Case: 16-20611 Document: 00514094231 Page: 1 Date Filed: 07/28/2017
IN THE UNITED STATES COURT OF APPEALS
FOR THE FIFTH CIRCUIT United States Court of Appeals
Fifth Circuit
FILED
July 28, 2017
No. 16-20611
Lyle W. Cayce
Clerk
MARITES VOCES, Individually and on behalf of the Estate of Peter Jorge
Voces, Deceased, & A/N/F J.V., M.V., M.P.V. and P.V., Minor Children
Plaintiff - Appellant
v.
ENERGY RESOURCE TECHNOLOGY, G.O.M., L.L.C.; TALOS ENERGY,
L.L.C.,
Defendants - Appellees
Appeal from the United States District Court
for the Southern District of Texas
USDC No. 4:14-CV-525
Before KING, PRADO, and SOUTHWICK, Circuit Judges.
PER CURIAM: *
Defendant–Appellee Energy Resource Technology GOM, L.L.C. hired an
independent contractor to remove one of its oil and gas platforms located on
the outer continental shelf off the coast of Louisiana. During the removal,
Peter Voces, a welder employed by the independent contractor, was killed. Mr.
Voces’s wife, Plaintiff–Appellant Marites Voces, individually and on behalf of
* Pursuant to 5TH CIR. R. 47.5, the court has determined that this opinion should not
be published and is not precedent except under the limited circumstances set forth in 5TH
CIR. R. 47.5.4.
Case: 16-20611 Document: 00514094231 Page: 2 Date Filed: 07/28/2017
No. 16-20611
Mr. Voces’s estate and their four minor children, sued Defendants–Appellees,
asserting that they were vicariously liable for the independent contractor’s
negligent acts and independently liable for their own negligent acts. The
district court granted Defendants–Appellees’ motion for summary judgment
and denied Plaintiff–Appellant’s motion for reconsideration. We AFFIRM.
I. FACTS AND PROCEDURE
A. Factual Background
Peter Voces was a welder employed by Offshore Specialty Fabricators,
L.L.C. (OSF), a company specializing in the removal of decommissioned oil and
gas platforms in the Gulf of Mexico. On May 30, 2013, Defendant–Appellee
Energy Resource Technology GOM, L.L.C. (ERT) awarded OSF a contract to
remove ERT’s decommissioned Vermillion 200A oil and gas platform (the
Contract). 1 The Contract was for a lump sum of $4,316,235 and consisted of
several related documents. The Contract provided that OSF would perform all
work as an independent contractor and that OSF was responsible for providing
all necessary services, equipment, materials, personnel, and engineering to
safely remove the Vermillion 200A. Specifically, the Contract provided that
OSF’s duties and responsibilities included (1) establishing written operating
procedures to ensure safe working conditions; (2) performing all work in
accordance with the operating procedures; (3) periodically reviewing the
operating procedures to ensure they reflect actual operating conditions; and
(4) performing work only with personnel trained to do so in a safe manner.
OSF developed its operating procedures for removing the Vermillion
200A (the Work Plan). An ERT company man 2 and an ERT platform engineer
1 ERT is a subsidiary of Defendant–Appellee Talos Energy, L.L.C. (Talos). Plaintiff
does not challenge Talos’s assertions that she sued Talos in name only and has not prosecuted
any cause of action against Talos. Accordingly, this opinion does not separately address the
claims Plaintiff nominally asserted against Talos.
2 A “company man” is an on-site representative of an oil and gas company.
2
Case: 16-20611 Document: 00514094231 Page: 3 Date Filed: 07/28/2017
No. 16-20611
both reviewed the Work Plan, primarily to ensure OSF understood the scope
of the work under the Contract. Under the Work Plan, the first components of
the Vermillion 200A to be removed were two 83-foot flare booms that were
attached to the top of, and extended out over the Gulf of Mexico from, a
cylindrical dry oil tank, known as ABJ-332 tank, which was connected to the
edge of the platform by several rectangular steel pads. After the flare booms
were removed, the Work Plan provided that the ABJ-332 tank would be
removed. The Work Plan, however, expressly provided that its procedures
were “subject to change for offshore environment”; that the OSF’s barge
superintendent would “determine the final procedure based on actual site
requirements”; and that ERT’s company man would “be informed of any
changes.” As the Work Plan suggested, OSF’s barge superintendent was in
charge of all platform removal activities, while the primary role of ERT’s
company man was monitoring OSF’s work for compliance with the Contract.
