amended Complaint on February 12, 2016, which Defendants did not oppose and
the court granted. See Pl.’s Unopposed Mot. for Leave to File Second Am. Compl., ECF No. 25;
Min. Order, Feb. 16, 2016. Plaintiff’s Second Amended Complaint repeated the same two claims
for relief contained in the first two complaints and, for the first time, included a demand for a jury
trial. See Second Am. Compl.
12
Plaintiff’s Second Amended Complaint advances two claims. In Count I, Plaintiff brings
a breach of contract claim against Hirani, which alleges that Hirani breached the Subcontract by
(1) wrongfully refusing to pay Plaintiff amounts due under the Subcontract, (2) delaying Plaintiff’s
performance of its work, and (3) terminating the Subcontract without notice. See id. ¶¶ 26, 28.
Plaintiff seeks to recover the amounts unpaid under the Subcontract, as well as an additional sum
for the “unpaid reasonable value of the services provided by [Plaintiff].” Id. ¶ 21. All told, Plaintiff
seeks $2,070,185.23 in money damages, plus prejudgment interest, attorney’s fees, and costs. Id.
¶ 29. In Count II, Plaintiff asserts a claim under the Miller Act against Colonial, premised on the
payment bond Colonial issued in connection with the Subcontract and in light of Hirani’s failure
to pay. Plaintiff makes the same demand for money damages against Colonial as it does against
Hirani. Id. ¶¶ 31, 35.
Following discovery, Defendants jointly filed a Motion for Summary Judgment and a
Motion to Strike Plaintiff’s Jury Demand. See Defs.’ Mot. for Summ. J.; Defs.’ Mot. to Strike
Jury Demand, ECF No. 45 [hereinafter Defs.’ Mot. to Strike]. Those Motions are now ripe for
review.
II. LEGAL STANDARD
Summary judgment is appropriate “if the movant shows that there is no genuine dispute as
to any material fact and the movant is entitled to judgment as a matter of law.” Fed. R. Civ. P.
56(a). A “genuine dispute” of a “material fact” exists when the fact is “capable of affecting the
substantive outcome of the litigation” and “the evidence is such that a reasonable jury could return
a verdict for the nonmoving party.” Elzeneiny v. District of Columbia, 125 F. Supp. 3d 18, 28
(D.D.C. 2015).
13
In assessing a motion for summary judgment, the court looks at the facts in the light most
favorable to the nonmoving party and draws all justifiable inferences in that party’s favor.
Anderson v. Liberty Lobby, Inc., 477 U.S. 242, 255 (1986). To defeat a motion for summary
judgment, the nonmoving party must put forward “more than mere unsupported allegations or
denials”; its opposition must be “supported by affidavits, declarations, or other competent
evidence, setting forth specific facts showing that there is a genuine issue for trial” and that a
reasonable jury could find in its favor. Elzeneiny, 125 F. Supp. 3d at 28 (citing Fed. R. Civ. P.
56(e)); Celotex Corp. v. Catrett, 477 U.S. 317, 324 (1986)). Evidence that is “merely colorable”
or “not significantly probative” will not defeat a motion for summary judgment. Anderson, 477
U.S. at 249–50.
III. DISCUSSION
Defendants move for an entry of summary judgment in their favor as to both Plaintiff’s
common law claim for breach of contract (Count I) and federal claim under the Miller Act (Count
II). As part of that motion, Colonial also seeks summary judgment on one theory of its
counterclaim for breach of contract—namely, that Plaintiff breached the agreement by failing to
provide work schedules, as required under the Subcontract. Lastly, Defendants move to strike the
demand for a jury trial in Plaintiff’s Second Amended Complaint. 4 The court addresses each
motion in turn.
4
Colonial raised multiple counterclaims in response to Plaintiff’s Amended Complaint, including two counterclaims
for breach of contract. See Colonial’s Answer & Countercls. at 14–15. The only difference between the two breach
of contract counterclaims is that one identifies Hirani as the victim of Plaintiff’s purported breach, with Colonial
seeking to recover as assignee, while the other identifies Colonial as the victim of Plaintiff’s purported breach, with
Colonial seeking to recover as subrogee. See id. For ease of reference in the present discussion, the court refers to
these counterclaims as a single counterclaim for breach of contract.
14
A. Defendants’ Motion for Summary Judgment
The court begins its analysis with the federal question in this case—whether Plaintiff can
recover against Colonial under the Miller Act, 40 U.S.C. § 3133—before turning to Plaintiff’s state
law claim for breach of contract against Hirani and Colonial’s counterclaim for breach of contract. 5
1. Plaintiff’s Claim Against Colonial Under the Miller Act
Plaintiff’s Second Amended Complaint seeks relief against Colonial for Hirani’s failure to
pay for labor, services, and materials Plaintiff furnished to the Project. See Second Am. Compl.
¶¶ 30–35. Defendants submit that Plaintiff’s claim under the Miller Act is time barred because
Plaintiff did not file suit within one year of either the Subcontract being terminated or the last day
on which it supplied labor or materials to the Project. See Defs.’ Mot. for Summ. J. at 10–13.
Alternatively, Defendants contend that Plaintiff’s claim must fail because Plaintiff has only
claimed quantum meruit damages, which Defendants believe are unavailable for a claim under the
Miller Act, thereby making it impossible for Plaintiff to prove “damages.” Id. at 16–17. Plaintiff
proffers that it did timely file suit on April 29, 2014, because the last day it performed the Work
owed under the Subcontract was on May 1, 2013, and the Subcontract was not terminated until
Hirani directed Plaintiff to stop working on May 2, 2013. See Pl.’s Opp’n to Summ. J. at 12–14.
Additionally, Plaintiff submits that quantum meruit damages are available under the Miller Act.
Id. 14–15.
a. When the Statute of Limitations Begins to Run
The Miller Act legally obligates those who contract with the federal government to work
on “any public building or public work of the [f]ederal [g]overnment” to obtain a payment bond
to protect subcontractors who provide the labor and materials necessary to carry out the project.
5
Although each Count only pertains to one Defendant, for ease of discussion, the court refers to the arguments in
favor of summary judgment as belonging to both Defendants.
