BAE Systems Technology v. Republic of Korea's Defense

PUBLISHED

UNITED STATES COURT OF APPEALS
FOR THE FOURTH CIRCUIT

No. 17-1041

BAE SYSTEMS TECHNOLOGY SOLUTION & SERVICES, INC.,

Plaintiff - Appellee,

v.

REPUBLIC OF KOREA’S DEFENSE ACQUISITION PROGRAM
ADMINISTRATION; REPUBLIC OF KOREA,

Defendants - Appellants.

------------------------------

UNITED STATES OF AMERICA,

Amicus Curiae.

No. 17-1070

BAE SYSTEMS TECHNOLOGY SOLUTION & SERVICES, INC.,

Plaintiff - Appellant,

v.

REPUBLIC OF KOREA’S DEFENSE ACQUISITION PROGRAM
ADMINISTRATION; REPUBLIC OF KOREA,

Defendants - Appellees.

------------------------------
UNITED STATES OF AMERICA,

Amicus Curiae.

Appeals from the United States District Court for the District of Maryland, at Greenbelt.
Paul W. Grimm, District Judge. (8:14-cv-03551-PWG)

Argued: October 24, 2017 Decided: March 6, 2018
Amended: March 27, 2018

Before MOTZ, KEENAN, and THACKER, Circuit Judges.

Affirmed by published opinion. Judge Motz wrote the opinion, in which Judge Keenan
and Judge Thacker joined.

ARGUED: Danny Christopher Onorato, SCHERTLER & ONORATO, LLP,
Washington, D.C., for Appellants/Cross-Appellees. Gregory Michael Williams, WILEY
REIN LLP, Washington, D.C., for Appellee/Cross-Appellant. ON BRIEF: Robert J.
Spagnoletti, SCHERTLER & ONORATO, LLP, Washington, D.C.; Jason D. Wallach,
BLANK ROME LLP, Washington, D.C., for Appellants/Cross-Appellees. Richard W.
Smith, Ari S. Meltzer, Katherine C. Campbell, Scott A. Felder, WILEY REIN LLP,
Washington, D.C., for Appellee/Cross-Appellant. Chad A. Readler, Acting Assistant
Attorney General, Sharon Swingle, Benjamin M. Shultz, UNITED STATES
DEPARTMENT OF JUSTICE, Washington, D.C.; Stephen M. Schenning, Acting United
States Attorney, OFFICE OF THE UNITED STATES ATTORNEY, Baltimore,
Maryland, for Amicus Curiae.

2
DIANA GRIBBON MOTZ, Circuit Judge:

These appeals arise from a contract dispute between a United States defense

contractor, BAE Systems Technology Solutions & Services, Inc. (BAE), and the

Republic of Korea and its Defense Acquisition Program Administration (collectively

Korea). BAE sought a declaratory judgment that it had not breached any contractual

obligation to Korea and a permanent injunction barring Korea from prosecuting its suit

against BAE in Korean courts. The district court granted BAE the requested declaration

but refused to issue a permanent anti-suit injunction. Korea appeals, and BAE cross-

appeals. For the reasons that follow, we affirm.

I.

A.

The Arms Export Control Act (AECA), 22 U.S.C. §§ 2751 et seq., authorizes the

Executive Branch to engage in Foreign Military Sales (FMS) transactions when selling

certain U.S. military goods or services to a foreign government. This dispute centers on

such a transaction between the United States and Korea. 1

In an FMS transaction, the foreign sovereign contracts with the U.S. government

through a Letter of Offer and Acceptance. The U.S. government then contracts with a

U.S. contractor for the goods or services that the U.S. government will eventually resell

1
For present purposes, the term “FMS transaction” refers to the purchase by the
U.S. government of goods or services from U.S. contractors and subsequent resale to a
foreign government, as authorized under 22 U.S.C. § 2762(a). Not implicated in this case
are U.S. government sales from existing government stocks authorized under § 2761.

3
to the foreign sovereign. See 28 U.S.C. § 2762. Under the FMS structure, the U.S.

contractor is “directly obligated” to the U.S. government and “has no direct contractual

relationship” with the foreign government. Def. Inst. of Sec. Cooperation Studies, The

Management of Security Cooperation (Green Book) 9-3 (37.1 ed. May 2017). 2 For that

reason, this dual-contract structure precludes the foreign sovereign from directly suing

the U.S. contractor for its performance on an FMS contract. See Sec’y of State for

Defence v. Trimble Nav. Ltd., 484 F.3d 700, 707 (4th Cir. 2007).

The FMS structure also permits the U.S. government to exercise significant

control over the transaction. Once the two sovereigns agree on the terms of sale, the

foreign sovereign must “trust[]” the U.S. government “to negotiate a contract [with a U.S.

contractor] that will meet [the foreign government’s] needs.” Green Book at 15-8. The

U.S. government “determines the contract type, selects the contract source, and

negotiates prices and contract terms with individual contractors.” Id. Importantly here,

in an FMS transaction, the U.S. government retains control over price. Although the

sovereign-to-sovereign agreement contains an initial price estimate, the foreign

government must pay whatever the U.S. government contends the transaction costs —

even if that amount exceeds the previous estimate. See Def. Sec. Cooperation Agency,

2
The Green Book is a textbook published by the Defense Institute of Security
Cooperation Studies (DISCS), a part of the Department of Defense (DoD) that provides
research support to advance U.S. foreign policy through security assistance and
cooperation. “It does not set policy, precedent, or procedures,” but rather “describes
them.” Resources: Publications, DISCS, Def. Sec. Cooperation Agency,
http://www.discs.dsca.mil/_pages/resources/default.aspx?section=publications&type=gre
enbook (last visited February 15, 2018).