On the evening of October 26, 2013, OSF’s derrick barge (with ERT’s
company man on board) arrived at the Vermillion 200A to begin the removal
process. Based on the weather forecast, OSF’s barge superintendent decided
to delay heavy lifts, including removal of the flare booms connected to the ABJ-
332 tank, until the weather improved. He then “notified” ERT’s company man
of his intention to delay any heavy lifts as “[p]art of [their] conversation of
talking about the work.” OSF’s barge superintendent nonetheless decided it
was safe to start “prep work” for the Vermillion 200A removal, including
cutting the skid pads connecting the ABJ-332 tank to the platform.
OSF’s crew was divided into two shifts, a day and night shift, to
accomplish the removal prep work. In conducting prep work, it was OSF’s
policy not to cut more than 50% of pad welds connecting heavy equipment to
the platform unless that equipment was hooked up to, and supported by, the
derrick barge’s crane (the 50% Rule). OSF’s welding foremen were responsible
3
Case: 16-20611 Document: 00514094231 Page: 4 Date Filed: 07/28/2017
No. 16-20611
for ensuring the 50% Rule was followed, and OSF’s barge superintendent told
ERT’s company man the 50% Rule would be observed.
The prep work commenced early on October 27. At the mid-day shift
change, the welding foremen for the day and night shifts discussed the prep
work. There is conflicting testimony as to whether they discussed how many
or how much of the pad welds securing the ABJ-332 tank to the platform had
been cut. According to the welding foreman for the day shift, he was not told
that the night shift had already cut on the ABJ-332 tank’s pad welds. After
the shift change, OSF’s welders continued cutting the ABJ-332 tank’s pad
welds. At approximately 4 p.m., several workers heard a loud pop from the
vicinity of the ABJ-332 tank, which one welder attributed to a weld on one side
of the tank breaking. OSF’s welding foreman heard the pop, but did not order
the prep work stopped or notify ERT’s company man about the noise. About
an hour later, Mr. Voces cut the catwalk that connected the ABJ-332 tank to
adjoining equipment. With no pad welds left securing the ABJ-332 tank to the
platform, the ABJ-332 tank rotated off the platform into the Gulf of Mexico,
carrying Mr. Voces with it and resulting in his drowning.
Following Mr. Voces’s death, the Bureau of Safety and Environmental
Enforcement (BSEE) conducted a panel investigation. 3 The panel
recommended that the BSEE consider issuing ERT an “Incident of Non-
Compliance” (INC) for failing to perform operations in a safe and workmanlike
manner, as required by 30 C.F.R. § 250.107(a). 4 Following the panel’s
recommendation, the BSEE issued ERT a Notification of INC under 30 C.F.R.
§ 250.107(a) on November 13, 2014, citing (1) the ERT platform engineer’s
3 The BSEE is the lead agency under the Department of Interior in charge of ensuring
safety and environmental protection for offshore oil and gas production.
4 30 C.F.R. § 250.107(a) provides that a lessee or its designated operator under an
offshore mineral lease “must protect health, safety, property, and the environment by,” inter
alia, “[p]erforming all operations in a safe and workmanlike manner.”
4
Case: 16-20611 Document: 00514094231 Page: 5 Date Filed: 07/28/2017
No. 16-20611
acceptance of OSF’s bid without further engineering verification of the Work
Plan 5 and (2) the failure of ERT’s company man to recognize or question OSF’s
non-compliance with OSF’s safety policies during the prep work, which ERT
understands as a reference to the 50% Rule.
On November 25, ERT responded to the Notification of INC via letter,
asserting that (1) the Work Plan created by OSF was safe and (2) ERT’s
company man did not know and should not have known that OSF was not
following OSF’s safety policies. In part, the letter stated:
As the representative of the operator charged with oversight of
[OSF’s] removal of [the Vermillion 200A], [ERT’s company man’s]
responsibility was to ensure that OSF’s work plan was safe and
that the work plan had been properly communicated to all OSF
employees. The work plan presented to [ERT’s company man] was
safe, as it included a safe plan for the removal of the vent booms
and the inclusion of the 50% cut limit. It is also undisputable that,
as far as [ERT’s company man] could possibly have known, OSF
had properly communicated the work plan to all of its employees,
which OSF confirmed to [ERT’s company man].
ERT’s appeal to the BSEE has not been resolved and no civil penalty has been
issued.
B. Procedural Background
Plaintiff–Appellant Marites Voces, individually and on behalf of Mr.
