ARMED SERVICES BOARD OF CONTRACT APPEALS
Appeal of -- )
)
Black Bear Construction Company ) ASBCA No. 61181
)
Under Contract No. W91B4L-12-C-0185 )
APPEARANCE FOR THE APPELLANT: Mr. Samir
Corporate Officer
APPEARANCES FOR THE GOVERNMENT: Raymond M. Saunders, Esq.
Army Chief Trial Attorney
MAJ Elinor J. Kim, JA
Trial Attorney
OPINION BY ADMINISTRATIVE JUDGE OSTERHOUT
ON THE GOVERNMENT'S MOTION FOR SUMMARY JUDGMENT
This is an appeal of a contracting officer's denial of a claim by Black Bear
Construction Company (Black Bear or appellant), alleging that it is owed $462,160.00
for settlement costs due to a termination for convenience of runway improvement
construction Contract No. W91B4L-12-C-0185 (the contract) through the Kandahar
Regional Contracting Office, Kandahar Air Field, Afghanistan (the government). In
its complaint, Black Bear states that it incurred costs after receiving a notice to
proceed and before the government terminated for convenience. The government filed
a motion for summary judgment requesting that we deny the appeal because Black
Bear waited more than one year to file its settlement proposal as required by the
contract. We agree with the government and deny the appeal.
STATEMENT OFF ACTS (SOF) FOR PURPOSES OF THE MOTION
1. On 18 May 2012, the government awarded the contract to Black Bear for
runway improvement at the forward operating base Spin Boldak in Kandahar
Province, Afghanistan, for $553,150.00 (R4, tab 1).
2. The contract incorporated Federal Acquisition Regulation (FAR) clause
52.249-2, TERMINATION FOR CONVENIENCE OF THE GOVERNMENT (FIXED-PRICE)
(APR 2012)-ALTERNATE I, by reference. Specific to this appeal, the clause included
language about termination settlement proposals:
(e) After termination, the Contractor shall submit a
final termination settlement proposal to the Contracting
Officer in the form and with the certification prescribed by
the Contracting Officer. The Contractor shall submit the
proposal promptly, but not later than I year from the
effective date of termination, unless extended in writing by
the Contracting Officer upon written request of the
Contractor within this I-year period. However, if the
Contracting Officer determines that the facts justify it, a
termination settlement proposal may be received and acted
on after I year or any extension. If the Contractor fails to
submit the proposal within the time allowed, the
Contracting Officer may determine, on the basis of
information available, the amount, if any, due the
Contractor because of the termination and shall pay the
amount determined.
G) The Contractor shall have the right of appeal,
under the Disputes clause, from any determination made
by the Contracting Officer under paragraph ( e ), (g), or (I)
of this clause, except that if the Contractor failed to submit
the termination settlement proposal or request for equitable
adjustment within the time provided in paragraph (e) or (I),
respectively, and failed to request a time extension, there is
no right of appeaI.[11
3. On 28 June 2012, the government issued the notice to proceed and reminded
Black Bear that the period of performance was 90 days, starting on 8 July 2012 (R4, tab 2).
4. On 13 July 2012, the government issued a suspension of work notice (R4, tab 3).
5. On 16 July 2012, the government sent Black Bear a letter terminating the
contract for convenience. The government asked that Black Bear submit its termination
settlement proposal and documentation within 30 days of the notice. (R4, tab 4)
6. On 12 August 2012, the government executed Modification No. POOOOI,
terminating the contract for convenience (R4, tab 6).
1 Paragraph(g) references a situation where the government and contractor do not
agree on the settlement price. Paragraph (1) references partial terminations.
Neither of these paragraphs apply to this appeal.
2
7. On 25 March 2017, Black Bear submitted its claim letter to the contracting
officer. Black Bear requested $462,160.00. (R4, tabs 8, 9; gov't mot., 12; app. resp., 7)
There is no evidence in the record that Black Bear requested a time extension prior to
submitting its claim.
8. On 22 May 2017, the contracting officer issued a final decision, denying the
claim. The contracting officer denied the claim because the parties apparently agreed to a
no-cost termination, Modification No. POOOO 1 contained a release of claims, and Black
Bear did not provide a settlement proposal within 30 days of the termination notice. 2
(R4, tab 14)
9. On 25 May 2017, Black Bear timely appealed the decision to the Board,
which was docketed as ASBCA No. 61181.
DECISION
As an initial matter, "we must satisfy ourselves that we have jurisdiction to
entertain the appeal." Ryste & Ricas, Inc., ASBCA No. 54514, 06-1BCA,33,124 at
164,146, aff'd, Ryste & Ricas, Inc. v. Harvey, 477 F.3d 1337 (Fed. Cir. 2007). In
Ryste & Ricas, appellant certified its proposal as a claim. Black Bear did the same in
this case. As a result, we conclude that we have jurisdiction.
The Court of Appeals for the Federal Circuit has determined that the Board has
jurisdiction over termination settlement appeals where the contractor has failed to
submit a settlement proposal within one year but has filed a certified claim with the
contracting officer. See Ryste & Ricas, 477 F.3d 1337. In Ryste & Ricas, the Federal
Circuit affirmed the Board's decision to grant summary judgment because appellant
failed to submit a termination settlement proposal within one year of the effective date
but submitted it later. Ryste & Ricas, 477 F.3d at 1341. The Federal Circuit explained
why this did not conflict with a prior case, England v. The Swanson Group, Inc., 353
F.3d 1375 (Fed. Cir. 2004), that it remanded and directed the Board to dismiss for lack
of jurisdiction.