15
40 U.S.C. § 3131. In the event the general contractor does not pay his subcontractors in full within
90 days of their performance, the Miller Act allows the subcontractor to file suit:
Every person that has furnished labor or material in carrying out
work provided for in a contract for which a payment bond is
furnished under section 3131 of this title and that has not been paid
in full within 90 days after the day on which the person did or
performed the last of the labor or furnished or supplied the material
for which the claim is made may bring a civil action on the payment
bond for the amount unpaid at the time the civil action is brought
and may prosecute the action to final execution and judgment for the
amount due.
Id. § 3133(b)(1). The Act explicitly sets an outer limit on when those suits must be filed: “An
action brought under this subsection must be brought no later than one year after the day on which
the last of the labor was performed or material was supplied by the person bringing the action.”
Id. § 3133(b)(4). When the statute of limitations begins to run on a claim under the Miller Act is
necessarily a fact-intensive inquiry. See Ex parte Sw. Sur. Ins. Co., 247 U.S. 19, 20 (1918).
Neither the Supreme Court nor the D.C. Circuit has interpreted the Miller Act’s accrual provision,
but several other federal circuits and district courts—including courts in this District—have done
so. As a general matter, the federal courts have taken three approaches in determining when the
statute of limitations begins to run on a claim under the Miller Act.
A majority of courts have held that only work performed and materials supplied as part of
the original contract—as opposed to corrective or repair work performed after final inspection and
not provided for in the contract—fall within the meaning of “labor” or “materials” for purposes of
the statute of limitations provision in Section 3133(b). See, e.g., United States ex rel. Interstate
Mech. Contractors, Inc. v. Int’l Fid. Ins. Co., 200 F.3d 456, 459–60 (6th Cir. 2000); United States
ex rel. Magna Masonry, Inc. v. R.T. Woodfield, Inc., 709 F.2d 249, 250–51 (4th Cir. 1983); see
also United States ex rel. Hussmann Corp. v. Fid. & Deposit Co. of Md., 999 F. Supp. 734, 742,
16
744 (D.N.J. 1998) (collecting additional cases); cf. United States ex rel. State Elec. Supply Co. v.
Hesselden Constr. Co., 404 F.2d 774, 776–77 (10th Cir. 1968) (applying this distinction to nearly
identical statutory language in Section 3133(b)(2) to parse when notice is timely given); United
States ex rel. Austin v. W. Elec. Co., 337 F.2d 568, 572–73 (9th Cir. 1964) (same); United States
ex rel. Gen. Elec. Co. v. Gunnar I. Johnson & Son, Inc., 310 F.2d 899, 903 (8th Cir. 1962) (same).
At least two courts in this District have followed that approach. See Highland Renovation Corp.
v. Hanover Ins. Grp., 620 F. Supp. 2d 79, 83–84 (D.D.C. 2009); United States ex rel. Lank
Woodwork Co. v. CSH Contractors, Inc., 452 F. Supp. 922, 924 (D.D.C. 1978).
The “correction-or-repair versus original-contract test” is distinct from the “substantial
completion rule,” under which the statute of limitations begins to run “whenever applicable
contract law would deem substantial completion to have occurred.” Fid. & Deposit Co. of Md.,
999 F. Supp. at 744. Courts applying the substantial completion rule hold that the statute of
limitations continues to run on a subcontractor’s Miller Act claim even “when ‘insubstantial’
subcontract requirements have not yet been completed.” Id.; see, e.g., United States ex rel. T.L.
Wallace Constr., Inc. v. Fireman’s Fund Ins. Co., 790 F. Supp. 680, 684 (S.D. Miss. 1992); see
also Gen. Ins. Co. of Am. v. United States ex rel. Audley Moore & Son, 406 F.2d 442, 443–44 (5th
Cir. 1969).
Lastly, a few courts have applied a multi-factor analysis—considering “the value of the
materials, the original contract specifications, the unexpected nature of the work, and the
importance of the materials to the operation of the system in which they are used”—to determine
if the date on which those materials or labor were provided should be the date when the limitations
period begins to run. See United States ex rel. Ga. Elec. Supply Co. v. United States Fid. &
Guaranty Co., 656 F.2d 993, 995–96 (5th Cir. Unit B Sept. 1981) (articulating this approach for
17
the first time); United States v. Benetech, LLC, No. 12-393, 2013 WL 3984006, at *7 (E.D. La.
Aug. 1, 2013) (discussing the Georgia Electric factors as a test distinct from the substantial
completion rule), aff’d sub nom. United States ex rel. Jems Fabrication, Inc. v. Fid. & Deposit Co.
of Md., 566 F. App’x 298 (5th Cir. 2014); Fid. & Deposit Co. of Md., 999 F. Supp. at 745
(describing and applying the Georgia Electric factors as distinct from the “correction-or-repair
versus original-contract test” or “substantial completion test”); cf. S. Steel Co. v. United Pacific
Ins. Co., 935 F.2d 1201, 1204–05 & n.3 (11th Cir. 1991) (per curiam) (applying the Georgia
Electric factors to interpret the Georgia Little Miller Act).
In the court’s view, the latter two approaches unnecessarily complicate application of the
statute. The statutory text says “performed or . . . supplied,” 40 U.S.C. § 3133(b)(4), not
“substantially performed” or “substantially supplied.” Moreover, Congress did not set out any
factors for the courts to weigh when considering whether the labor or materials a subcontractor
supplies are of the right type to fall within the meaning of the statute. Over the years, courts
following these approaches have embroidered requirements and exceptions onto the text that
simply do not exist on its face. The malady is obvious: the broad remedy Congress provided to
ensure compensation of subcontractors who benefit the public by working on federal projects has
become, in many instances, a subjective line-drawing exercise by judges unfamiliar with the
intricacies and nuances of construction work.