Voces’s estate and their four minor children (Plaintiff), sued ERT in federal
district court on March 3, 2014, asserting several causes of action under
Louisiana law (as surrogate to federal law under the Outer Continental Shelf
Lands Act). 6 Specifically, Plaintiff claimed ERT was (1) vicariously liable for
5 The platform engineer performed a “very rough” calculation of “weight take off on
the jacket”—the legs that support the Vermillion 200A below the surface—and, based on that
calculation, requested that OSF have an independent structural engineering analysis
conducted.
6 The Outer Continental Shelf Lands Act mandates that when disputes arise involving
fixed structures erected on the outer continental shelf, the applicable laws of the adjacent
state will be applied to the extent not inconsistent with other federal laws and regulations.
5
Case: 16-20611 Document: 00514094231 Page: 6 Date Filed: 07/28/2017
No. 16-20611
the negligence of its contractor, OSF, and (2) independently liable for its own
negligence (i.e., ERT was liable for Mr. Voces’s death due to its breach of
independent duties owed to Mr. Voces). 7
ERT moved for summary judgment as to all claims asserted by Plaintiff.
On February 18, 2016, the district court granted ERT’s motion for summary
judgment on all of Plaintiff’s claims, without directly addressing Plaintiff’s
claim arising from ERT’s alleged independent negligence. Plaintiff timely
moved for reconsideration, arguing that factual issues precluded summary
judgment on both her independent negligence claim and her vicarious liability
claim. The district court denied that motion and supplemented its original
order. Plaintiff timely appeals.
II. STANDARDS OF REVIEW
“We generally review a decision on a motion to alter or amend judgment
under Rule 59(e) for abuse of discretion.” Pioneer Nat. Res. USA, Inc. v. Paper,
Allied Indus., Chem. & Energy Workers Int’l Union Local 4–487, 328 F.3d 818,
820 (5th Cir. 2003). However, the standard of review is de novo where the
ruling seeks reconsideration of a question of law. Id. We likewise review the
grant of summary judgment de novo. Kemp v. Holder, 610 F.3d 231, 234 (5th
Cir. 2010) (per curiam). A party is entitled to summary judgment if “the
movant shows that there is no genuine dispute as to any material fact and the
movant is entitled to judgment as a matter of law.” Fed. R. Civ. P. 56(a). “A
genuine issue of material fact exists if a reasonable jury could enter a verdict
43 U.S.C. § 1333(a)(1); see also Rodrigue v. Aetna Cas. & Sur. Co., 395 U.S. 352, 355 (1969)
(“The [Outer Continental Shelf] Lands Act makes it clear that federal law, supplemented by
state law of the adjacent State, is to be applied to these artificial islands as though they were
federal enclaves in an upland State.”). Thus, Louisiana law applies here.
7 Plaintiffs also asserted that ERT was liable under a theory of strict premises
liability. The district court granted summary judgment on that claim, and Plaintiff does not
challenge that ruling on appeal.
6
Case: 16-20611 Document: 00514094231 Page: 7 Date Filed: 07/28/2017
No. 16-20611
for the non-moving party.” Kemp, 610 F.3d at 234 (quoting Brumfield v.
Hollins, 551 F.3d 322, 326 (5th Cir. 2008) (citation omitted)). We view the facts
and evidence in the light most favorable to the non-moving party. Id.
III. LIABILITY
The Contract provided, and Plaintiff does not dispute, that ERT and OSF
had a principal/independent contractor relationship, as opposed to a
master/servant relationship. “Louisiana law provides the general rule that a
principal is not liable for the negligent acts of an independent contractor acting
pursuant to the contract.” Graham v. Amoco Oil Co., 21 F.3d 643, 645 (5th Cir.