In Swanson, the contractor failed to submit anything more than a request for an
extension and never filed a claim or a settlement proposal. Swanson, 353 F.3d at
1380. The Court explained that "[t]he fact that the Board lacked jurisdiction over
Swanson's previous appeal does not, however, bar Swanson from submitting a
2
The contracting officer incorrectly determined that because Black Bear had not
submitted its termination settlement proposal within 30 days, it could not
recover (R4, tab 14). However, the decision remains the same when the
appropriate time period of one year is applied. It is unnecessary for the Board
to consider the other reasons the contracting officer denied the claim.
3
termination settlement proposal to the contracting officer at this time. If Swanson
submits such a proposal now, the contracting officer will be in a position either to
reject it on the ground that it is untimely or to consider it on the merits." Id. If the
contracting officer ruled the newly submitted proposal was untimely or if the
contracting officer denied it, even partially, then Swanson would "have the option of
appealing that decision as a denial of a claim under the CDA." Id.
In Ryste & Ricas, the Federal Circuit explained that the decision did not conflict
with Swanson because "[w ]e held that the Board lacked jurisdiction to entertain
Swanson's appeal from the contracting officer's settlement determination because,
although Swanson submitted a letter requesting an extension of time to file a claim within
the requited one-year period, it failed to present to the contracting officer a 'claim' within
the meaning of the CDA prior to the contracting officer's settlement determination."
Ryste & Ricas, 477 F.3d at 1341-42. In contrast to Swanson, Ryste & Ricas submitted a
termination settlement proposal, but submitted it after the required one-year period.
Ryste & Ricas, 477 F.3d at 1339. The Federal Circuit explained that it was Swanson's
"failure to submit a claim that was the basis for our holding that the Board lacked
jurisdiction over Swanson's appeal." Id. at 1342. In the case at hand, the facts are
similar to Ryste & Ricas-Black Bear submitted a certified claim but did not do so within
the required one-year period. Therefore we have jurisdiction.
It is well settled that summary judgment is appropriate where the moving party
establishes that there are no disputed material facts, and the moving party is entitled to
judgment as a matter oflaw. Riley & Ephriam Constr. Co. v. United States, 408 F.3d
1369, 1371-72 (Fed. Cir. 2005); Mingus Constructors, Inc. v. United States, 812 F.2d
1387, 1390 (Fed. Cir. 1987). When considering summary judgment motions, "the
evidence of the non-moving party is to be believed, and all justifiable inferences are to
be drawn in his favor." Tri-County Contractors, Inc., ASBCA No. 58167, 13 BCA
~ 35,310 at 173,346 (citing FED. R. CIV. P. 56(a); Anderson v. Liberty Lobby, Inc., 477
U.S. 242, 247 (1986)). The parties do not genuinely dispute any of the material facts
set forth in our SOF.
The parties do not dispute that the government notified Black Bear of the
termination in July 2012 and that the effective date of the termination was 12 August 2012
(comp I. ~ 6; gov't mot. ~ 6). The parties also do not dispute that Black Bear did not file its
termination settlement claim until 25 March 2017 (compl. ~ 7; gov't mot.~ 12). Further,
the parties do not dispute that the contract was issued and do not dispute the terms and
conditions of the contract (compl. ii 2; gov't mot. ii 1). As a result, the inclusion of FAR
52.249-2, Alt I, is not contested. Thus, Black Bear was required to submit its termination
settlement proposal within one year of the effective date of the termination, which would
have occurred by 12 August 2013. However, Black Bear waited until 25 March 2017,
over three additional years, before submitting its claim without asking for an extension in
which to file its proposal or claim. (See SOF ~ii 2, 7)
4
Appellant was allowed "1 year from the effective date of termination, unless
extended in writing by the Contracting Officer upon written request of the Contractor
within this I-year period" to file its claim pursuant to FAR 52.249-2(e), Termination
for Convenience of the Government, Alt I. Further, FAR 52.249-20) states "that ifthe
Contractor failed to submit the termination settlement proposal or request for equitable
adjustment within the time provided in paragraph (e) or (1), respectively, and failed to
request a time extension, there is no right of appeal" (see SOF ii 2). Black Bear does
not contest that the claim was not filed until 25 March 2017. Black Bear also does not
claim that it submitted any requests for extension. Black Bear does not provide any
rationale for why its claim was late and simply states that the government is liable for
the costs it incurred. (Compl.; app. resp.) Thus, because Black Bear's termination
settlement claim was late, we must deny the appeal.
CONCLUSION
The government's motion for summary judgment is granted. The appeal is
denied.
Dated: 14 November 2017
Administrative Judge
Armed Services Board
of Contract Appeals
I concur
RICHARD SHACKLEFORD OWEN C. WILSON
Administrative Judge Administrative Judge
Acting Chairman Vice Chairman
Armed Services Board Armed Services Board
of Contract Appeals of Contract Appeals
5
I certify that the foregoing is a true copy of the Opinion and Decision of the
Armed Services Board of Contract Appeals in ASBCA No. 61181, Appeal of Black
Bear Construction Company, rendered in conformance with the Board's Charter.
Dated:
JEFFREY D. GARDIN
Recorder, Armed Services
Board of Contract Appeals
6