Instead, the court will simply look to the contract to determine for what tasks the parties
agreed the subcontractor would be compensated, then determine the last date on which the
subcontractor supplied materials or labor for one of those tasks. This approach generally aligns
with the one the majority of courts are taking, but avoids the unnecessary distinction between
“corrective or remedial work” and “original contract work” to determine when the statute of
18
limitations begins to run. Cf. United States ex rel. GE Supply v. C & G Enters., Inc., 212 F.3d 14,
17–18 (1st Cir. 2000) (interpreting the Miller Act statute of limitations provision broadly to run
from “the time that the last material was supplied” for the project).
Focusing the analysis on the parties’ contractual agreement, without providing room for
judicially created exceptions, also more closely tracks the text of the statute. Subsection (b)(1)
defines those able to bring suit as “[e]very person that has furnished labor or material in carrying
out work provided for in a contract for which a payment bond is furnished under section 3131,”
40 U.S.C. § 3131, and subsection (b)(4) restricts the timeline for filing those lawsuits to “no later
than one year after the day on which the last of the labor was performed or material was supplied
by the person bringing the action,” id. § 3133(b)(4). By including the phrase “the person bringing
the action” in the statute of limitations provision, the drafters explicitly cross-referenced and
incorporated the earlier provision, tying the two together. The words “labor” and “materials” in
(b)(4) find meaning through reference to (b)(1), which describes those terms in the context of
“work provided for in a contract.” The relevant contract is the subcontract—the contract that
obligated the prime contractor to secure a bond under Section 3131. Therefore, the statute of
limitations begins to run when the subcontractor bringing suit “last” performed labor or supplied
materials for “work provided for” in the subcontract.
In sum, to determine whether a claim is timely brought under the Miller Act, the court need
only (1) identify the compensable tasks to which the parties agreed, as set forth in the subcontract,
and (2) determine the last date on which labor was performed or materials were supplied for any
one of those tasks.
19
b. Whether Plaintiff’s Suit is Timely
Defendants claim Plaintiff’s suit is untimely for either of two reasons. First, Defendants
contend that when the Prime Contract was terminated on April 26, 2013, there was no longer any
work to be performed under the Subcontract because “the only contract that linked [Plaintiff] to
the Project had already been terminated.” Defs.’ Mot. for Summ. J. at 11. In other words,
Defendants believe termination of the Prime Contract automatically terminated the Subcontract
and cut off the possibility of any compensable work as of the date the USACE terminated the
Prime Contract. Accordingly, they conclude, April 26, 2014, was the last day on which Plaintiff
could timely file suit, making the suit Plaintiff filed on April 29, 2014, untimely. See id.
Alternatively, Defendants submit that the last day Plaintiff performed Work, as that term is defined
in the Subcontract, was on March 22, 2013, and the statute of limitations began to run on that day.
Id. at 12–13. For support, Defendants point to the series of e-mails in which Plaintiff advised
Hirani that it was out of productive work in light of monetary constraints. Id. On that theory, the
last day on which Plaintiff could timely file suit was March 22, 2014. See id. Plaintiff counters
that its suit is timely filed because the last day on which it performed Work under the Subcontract
was May 1, 2013—pursuant to Hirani’s explicit instruction to continue working despite
termination of the Prime Contract—and the original Complaint was timely filed on April 29, 2014.
See Pl.’s Opp’n to Summ. J. at 12–14.
The court finds Defendants’ first theory unpersuasive because it misconstrues under which
contract Plaintiff performed. Defendants cite three cases for the proposition that a subcontractor
cannot supply labor or materials in “carrying out work provided for in a contract” when the
subcontract has been terminated by the prime contractor, then simply assert that “[t]he same logic
is true where the prime contract has been terminated.” Defs.’ Mot. for Summ. J. at 11. Not so
20
fast. The subcontractor is only ever “carrying out work provided for in a [sub]contract”—the
document the subcontractor signed. 6 Although the subcontract may incorporate portions of the
prime contract to outline the work to be performed, such references do not convert agreement to
the subcontract into agreement to the prime contract; the subcontractor is only bound by the
subcontract. Attendant federal regulations confirm that the subcontract operates independent of
the prime contract. After receiving notice that the prime contract has been terminated, a prime
contractor is required, among other things, to “[t]erminate all subcontracts related to the terminated
portion of the prime contract.” 48 C.F.R. § 49.104(b). That provision would be superfluous if, as
Defendants posit, the subcontract automatically terminated in response to the prime contract being
terminated. A prime contractor could, in theory, seek to comply with the federal regulation by
including a provision in the subcontract that provides for automatic termination upon termination
of the prime contract, but he or she would need do so expressly. Thus, termination of the prime
contract has no immediate effect on the subcontract unless the subcontract so provides.
Here, the text of the Subcontract confirms that termination of the Prime Contract for default
did not automatically terminate the Subcontract. The Subcontract’s “Termination of Agreement”
provision contemplates two circumstances in which the Subcontract could be terminated: (1) when
Plaintiff defaults by failing to “timely provide labor, services, and/or materials for the Project” in
compliance with the terms of the Subcontract; or (2) when the Government terminates Hirani for
convenience, thereby triggering termination of the Subcontract for convenience. See Subcontract
at 6 (Art. XV, § 15.1). There is neither allegation nor evidence before the court suggesting the
Prime Contract was terminated for convenience; indeed, the USACE’s termination letter expressly
6
This makes intuitive sense: there may be more than one subcontractor contributing to the creation of a federal project
outlined, in whole, in a prime contract—the individual subcontracts define the work to be carried out by each
subcontractor.
21
cites default. See Defs.’ Ex. T. Therefore, the court finds that termination of the Prime Contract
for default on April 26, 2013, had no effect on the Subcontract. The Subcontract had to be
terminated separately, see 48 C.F.R. § 49.104(b), and, prior to its termination, Plaintiff could
continue to carry out Work under the Subcontract, such that the statute of limitations had not
started to run. The court therefore rejects Defendants’ theory that termination of the Prime
Contract on April 26, 2013, caused the Subcontract to terminate and the statute of limitations to
begin running.