1994). There are exceptions to the general rule against vicarious liability,
however, including when the principal retains or exercises “operational control
over [the independent contractor’s] acts or expressly or impliedly authorizes an
unsafe practice” (the operational control exception). 8 Bartholomew v. CNG
Producing Co., 832 F.2d 326, 329 (5th Cir. 1987). “Further . . . , the principal
remains liable for its own acts of negligence.” Graham, 21 F.3d at 645. Here,
Plaintiff argues that the district court erred in granting summary judgment
8 ERT argues that the express or implied authorization language in this statement of
the operational control exception (and countless others) is merely surplusage. According to
ERT, the express or implied authorization language is rooted in a previous exception for
inherently dangerous activities, which the Louisiana Supreme Court rejected in Kent v. Gulf
States Utilities Co., 418 So. 2d 493 (La. 1982), and this court rejected in Roberts v. Cardinal
Services, Inc., 266 F.3d 368 (5th Cir. 2001). While ERT’s proposed etymology is not without
some support, see Ben Perkowski, Jr., The Employee and the Torts of His Independent
Contractor in Louisiana, 21 Tul. L. Rev. 619, 627 (1947); see also Massey v. Century Ready
Mix. Corp., 552 So. 2d 565, 574–76 (La. Ct. App. 1989); Guillory v. Conoco Inc., 521 So. 2d
1220, 1224 (La. Ct. App. 1988), neither Kent nor Roberts directly addresses, much less rejects,
express or implied authorization of an independent contractor’s negligent act as a viable
means for establishing a principal’s vicarious liability. Indeed, this court (and Louisiana
courts) have consistently looked for express or implied authorization as a means of
establishing such liability, even following both decisions. See, e.g., Davis v. Dynamic Offshore
Res., L.L.C., --- F.3d ---, 2017 WL 1958950, *2 (5th Cir. 2017); Fruge ex rel. Fruge v. Parker
Drilling Co., 337 F.3d 558, 564 (5th Cir. 2003). We are bound by these prior decisions as to
the meaning of Louisiana law. See Welborn v. State Farm Mut. Auto. Ins. Co., 480 F.3d 685,
687 (5th Cir. 2007) (per curiam).
7
Case: 16-20611 Document: 00514094231 Page: 8 Date Filed: 07/28/2017
No. 16-20611
because she raised genuine issues of material fact both as to ERT’s vicarious
liability under the operational control exception and as to its independent
negligence. We address each argument in turn.
A. Vicarious Liability
Plaintiff argues that the district court erred in granting summary
judgment on her vicarious liability claim because she offered evidence raising
genuine issues of material fact regarding both ERT’s operational control over
OSF’s acts and ERT’s express or implied authorization of OSF’s unsafe
practice. We disagree.
1. Operational Control
Determining operational control “depends in great measure upon
whether and to what degree the right to control the work has been
contractually reserved by the principal.” Ainsworth v. Shell Offshore, Inc., 829
F.2d 548, 550 (5th Cir. 1987) (quoting Hemphill v. State Farm Ins. Co., 472 So.
2d 320, 322 (La. Ct. App. 1985)). Whether and to what degree control “is
actually exercised by the principal is less significant.” Id. at 550–51 (quoting
Hemphill, 472 So. 2d at 322). “Operational control exists only if the principal
has direct supervision over the step-by-step process of accomplishing the work
such that the contractor is not entirely free to do the work in his own way.”
Fruge, 337 F.3d at 564.
A principal may demand in its contract that an independent contractor
develop safe work procedures without triggering the operational control
exception. See LeJeune v. Shell Oil Co., 950 F.2d 267, 269–70 (5th Cir. 1992)
(recognizing a contractual clause requiring a contractor to comply with the
owner’s safety rules was insufficient to show operational control). And a
principal may monitor its independent contractor’s work for compliance with
contractual demands without triggering the operational control exception. See
Dauzat v. Thompson Constr. Co., 839 So. 2d 319, 322 (La. Ct. App. 2003)
8
Case: 16-20611 Document: 00514094231 Page: 9 Date Filed: 07/28/2017
No. 16-20611
(“Approving the plans and inspecting for compliance with the specifications
does not establish such control that would result in its liability.”); Nippa v.
Chevron, USA, 774 So. 2d 310, 315 (La. Ct. App. 2000) (“[A principal] is entitled
to supervise its independent contractors to the extent necessary to insure
compliance with the terms of the contract.”). Thus, the mere facts that a
principal takes an interest in the safety of the employees of its independent
contractors and stations a company man on an oil platform do not, in and of
themselves, constitute operational control. See Duplantis v. Shell Offshore,
Inc., 948 F.2d 187, 193 (5th Cir. 1991); Coulter v. Texaco, Inc., 117 F.3d 909,
912 (5th Cir. 1997).
Here, as previously detailed, the Contract expressly vests OSF, not ERT,
with responsibility for developing the procedures to ensure safe working
conditions during the removal of the Vermillion 200A. Further, it expressly
provides that “[OSF] conclusively shall be deemed an independent contractor,
with the authority and right to direct and control all of the details of the Work,
[ERT] being interested only in the result obtained . . . and shall be subject to
[ERT’s] general right of inspection.” The Work Plan similarly provides that
“[t]he [OSF] barge [superintendent] will determine the final procedure [for
removal] based on actual site requirements,” with ERT merely retaining the
right for ERT’s company man to “be informed of any changes.”
Notwithstanding these contractual provisions, Plaintiff points to three
pieces of evidence she asserts show operational control. First, she points to the
deposition testimony of OSF’s barge superintendent, where he purportedly
admitted he needed approval from ERT’s company man in order to make
changes to the Work Plan. However, the barge superintendent’s actual
testimony was that, while he felt it important to discuss procedure with ERT’s
company man, he (not the company man) was in charge of all platform removal
activities and the company man’s primary role was to monitor OSF’s work for
9
Case: 16-20611 Document: 00514094231 Page: 10 Date Filed: 07/28/2017
No. 16-20611
compliance with the Contract. Because the barge superintendent’s testimony
is entirely consistent with OSF acting in the capacity of a true independent
contractor pursuant to the terms of the Contract, it does not raise a genuine
issue of material fact as to OSF’s retention or exercise of operational control.
See Boutwell v. Chevron U.S.A., Inc., 864 F.2d 406, 409 (5th Cir. 1989)
(concluding evidence that principal’s company man discussed the independent
contractor’s work with its representative and informed the representative of
deficiencies in that work did not raise genuine issue of material fact as to
operational control because it was consistent with the contractor acting “in the
capacity of a true independent contractor pursuant to the terms of the
contractual arrangement”).
Second, Plaintiff points to the declaration from an OSF welding foreman,
which conclusorily states that “[t]he final procedures of the operation were
subject to the approval of” ERT’s company man and that ERT’s company man
“was ultimately in charge of the procedures and the entire operation.” The
declaration, however, provides no factual support for these generalizations—
which, if read broadly, would completely contradict the Work Plan attached to
the declaration as an exhibit. Moreover, the declaration does not indicate that
ERT’s company man (or any other ERT representative) detailed how the
removal was to be performed or otherwise prevented OSF from conducting the
removal in its own way, which would be required to show operational control.
See Fruge, 337 F.3d at 564; see also Landry, 889 F.2d at 1471–72 (“[O]nly
instructions designating ‘how to’ conduct operations merit application of the
operational control exception.” (quoting Grammer v. Patterson Servs., Inc., 860
F.2d 639, 639 (5th Cir. 1988))). Accordingly, the declaration’s statements are
insufficient to defeat summary judgment. See Lechuga v. S. Pac. Transp. Co.,
949 F.2d 790, 798 (5th Cir. 1992) (per curiam) (“Conclusory statements in an
affidavit do not provide facts that will counter summary judgment evidence . .
10
Case: 16-20611 Document: 00514094231 Page: 11 Date Filed: 07/28/2017
No. 16-20611
. .”); see also Little v. Liquid Air Corp., 37 F.3d 1069, 1075 (5th Cir. 1994) (en
banc) (per curiam) (recognizing that a non-movant cannot meets its summary
judgment burden with conclusory allegations and unsubstantiated assertions).
Finally, Plaintiff points to ERT’s purported “admission” in its letter to
the BSEE that its company man was responsible for the safety and proper
communication of the Work Plan. Plaintiff misapprehends the import of the
letter. Under the Contract (and in day-to-day practice), OSF, not ERT, was
responsible for ensuring the safety and proper communication of the Work
Plan. The letter makes that clear: “oversight of the performance of the [W]ork
[P]lan, including the prep work, appropriately falls within the responsibilities
of OSF as a specialized contractor with thousands of hours of training and on-
the-job experience related to the equipment and procedures necessary to safely
perform decommissioning work.” Thus, the letter’s summary assertion about
ERT’s company man’s responsibilities is, at most, evidence that the company
man oversaw OSF’s compliance with OSF’s contractual obligations—which
included ensuring the safety and proper communication of the Work Plan.
Such oversight by a company man does not amount to an exercise of
operational control. See Duplantis, 948 F.2d at 193; Coulter, 117 F.3d at 912;
see also Grammer, 860 F.2d at 644 (“It is not enough that [the principal] has
merely a general right to order the work stopped or resumed, to inspect its
progress or to receive reports, to make suggestions or recommendations which
need not necessarily be followed, or to prescribe alterations and deviations.”
(quoting Restatement (Second) of Torts § 414 cmt. c. (1965)) (emphasis
omitted)).