Defendants’ second theory identifies the right legal framework for determining when the
statute of limitations began to run on Plaintiff’s Miller Act claim, but there is a genuine dispute as
to whether Plaintiff performed compensable work after April 29, 2013. Plaintiff has put forward
several Quality Control Reports that contemporaneously and specifically document the tasks
Plaintiff performed each day at the Project’s worksite. The Reports for April 29 and April 30,
2013, state that no work took place on those days due to heavy rain. See Pl.’s Ex. J (Quality
Control Reports for April 29 and 30, 2013). The Report for May 1, 2013, reads as follows:
WORK PERFORMED TODAY: All crew members in today;
Today, clean up lumber and WWF fabric mesh up off of East Side
of project; Backfill remaining East Side Grade Beam cutting hole
along curb line at East Side of Project; Remove that covering lumber
and plywood and take to staging yard; Install temporary fence at
construction entrance East Side at end of day; Finish grass cutting
and cleanup of any trash or debris at East Side from construction
operations; West Side take down and disaassemble [sic] MOT
signage from stands; Take signs back to staging yard; Remove MPT
barrels from site today and take to staging yard; Take WWF fabric
mesh from West Side side [sic] [illegible] areas back to staging yard
for storage; Cleanup West Side work area of any possible remaining
minor construction trash from last week work; Move all heavy
equipment from West Side work area to Staging Area today; Clean
up heavy equipment at West Side before move to staging area; also
trailers, etc. . . . . Leave CAT 325CXL and Drill and 10’6” Stick on
West Side until move here this week; Move sanitary toilet to area
where service can pick it up; Buttom [sic] up construction entrances
22
with Orange snow fence for temporary period; Apparently some
walkthrough tomorrow per George Barger; by Noon Time all small
heavy equipment, signage, formwork, lumber, and related items
were into staging yard by [Plaintiff’s] crews; Holes were getting
backfilled; safety fences were going up, and cleanup at site was
occurring by [Plaintiff]; Heavy equipment maintenance and cleanup
and greasing in afternoon;
EXTRA OR ADDITIONAL WORK: Temporary close down of
project site per George Barger per yesterday; Some walkthrough is
tomorrow; Remove MOT devices and equipment and items from
site for now to Stage Area; All extra work today due to termination
if [sic] Hirani; Safety and project close up for safety possibly long
term;
....
REMARKS: . . . . Called Eric Hirani back at 10:45 AM to see why
he called me about 9 times this morning; At opening of phone call
he was a smart ass, [illegible] why I would not drop my other calls;
I told I [sic] do not drop calls, he knew that already; He then wanted
to talk about the stone and other work; I told him that George Barger
had told me this morning that Hirani had gotten fired yesterday; Eric
said they were fighting it and that I was not to stop any work at site;
He said he wanted to be clear about that; Told him only got work
left for about 1 day in any event; Need CO answers on traffic
control, and other items; He started yelling at that point; I then asked
to get off the phone and would not talk to him this way; He then
called back several minutes later asking me what I was going to do
if he can not [sic] get the firing reversed; Told him did not know
here; I asked him what the Surety Company said on this; He siad
[sic] that they have not commented other than to say they will study
the matter; Told of course that [sic] what they say in these matters;
After a few minutes he said that he would get back to me on
continuing to work here, but that I was not to stop working; Told
him needed to answer [sic] in next day or so, so I can plan moving
out if necessary; He acknowledged this[.]
Id. (Quality Control Report for May 1, 2013). This Report raises a genuine issue of material fact
concerning whether Plaintiff performed compensable work under the Subcontract on May 1, 2013.
Schedule B of the Subcontract, which identifies the Work in greater detail, specifically includes:
“Furnish & install all fencing (site, silt, tree protection, temporary) and relocate as per the drawings
and specifications with appropriate signage.” See Subcontract at 1, 9 (Art. I, § 1.3; Sch. B, Pt. 11).
23
At the same time, the Subcontract makes clear that cleaning up the worksite, including removal of
all equipment, is not compensable work and was to be performed at Plaintiff’s own cost. See id.
at 3 (Art. VII, § 7.1). The Report discusses both installation of fencing and removal of equipment
from the worksite, as well as indicates that Plaintiff was performing “extra work” in light of
Hirani’s termination. See Pl.’s Ex. J (Quality Control Report for May 1, 2013). It is unclear to the
court whether Plaintiff’s efforts on May 1, 2013, were solely to clean up the worksite in response
to the phone call with Hirani or whether Plaintiff performed both compensable and non-
compensable work that day. If the latter, then the statute of limitations did not begin to run until
May 1, 2013, making Plaintiff’s lawsuit timely filed on April 29, 2014; if the former, then the
limitations period began to run on some date prior to April 29, 2013, when Plaintiff could not
perform any work due to weather conditions, making Plaintiff’s suit untimely.
In sum, Plaintiff has advanced significantly probative evidence that it performed Work on
the Project after April 29, 2013, and that a reasonable jury could find its suit was timely filed. See
Anderson, 477 U.S. at 249–50; Elzeneiny, 125 F. Supp. 3d at 28. Thus, there is a triable issue of
fact as to the last day on which Plaintiff performed Work on the Project.
c. Whether Plaintiff Can Recover in Quantum Meruit
Lastly, Defendants submit that Plaintiff’s claim fails, even if timely filed, because Plaintiff
cannot recover in quantum meruit for a material breach under the Miller Act, which is the only
theory of relief Plaintiff alleged. See Defs.’ Mot. for Summ. J. at 16. It follows, according to
Defendants, “that [Plaintiff] cannot prove an essential element of its claim against Colonial and
Colonial is entitled to summary judgment.” Id. at 17. Plaintiff contests Defendants’ reading of
the case law and asserts that quantum meruit damages are available against a surety on a Miller
Act claim. See Pl.’s Opp’n to Summ. J. at 14–15.
24
Defendants’ theory misunderstands the text of the statute. To state a claim under the Miller
Act, a plaintiff need only make out two elements: “(1) it has ‘furnished labor or material in carrying
out work provided for in a contract for which a payment bond is furnished under section 3131’;
and (2) it ‘has not been paid in full within 90 days.’” United States ex rel. Tenn. Valley Marble
Holding Co. v. Grunley Constr., 433 F. Supp. 2d 104, 114 (D.D.C. 2006) (quoting 40 U.S.C.