In sum, the competent summary judgment evidence presents no genuine
dispute of material fact as to whether the parties’ conduct was at variance with
the Contract and Work Plan. ERT’s company man never dictated the work
methods or operative details of the removal procedure; rather, the summary
11
Case: 16-20611 Document: 00514094231 Page: 12 Date Filed: 07/28/2017
No. 16-20611
judgment evidence compels the conclusion that he merely inspected OSF’s
procedure and work to ensure OSF’s contractual compliance. Accordingly, the
district court properly concluded that ERT did not exercise operational control.
2. Express or Implied Authorization
“If ‘work is done in an unsafe manner, the [principal] will be liable if he
has expressly or impliedly authorized the particular manner which will render
the work unsafe, and not otherwise.’” See Davis, -- F.3d --, 2017 WL 1958950,
at *2 (alteration in original) (quoting Ewell v. Petro Processors of La., Inc., 364
So. 2d 604, 606–07 (La. Ct. App. 1978)). Thus, “absent an express or implied
order to the contractor to engage in an unsafe work practice leading to an
injury, a principal . . . cannot be liable under the operational control exception.”
Fruge, 337 F.3d at 564 (omission in original) (quoting Coulter, 117 F.3d at 912);
see also Davis, -- F.3d --, 2017 WL 1958950, at *2 (concluding principal’s
company man did not authorize an unsafe working condition that caused
injury to the plaintiff—a personnel-basket transfer to an offshore platform in
high winds—by ordering him to replace crane winch on the platform). Here,
there is no evidence that ERT ordered OSF to engage in any work practice, let
alone an unsafe one that led to an injury.
Citing Williams v. Gervais F. Favrot Co., 499 So. 2d 623, 626 (La. Ct.
App. 1986), Plaintiff argues that ERT’s company man’s participation in the
decision to delay heavy lifts because of the weather is an indicator of
authorization. However, Williams held that a principal was entitled to
summary judgment where the undisputed evidence showed that its company
man did not participate in a decision to engage in a particular work practice.
499 So. 2d at 626. It did not hold that a company man’s mere participation in,
or knowledge of, a decision to engage in a particular work practice was
sufficient to defeat summary judgment. In this case, the evidence showing that
ERT’s company man participated in the decision to delay heavy lifts is
12
Case: 16-20611 Document: 00514094231 Page: 13 Date Filed: 07/28/2017
No. 16-20611
insufficient to defeat summary judgment because that same evidence shows
that OSF’s barge superintendent made the decision to delay heavy lifts and
then discussed the delay with the company man. ERT’s knowledge of OSF’s
plan of action is not the type of authorization contemplated by the operational
control exception. See Cormier v. W & T Offshore, Inc., No. 10-1089, 2013 WL
1567406, at *13 (W.D. La. Apr. 12, 2013). Indeed, it is tantamount to observing
and failing to object to an unsafe work practice, which we have found does not
rise to the level of express or implied authorization. See Graham, 21 F.3d at
646–47 (concluding that company man did not expressly or impliedly authorize
unsafe work condition when he “merely observed” independent contractor’s
employees unsafely performing duties over which the contract gave them sole
responsibility); see also Ainsworth, 829 F.2d at 551 (“Louisiana law will not
support the imposition of liability upon [a principal] for failure to intercede in
[an independent contractor’s] decision to work [in an unsafe manner].”).
Because there is no genuine dispute of material fact as to whether ERT
authorized—either expressly or impliedly—OSF’s unsafe practice that caused
Plaintiff’s injury or as to whether ERT reserved or exercised operational
control over OSF’s work, summary judgment on Plaintiff’s vicarious liability
claim was proper.
B. Independent Negligence
Although we conclude that ERT cannot be held vicariously liable for the
negligent acts of OSF, we must still consider whether ERT can be held liable
for its own negligent acts. See Graham, 21 F.3d at 645. Under Louisiana law,
“[a] principal generally has no duty to take affirmative steps to ensure the
safety of a contractor’s employees, but it may assume such a duty by contract
or by later going beyond the contract and voluntarily policing the worksite for
safety problems.” Ukudi v. McMoran Oil & Gas, L.L.C., 587 F. App’x. 119, 123
(5th Cir. 2014) (per curiam); see also Graham, 21 F.3d at 647–48.