§ 3133(b)(1)). A specific theory of damages is not a necessary element.
Additionally, Defendants’ reading of the case law is mistaken. Although the D.C. Circuit
has not conclusively held that recovery in quantum meruit is available under the Miller Act when
the general contractor breaches the subcontract, several federal appellate courts have done so. See,
e.g., United States ex rel. Bldg. Rentals Corp. v. W. Cas. & Sur. Co., 498 F.2d 335, 337 (9th Cir.
1974); United States ex rel. Coastal Steel Erectors, Inc. v. Algernon Blair, Inc., 479 F.2d 638, 640
(4th Cir. 1973); S. Painting Co. of Tenn. v. United States ex rel. Silver, 222 F.2d 431, 433–34 (10th
Cir. 1955); United States ex rel. Susi Contracting Co., 146 F.2d 606, 610, 612 (2d Cir. 1944). As
discussed below, there remains a genuine issue of material fact concerning whether Hirani
breached the Subcontract, thus squarely placing the facts presented in that category of cases in
which other courts have recognized recovery in quantum meruit to be available. This court
anticipates the D.C. Circuit may adopt its sister Circuits’ reasoning, as it already has recognized at
least one instance in which equitable recovery under the Miller Act is appropriate and, in so doing,
cited for support “cases decided under the Miller Act that allow quantum meruit recovery against
a surety.” See United States ex rel. Heller Elec. Co. v. William F. Klingensmith, Inc., 670 F.2d
1227, 1232–33 (D.C. Cir. 1982) (holding that when the prime contractor has caused delay of the
subcontractor’s performance, “a surety is liable for the value of material and services provided at
the time they were provided,” and citing Western Casualty & Surety Co., 498 F.2d 335, and
25
Algernon Blair, Inc., 479 F.2d 638). Moreover, the Supreme Court has stated on more than one
occasion that the Miller Act “was intended to be highly remedial and should be construed
liberally.” Fleisher Eng’g & Constr. Co. v. United States ex rel. Hallenbeck, 311 U.S. 15, 17–18
(1940); accord United States ex rel. Sherman v. Carter, 353 U.S. 210, 216 (1957); see United
States ex rel. Noland Co. v. Irwin, 316 U.S. 23, 29 (1942). In light of such emphasis on the statute’s
remedial purpose, even were the D.C. Circuit to conclude recovery in quantum meruit is not
available for a Miller Act claim when the general contractor has breached the subcontract, the
court doubts the Circuit would foreclose Plaintiff from recovering altogether simply for failure to
plead the correct theory of recovery. Thus, the court concludes Plaintiff’s claim does not fail as
a matter of law simply because Plaintiff seeks relief in quantum meruit. 7
2. Plaintiff’s Claim Against Hirani for Breach of Contract
Plaintiff also seeks relief against Hirani for breach of contract because Hirani
(1) wrongfully failed to pay Plaintiff amounts due under the Subcontract for Work performed,
causing delay of Plaintiff’s performance; and (2) terminated the Subcontract without notice. See
Second Am. Compl. ¶¶ 26, 28. Plaintiff seeks to recover the reasonable value of its services, which
it submits is $2,070,185.23. See id. ¶ 29; Moldovan Decl. at 101–06 (Ex. U) [hereinafter Pl.’s
Revised Rule 26(a)(2) Discl.], at 2. That sum includes “[t]he reasonable gross profit for heavy and
highway (civil) construction work in the metropolitan DC area during the 2011–2013 time period,”
7
To be clear, the court does not read Plaintiff’s Miller Act claim to seek only quantum meruit damages. True, Plaintiff
seeks “[t]he unpaid reasonable value of the labor, materials and services provided to the Project,” which Plaintiff
asserts is over $2 million. Second Am. Compl. ¶¶ 32–33. As just discussed, to the extent Plaintiff seeks monetary
compensation for work performed beyond what the Subcontract called for, such damages are recoverable under a
theory of quantum meruit. When Plaintiff’s demand is properly understood, however, it also encompasses the unpaid
amounts that Plaintiff claims it is owed for work performed under the Subcontract. See id. ¶ 14 (alleging Plaintiff is
due “$571,447 from Pay Requisition Nos. 19–22, which Hirani and Colonial . . . failed to pay”). Those are contract
damages. Ultimately, the trier of fact will have to decide how to apportion Plaintiff’s claimed Miller Act damages, if
any.
26
when Plaintiff performed Work on the Project, which Plaintiff calculated as 35 percent of direct
costs. Pl.’s Revised Rule 26(a)(2) Discl. at 2, 5.
Defendants move for summary judgment on Plaintiff’s breach of contract claim on the
ground that Plaintiff’s claim fails as a matter of law because recovery in quantum meruit is not
possible when a valid and enforceable contract—like the Subcontract—exists. Instead, Defendants
submit, Plaintiff is bound to the terms of the Subcontract, which sets a fixed price for the Work
and precludes Plaintiff from recovering any amount beyond that fixed price absent Hirani’s written
consent. Thus, because Plaintiff has not submitted any evidence of damages for which the
Subcontract allows recovery, Defendants conclude, Plaintiff cannot prove Hirani breached their
agreement. See Defs.’ Mot. for Summ. J. at 14–15.
To state a claim for breach of contract under District of Columbia law, 8 the moving party
must show (1) a valid contract existed between the parties; (2) the contract created an obligation
or duty; (3) the other party breached that duty; and (4) the moving party was damaged as a result
of the breach. Corp. Sys. Res. v. Wash. Metro. Area Transit Auth., 31 F. Supp. 3d 124, 129 (D.D.C.
2014). As a general matter, the existence of a valid and enforceable contract precludes a plaintiff
from recovering under a theory of unjust enrichment. See Harrington v. Trotman, 983 A.2d 342,
346–48 (D.C. 2009). However, the District of Columbia Court of Appeals has recognized that, in
the narrow circumstance “[w]hen an express contract has been repudiated or materially breached
by the defendant, restitution for the value of the non-breaching party’s performance is available as
8
Both parties assume that District of Columbia law governs claims arising out of the Subcontract, and the court agrees.