13
Case: 16-20611 Document: 00514094231 Page: 14 Date Filed: 07/28/2017
No. 16-20611
Here, Plaintiff does not argue that ERT had an initial duty to ensure the
Work Plan was safe and properly communicated—whether pursuant to the
Contract, a statute or regulation, or otherwise. Plaintiff nonetheless argues
ERT did voluntarily assume such a duty. However, she fails to explain
precisely how (or why) ERT did so. Under the Contract, OSF—not ERT—had
the duty to ensure the Work Plan was safe and properly communicated and
Plaintiff does not point to any particular extra-contractual conduct by which
ERT purportedly assumed the duty to ensure the Work Plan was safe and
properly communicated. See Graham, 21 F.3d at 648 (discussing extra-
contractual assumption of duty); see also Ukudi, 587 F. App’x at 122 (same).
Instead, Plaintiff places great emphasis on ERT’s purported “admission” in its
letter to the BSEE that its company man was responsible for the safety and
proper communication of the Work Plan. But, as previously discussed, the
letter’s summary assertion about ERT’s company man’s responsibilities is, at
most, evidence that ERT’s company man was responsible for overseeing OSF’s
compliance with OSF’s contractual obligations. Plaintiff has not cited, and we
have not located, any Louisiana authority holding that a principal assumes a
duty to ensure the safety of the independent contractor’s employees by merely
stationing a company man on an oil platform for the purpose of overseeing a
contractor’s compliance with its contractual obligations. See Graham, 21 F.3d
at 648 (“Amoco’s ‘company man’ did not affirmatively assume any duty to
provide Dual’s employees with a safe work place simply by observing their
unsafe work habits.”); see also Davenport v. Amax Nickel, Inc., 569 So. 2d 23,
28 (La. Ct. App. 1990).
But even if ERT did engage in an undertaking to ensure the Work Plan
was safe and properly communicated, as Plaintiff asserts, summary judgment
was still proper. See LeJeune, 950 F.2d at 271 (concluding that, even if the
principal voluntarily undertook an effort to ensure the safety of an
14
Case: 16-20611 Document: 00514094231 Page: 15 Date Filed: 07/28/2017
No. 16-20611
independent contractor’s employees by publishing a safety manual, the
principal was not liable to the plaintiff because the independent contractor and
plaintiff did not act in reliance upon the manual); see also Lazzell v. Booker
Drilling Co., 816 F.2d 196, 198 (5th Cir. 1987). In her briefing, Plaintiff seems
to argue that ERT could be held liable under Louisiana law if it failed to
exercise reasonable care in performing its purportedly voluntary undertaking
to ensure the Work Plan was safe and properly communicated—even if that
undertaking did not increase the risk of harm to Mr. Voces or his injury was
not a consequence of reliance on that undertaking. But, as ERT points out,
each one of the number of cases Plaintiff cites in support of her interpretation
of Louisiana law involved a situation where the defendant’s undertaking did,
in fact, increase the risk of harm or where the plaintiff’s injury was, in fact, the
consequence of reliance on the defendant’s undertaking. See, e.g., Dupre v.
Chevron U.S.A. Inc., 913 F. Supp. 473, 483 (E.D. La. 1996) (granting summary
judgment because the record demonstrated the independent contractor “did
not shirk its safety responsibility in reliance on any action by” the principal),
aff’d, 109 F.3d 230 (5th Cir. 1997) (per curiam).
For instance, Plaintiff cites the Louisiana Supreme Court’s decision in
Harris v. Pizza Hut of Louisiana, Inc., 455 So. 2d 1364 (La. 1984), in support
of her interpretation of Louisiana law. But the Louisiana Supreme Court
expressly rejected Plaintiff’s interpretation of that case:
Pizza Hut does not stand for the proposition that a business
assumes the duty to protect its customers from the criminal acts of
third persons merely because it undertakes some security
measures. Rather, Pizza Hut was an ordinary negligence case,
holding that a security guard employed by a business must
exercise reasonable care for the safety of the business’ patrons and
breaches that duty when his actions cause an escalation in the risk
of harm. In Pizza Hut, the restaurant’s security guard was
negligent because he heightened the risk of harm to Pizza Hut’s
15
Case: 16-20611 Document: 00514094231 Page: 16 Date Filed: 07/28/2017
No. 16-20611
customers by provoking gunfire from armed robbers who had
entered the restaurant.