The District of Columbia plainly is the jurisdiction with the “most significant relationship” to the dispute. See Shaw
v. Marriott Int’l, Inc., 605 F.3d 1039, 1045 (D.C. Cir. 2010). Plaintiff’s claim concerns a contract for a construction
project located in the District of Columbia, to be performed for a federal government entity headquartered in the
District of Columbia, and the text of the contract directs the parties to the “[c]ourt system in the District of Columbia”
for resolution of at least certain disputes arising under the contract. See Subcontract at 1, 6 (Art. I, § 1.1; Art. XII, §
12.1). Accordingly, Plaintiff’s claim is subject to District of Columbia contract law.
27
an alternative to an action for damages on the contract.” Lee v. Foote, 481 A.2d 484, 485 (D.C.
1984) (per curiam); accord Harrington, 983 A.2d at 346–48; see Shtauber v. Gerson, No. 16-961,
2017 WL 972088, at *6 (D.D.C. Mar. 10, 2017). Consequently, depending on the facts, a non-
breaching plaintiff who is a party to a contract may seek relief for the reasonable value of the
services rendered rather than for contract damages.
The court is unpersuaded that Plaintiff cannot succeed on its breach of contract claim
against Hirani as a matter of law simply because Plaintiff calculates its damages based on the
reasonable value of its services as opposed to the text of the Subcontract. As a preliminary matter,
failure to attach the proper “legal label for the relief sought is not controlling so long as the
complaint complies with [the local civil rule] to put defendant on notice regarding the nature of
the claim.” Lee, 481 A.2d at 487 n.8. Plaintiff’s Second Amended Complaint plainly put
Defendants on notice that it claimed it was damaged by Hirani’s failure to pay for the services and
materials it provided. See Second Am. Compl. ¶¶ 5, 9–10, 13–14, 21, 25–26, 29; cf. Sup. Ct. Civ.
R. 8(a). More importantly, though, the law in the District of Columbia plainly allows for recovery
in quantum meruit, as an alternative to contract damages, when the defendant breached the
contract—precisely the facts Plaintiff alleges. See Lee, 481 A.2d at 487. Here, the Subcontract
both provided for a sum-certain amount to be paid upon the Work’s completion and contemplated
compensating Plaintiff should the amount of Work need to be enlarged. The Subcontract states
that “the sum to be paid by [Hirani] to [Plaintiff] for the satisfactory performance and completion
of the Work and of all of the duties, obligations, and responsibilities of [Plaintiff] under this
Subcontract . . . is $2,845,600.00 . . . subject to additions and deductions as herein provided.”
Subcontract at 2 (Art. III, § 3.1). The agreement also allows Hirani “to make changes, additions,
and/or deletions in the Work as it may deem necessary upon written order,” but only permits
28
Plaintiff to seek additional compensation for extra or additional work “done pursuant to a written
order, signed by the representative designated by [Hirani].” Id. (Art. IV, § 4.1). Plaintiff has
alleged that Hirani materially breached the Subcontract by requiring Plaintiff to perform additional
work but failing to pay Plaintiff for such performance. See Second Am. Compl. ¶ 10. To support
its claim, Plaintiff has presented sworn statements and evidence of payment history that indicate
both an enlargement of the Work performed under the Subcontract and nonpayment for that
performance. See Stephen Decl. ¶ 7; Pls.’ Opp’n Attach. 3 at 28–45 (Ex. A.), at 2; id. at 46–47
(Ex. B). Thus, there remains a genuine dispute as to whether Hirani breached the Subcontract by
withholding from Plaintiff payments owed under the Subcontract either for work expressly
contemplated by the Subcontract or additional work demanded by Hirani. See Elzeneiny, 125 F.
Supp. 3d at 28. On these facts, Plaintiff may seek to recover the reasonable value of its services
and the materials furnished as an alternative to contract damages. See Shtauber, 2017 WL 972088,
at *6.
3. Colonial’s Counterclaim for Breach of Contract
Although Colonial’s counterclaim alleges that Plaintiff breached the Subcontract in no less
than 16 different ways, Colonial seeks summary judgment only as to whether Plaintiff breached
the Subcontract by failing to provide schedules and scheduling information to Hirani during the
Project. See Colonial’s Answer & Countercls. at 14; Defs.’ Mot. for Summ. J. at 17–21. Colonial
complains that Plaintiff’s failure to provide Hirani with the schedules and scheduling information
caused the USACE to terminate the Prime Contract for default, thereby damaging both Hirani and
Colonial. See Colonial’s Answer & Countercls. at 14. For the reasons that follow, the court
concludes there remain triable issues of fact concerning the scope of Plaintiff’s scheduling
responsibilities under the Subcontract and whether Plaintiff fulfilled those responsibilities.
29
Both Colonial and Plaintiff believe the text of the Subcontract answers the question of who
was responsible for the Project’s scheduling. Indeed, each party hangs its hat on the phrase
“scheduling information” in Article II, Section 2.2 of the Subcontract. Colonial contends that that
phrase obligated Plaintiff to oversee all scheduling matters for the Project, and Plaintiff’s failure
to do so constituted a material breach warranting termination of the Subcontract. See Defs.’ Mot.
for Summ. J. at 18; cf. Defs.’ Mot. for Summ. J., Attach. 2, ECF No. 44-2 [hereinafter Hirani
Decl.], ¶¶ 5–7. Plaintiff contends that the Subcontract obligated Plaintiff to provide only
“scheduling information,” which it complied with in full, but the overarching schedule for the
Project was Hirani’s responsibility. See Pl.’s Opp’n to Summ. J. at 15–16.
For ease of discussion, the court groups the relevant portions of the Subcontract, which
read as follows:
[Plaintiff] shall provide the entire scope of work to construct and
manage the 17th Street closure structure except for the Project
Manager and the misc. metal structures/panels as required by Hirani
under the base bid to the USACE and related work required . . . for
the Local Flood Protection Project @ 17th Street Closure Structure
. . . located at 17th Street . . . .
....
The scheduling of all construction operations at the Project,
including the Schedule, shall be as mutually agreed with [Hirani],
and [Plaintiff] shall, if requested, furnish all scheduling information
in such form and detail as requested by [Hirani], to the satisfaction
[of] [Hirani], and [Plaintiff] shall furnish such information within
seven (7) days of request. [Plaintiff] shall also update and/or revise
such information as requested by [Hirani], at any time, either prior
to or during the performance of its Work.
....
In the event [Plaintiff] fails to commence the Work after being
notified in writing to do so, or should [Hirani] judge that [Plaintiff]
is delaying the process of the Work or not complying with the
Schedule, or not pursuing the Work in the manner set forth by the
drawings, specifications or the other Subcontract Documents, or in
30
a thorough and workmanlike manner, [Hirani] shall notify [Plaintiff]
in writing, who shall, within seven (7) calendar days thereafter,
furnish additional materials are required by [Hirani] and employ
additional workmen, equipment and supplies, as required, so as to
bring the Work into conformity with the Schedule or as required by
[Hirani], or be found in material breach and default of this
Subcontract, at the option of [Hirani].
Subcontract at 1–2 (Art. I, § 1.1; Art. II, §§ 2.2, 2.3).
Two things are clear from the plain language of the Subcontract: Plaintiff was obligated
to provide “scheduling information,” “if requested,” and, contrary to Colonial’s argument, Hirani
bore some responsibility for “the Schedule.” The operative sentence in Section 2.2 states: “[t]he
scheduling of all construction operations at the Project, including the Schedule, shall be as
mutually agreed with [Hirani], and [Plaintiff] shall, if requested, furnish all scheduling information
in such form and detail as requested by [Hirani], to the satisfaction of [Hirani] . . . .” Id. (Art. II,
§ 2.2). The parties plainly gave this clause special attention, because the words following “shall
be” and preceding “Hirani” are crossed out and replaced with the handwritten words “as mutually
agreed with.” A natural reading of the clause makes it clear that Plaintiff was not solely responsible
for “the Schedule.” Plaintiff, as the subcontractor, was responsible for providing “scheduling
information” “if requested” by Hirani. Why might Hirani request scheduling information “in such
form and detail as requested by Hirani” and “to the satisfaction of Hirani”? In order to “mutually
agree” to “the Schedule.” Although the Subcontract does not define the term “Schedule,” it likely
includes “[t]he scheduling of all construction operations at the Project.” Thus, a straightforward
reading of the Subcontract provides that Hirani’s assent was required in the scheduling of all
construction operations. Colonial’s suggested reading of the Subcontract—that Plaintiff’s
obligation to provide “scheduling information” means it was responsible for all scheduling of the
Project and that Hirani bore no responsibility for it—bulldozes the clear contractual language.
31
Additionally, Plaintiff has pointed to probative evidence that it was not responsible for
preparing all scheduling matter relating to the Project. First, Plaintiff provided material referenced
by and incorporated into the Subcontract as part of “the Work” for which Plaintiff was responsible,
but which are not part of Defendants’ exhibit—specifically, Section 01 32 01. See Subcontract at
1, 8 (Art. I, § 1.3; Sch. A); Stephen Decl. ¶ 20. That Section states, in part:
3.1 GENERAL REQUIREMENTS
Prepare for approval a Project Schedule, as specified herein,
pursuant to the Contract Clause, SCHEDULE FOR
CONSTRUCTION CONTRACTS. Show in the schedule the
sequence in which the Contractor proposes to perform the work and
dates on which the Contractor contemplates starting and completing
all schedule activities. The scheduling of the entire project,
including the design and construction sequences, is required. The
scheduling of construction is the responsibility of the Contractor.
Contractor management personnel shall actively participate in its
development. SubContractors and suppliers working on the project
shall also contribute in developing and maintain an accurate Project
Schedule. The schedule must be a forward planning as well as a
project monitoring tool.
Pl.’s Opp’n to Summ. J., Attach. 4, ECF No. 46-4, at 69–85 (Ex. N). Although the above-quoted
text talks about the responsibilities of “the Contractor” and “the SubContractor,” by incorporating
this document into the Subcontract as “Work” for which Plaintiff was responsible, see Subcontract
at 1 (Art. I, § 1.3), it is plausible that Plaintiff was to perform all the scheduling responsibilities of
the Contractor and SubContractor in this document. It is equally plausible, though, as Plaintiff
posits, that Hirani was only responsible for those tasks assigned to the SubContractor in this
document—namely, “contribut[ing] in developing and maintain[ing] an accurate Project
Schedule.” See Pl.’s Opp’n to Summ. J. at 16. Clearly, this evidence generates further dispute as
to who was responsible for the Project’s schedule. In light of this ambiguity, the court may
consider evidence beyond the four corners of the Subcontract. See Armenian Assembly of Am.,
32
Inc. v. Cafesjian, 758 F.3d 265, 278 (D.C. Cir. 2014). Plaintiff also provided evidence that Hirani
specifically hired an individual to create an overarching schedule for the Project. See Stephen
Decl. ¶¶ 21–22, 25 (explaining that Hirani hired an outside scheduler, Tom Miller, “to prepare the
overall Project Baseline Schedule”); Pl.’s Opp’n to Summ. J. at 7. That evidence also indicates
Plaintiff was not charged with all scheduling responsibilities.
Lastly, ambiguity surrounding the role of the Project Manager also precludes an entry of
summary judgment in Colonial’s favor on its counterclaim. The Subcontract is silent as to the
scope of the Project Manager’s responsibilities, but plainly calls for an individual other than
Plaintiff to fill the role of Project Manager. Plaintiff was responsible for “the entire scope of work
to construct and manage the 17th Street closure structure except the Project Manager.” Subcontract
at 1 (Art. I, § 1.1) (emphasis added). And, Schedule B expressly obligates Plaintiff to “[p]rovide
project supervision (Superintendent, Site Safety Officer, Traffic Control Officer) except for a
project manager to act on behalf of [Hirani]” and to “work with the Hirani project manager in
submitting monthly requisitions, progress updates, etc.” Id. at 9 (Sch. B, Pts. 2, 5) (emphasis
added). These contractual provisions indicate Hirani may have had ultimate scheduling
responsibility, as the Project Manager was part of its team. Indeed, the record supports that
inference. In certain correspondence, for example, Eric Hirani signs his name as “Project
Manager” but also asserts that others are serving as Project Managers or that Hirani is attempting
to find a Project Manager. See Moldovan Decl. at 20–22 (Ex. D); Defs.’ Ex. E; Defs. Ex. G.