Posecai v. Wal-Mart Stores, Inc., 752 So. 2d 762, 769 n.7 (La. 1999) (emphasis
added). Plaintiff also unavailingly cites the Louisiana court of appeals’
decision in Moore v. Safeway, Inc., 700 So. 2d 831 (La. Ct. App. 1996). There,
the court of appeals affirmed the jury’s verdict against the principal precisely
because the principal precluded competent supervision by the plaintiff’s
employer by undertaking a duty to direct the prioritization of the independent
contractor’s work. 9 Id. at 847.
Here, unlike the cases Plaintiff cites, there is no evidence of an increase
in risk or reliance to support a claim for independent negligence. Indeed, in
her reply brief, Plaintiff seems to tacitly concede that no such evidence exists,
merely arguing that an increase in risk or reliance is not mandatory. Plaintiff’s
reply brief points to section 324A of the Restatement (Second) of Torts in
support of this assertion. 10 But even if we assume arguendo that Section 324A
9 Similarly, Plaintiff unavailingly cites Crane v. Exxon Corp., U.S.A., 613 So. 2d 214
(La. Ct. App. 1992), where the principal voluntarily policed the wellsite for safety problems
and reprimanded the independent contractor for various safety violations (a situation likely
to engender reliance) and increased the risk of injury to the plaintiff by requiring the hole or
chute into which the plaintiff stepped to be installed. Id. at 218, 221; see also Graham, 613
So. 2d at 221 (discussing Crane); see also, e.g., Maxwell v. Nabors Drilling U.S.A., Inc., No.
98–1339, 1999 WL 460777, at *7–8 (E.D. La. June 29, 1999) (same), aff’d sub nom., Maxwell
v. Nabors Drilling USA, 211 F.3d 594 (5th Cir. 2000) (per curiam).
10 Section 324A provides:
One who undertakes, gratuitously or for consideration, to render services to
another which he should recognize as necessary for the protection of a third
person or his things, is subject to liability to the third person for physical harm
resulting from his failure to exercise reasonable care to protect his
undertaking, if
(a) his failure to exercise reasonable care increases the risk of such
harm, or
(b) he has undertaken to perform a duty owed by the other to the third
person, or
(c) the harm is suffered because of reliance of the other or the third
person upon the undertaking.
16
Case: 16-20611 Document: 00514094231 Page: 17 Date Filed: 07/28/2017
No. 16-20611
governs this case, 11 Plaintiff’s reply brief does not explicitly argue that
subsection (b) of Section 324A is satisfied (subsections (a) and (c) require an
increase in risk and reliance, respectively), much less cite evidence raising a
genuine issue of material fact as to that subsection. As interpreted by the
Louisiana Supreme Court, subsection (b) requires a showing that the
defendant’s undertaking was intended to supplant, not merely supplement, the
duty another owed to the plaintiff. 12 See Bujol v. Entergy Servs., Inc., 922 So.
2d 1113, 1136 (La. 2004), on reh’g, 922 So. 2d 1145, 1148 (La. 2004). In the
absence of any argument or evidence showing that ERT intended to supplant,
not merely supplement, OSF’s duty to ensure the Work Plan was safe and
properly communicated (or an increase in risk as a result of, or reliance on,
ERT’s purported undertaking), summary judgment was, in any event, proper
as to Plaintiff’s independent negligence claim.
IV. CONCLUSION
For the foregoing reasons, the judgment of the district court is
AFFIRMED.
We note that section 43 of the Restatement (Third) of Torts: Liability for Physical and
Emotional Harm (2012) is a more recent version of this provision.
11 It is not clear that section 324A, rather than Section 323, of the Restatement
(Second) of Torts governs this case. Section 323 addresses the liability of one who undertakes
to render services to another for harm to the other (not to a third party) resulting from his or
her failure to exercise reasonable care. See Restatement (Second) of Torts §§ 323 & 324A
cmt. a. Here, Mr. Voces appears to be the person for whom Plaintiff alleges ERT voluntarily
undertook the effort to ensure the safety and proper communication of the Work Plan. Thus,
Section 323 would seemingly apply to require an increase in risk or reliance. See id. § 323.
12 Because Louisiana courts have not yet expressly adopted the Restatement (Third)
of Torts: Liability for Physical and Emotional Harm, see Morvant v. Oil States Int’l, Inc., 3 F.
Supp. 3d 561, 565 n. 17 (E.D. La. 2014), and because Plaintiff does not argue that the
Louisiana Supreme Court would adopt it, we need not, and do not, decide whether the same
result would obtain under section 43 of the Restatement (Third) of Torts: Liability for
Physical and Emotional Harm.
17