Consequently, the scope of the Project Manager’s duties—i.e., Hirani’s duties—is unclear on the
present record but may have included ultimate responsibility for the Schedule.
In sum, the text of the Subcontract, the additional evidence Plaintiff presents, and the
ambiguity surrounding the role of the Project Manager lead the court to conclude there exists a
33
genuine issue of fact as to who was responsible for “[t]he scheduling of all construction operations
at the Project, including the Schedule,” see Subcontract at 1 (Art. II, § 2.2), and, correlatively,
whether Plaintiff satisfied its contractual obligation.
Even assuming Plaintiff was only responsible for furnishing “scheduling information,” a
genuine dispute of material fact would still exist as to whether Plaintiff satisfied its contractual
obligation. The Subcontract plainly states that Plaintiff would be in breach and the Subcontract
subject to termination if Hirani determined Plaintiff was delaying performance of the Work, which
could reasonably be read to include delaying its provision of “scheduling information” upon
request. See Subcontract at 2 (Art. II, § 2.3). Each party has put forward probative and
contradictory evidence as to whether Plaintiff provided all the “scheduling information” that was
requested. Hirani points to correspondence sent to Plaintiff on February 13, February 18, March
22, and April 2, 2013, in which Hirani repeatedly told Plaintiff that it needed scheduling
information. See Def.’s Mot. for Summ. J. at 19–20; Hirani Decl. ¶¶ 9, 10, 13, 15. Plaintiff submits
that it “provided Hirani with ‘Three Week Look Ahead Schedules’ on a weekly basis throughout
the life of the Project” regarding its own activities, which were incorporated into weekly progress
meetings Plaintiff and Defendants attended. See Stephen Decl. ¶¶ 26. On the record presented,
the court cannot determine whether Plaintiff fulfilled its responsibilities or breached the
Subcontract.
Thus, the court concludes there exist genuine issues of material fact as to (1) whether
Plaintiff was responsible for all scheduling aspects of the Project, and (2) whether Plaintiff satisfied
its contractual obligations.
34
B. Defendants’ Motion to Strike Plaintiff’s Jury Demand
Defendants move to strike the jury demand in Plaintiff’s Second Amended Complaint on
the ground that it was not timely noticed. See Defs.’ Mot. to Strike Jury Demand, ECF No. 45
[hereinafter Defs.’ Mot. to Strike], at 2–3. Defendants acknowledge that they did not oppose
Plaintiff’s motion for leave to file its Second Amended Complaint, but contend that their
acquiescence was predicated on Plaintiff’s misrepresentation that the newly amended pleading did
not contain a jury demand. See id. at 2; Defs.’ Reply in Supp. of Mot. to Strike, ECF No. 52
[hereinafter Defs.’ Reply to Mot. to Strike], at 2. Specifically, Defendants state they were the
victims of a bait-and-switch because Plaintiff gave Defendants a draft version of the Second
Amended Complaint that did not contain a jury demand, sought their approval, and, upon filing
the actual Second Amended Complaint, did not alert them or the court to the new demand for a
jury trial. See Defs.’ Reply to Mot. to Strike at 2.
Plaintiff submits that it properly served Defendants with its jury demand in its Second
Amended Complaint, which Defendants did not oppose, and Defendants should not now be
permitted to revoke their consent. See Pl.’s Opp’n to Defs.’ Mot. to Strike, ECF No. 47 [hereinafter
Pl.’s Opp’n to Mot. to Strike], at 2–3. By consenting to the filing of the Second Amended
Complaint and failing to oppose the jury demand until more than a year later, Plaintiff asserts that
Defendants waived their opportunity to oppose trial by jury. Id.; cf. Defs.’ Reply to Mot. to Strike
at 2 (acknowledging that Defendants did not object to Plaintiff’s jury demand until mid-April
2016).
Under Rule 38 of the Federal Rules of Civil Procedure, a party waives a jury trial unless it
serves its demand on opposing counsel “no later than 14 days after the last pleading directed to the
issue is served” and “fil[es] the demand in accordance with Rule 5(d).” Fed. R. Civ. P. 38(b), (d).
35
Amending a pleading does not “revive a right to jury trial previously waived on the issues already
framed by the original pleadings.” 9 CHARLES WRIGHT & ARTHUR MILLER, FEDERAL PRACTICE
& PROCEDURE § 2320, Westlaw (database updated Apr. 2017); see also Great Socialist People’s
Libyan Arab Jamahiriya v. Miski, 683 F. Supp. 2d 1, 10 (D.D.C. 2010).
The court holds that Plaintiff’s jury demand is untimely. Plaintiff raised the exact same
two claims in each of its three complaints: a claim under the Miller Act against Colonial, and a
claim for breach of contract against Hirani. See Compl.; Am. Compl.; Second Am. Compl. Even
assuming that Colonial’s pleading of counterclaims on June 20, 2014, in response to Plaintiff’s
Amended Complaint extended the time for Plaintiff’s jury demand, cf. Bricks, Blocks & Concrete
Co. v. Frontier Ins. Co., 39 F. App’x 610, 611–12 (D.C. Cir. 2002) (per curiam), Plaintiff would
have had to serve and file its demand no later than July 7, 2014. Plaintiff’s submission of a jury
demand on February 16, 2016, in its Second Amended Complaint—more than 18 months later—
plainly is too late.
IV. CONCLUSION
In light of the foregoing, the court denies Defendants’ Motion for Summary Judgment,
both as to Plaintiff’s claims and Colonial’s counterclaim, and grants Defendants’ Motion to Strike
Plaintiff’s Jury Demand. A separate Order accompanies this Memorandum Opinion.
Dated: June 27, 2017 Amit P. Mehta
United States District Judge
36