4
U.S. Dep’t of Def., Security Assistance Management Manual (SAMM), Fig. C5.F4

§ 4.4.1, http://www.samm.dsca.mil (last visited February 9, 2018). In sum, the FMS

structure provides advantages and disadvantages for a foreign purchaser. One potential

advantage is that, in an FMS transaction, the foreign purchaser benefits from the U.S.

government’s procurement expertise. See Green Book at 15-7, 15-8. One disadvantage,

however, is the loss of control over several aspects of the transaction.

In most instances, a foreign sovereign may choose whether to procure goods and

services through the FMS structure or whether to purchase them directly from the U.S.

contractor through a Direct Commercial Sales (DCS) transaction. For military sales it

deems particularly sensitive, however, the U.S. government requires the use of the FMS

structure. See Trimble, 484 F.3d at 710 (noting the President has discretion to designate

which military items must be sold exclusively through FMS channels); SAMM at

§ C4.3.5 (“The AECA gives the President discretion to designate which military end-

items must be sold exclusively through FMS channels. This discretion is delegated under

statutory authority to the Secretary of State. Generally, as a matter of policy, this

discretion is exercised upon the recommendation of DoD.”). 3

Although in an FMS transaction the foreign government and U.S. contractor do

not contract directly, the foreign sovereign and U.S. contractor may coordinate in

advance of the government-to-government talks in an attempt to pre-determine the

3
“Unless an item has been designated as ‘FMS Only,’ DoD is generally neutral as
to whether a country purchases U.S.-origin defense articles or services commercially [i.e.,
through a DCS transaction] or through FMS channels.” SAMM at § C4.3.4.

5
contents of the eventual government-to-government agreement. Before submitting its

FMS purchase request to the U.S. government, for instance, a foreign sovereign may

negotiate proposed pricing and technical specifications with a favored U.S. contractor

and then urge the U.S. government to provide a sole source award to that contractor

under the pre-negotiated terms. But the U.S. government need not agree to do so.

The dual-contract structure of an FMS transaction has important implications for

resolving legal disputes. The foreign sovereign cannot directly sue the U.S. contractor

for its performance on an FMS contract. Nor can the two sovereigns sue each other for

failure to perform on the government-to-government contract: their only recourse is to

hold bilateral consultations. SAMM at Fig. C5.F4 § 7.2.

B.

In 2011, Korea announced its intention to upgrade its fighter planes. Because this

upgrade program required Korea to obtain sensitive military technology, the U.S.

government barred Korea from purchasing directly from U.S. contractors through a direct

purchase DCS transaction and instead required Korea to procure the desired goods and

services through an FMS transaction.

In preparation for this FMS transaction, Korea solicited bids from U.S. defense

contractors, including BAE, as to the cost of providing the desired upgrades. BAE

responded and issued successive Letters of Guarantee to Korea. In those letters, BAE

agreed to pay Korea $43.25 million if BAE failed to “respond timely to the evaluation

formalities of the bidder’s qualification,” assuming BAE was “designated as an eligible

bidder,” or if BAE failed to execute a contract with Korea after Korea awarded its bid to

6
BAE. BAE issued the first Letter of Guarantee in late 2011; soon thereafter, Korea

selected BAE as its favored contractor for the upgrade program. In the ensuing years,

BAE renewed its Letter of Guarantee several times, including in 2013 and 2014.

Given the dual-contract structure in an FMS transaction, Korea and BAE

attempted to pre-negotiate key aspects of the inter-governmental talks. They agreed on

what Korea would request from the U.S. government and at what price. BAE promised

to “put forth its best effort” to convince the U.S. government to agree to those terms. In

exchange, Korea promised to recommend BAE as its favored contractor to supply the

requested goods and services to the U.S. government.

On August 1, 2012, BAE and Korea memorialized their understandings in a

Memorandum of Agreement. That BAE-Korea agreement authorized Korea to demand

payment of the $43.25 million promised in the Letters of Guarantee if (1) BAE failed to

use its “best effort” to secure the terms specified in the BAE-Korea agreement in the

separate agreement between the U.S. and Korean governments, and (2) BAE’s failure to

use its “best effort” delayed conclusion of the government-to-government negotiations.

The BAE-Korea agreement also contains a forum selection clause, which provides that

any dispute between BAE and Korea “shall be resolved through a litigation and the Seoul

Central Court shall hold jurisdiction.” Finally, the BAE-Korea agreement provides that it

“automatically terminate[s]” upon execution of an FMS agreement between the U.S. and

Korean governments.

Korea then sent its formal purchase request to the U.S. government, initiating the

FMS government-to-government negotiations. In December 2013, the two sovereigns

7
signed an initial FMS agreement that covered preliminary issues and anticipated a

“follow-on amendment” to execute the core of the FMS transaction. With respect to the

anticipated follow-on amendment, the U.S. government initially signaled it could meet

Korea’s budget but later informed Korea that the price tag of the FMS transaction would

greatly exceed initial estimates. BAE, as the contractor chosen to provide the requested

goods and services, had participated in inter-governmental discussions related to price.

After the U.S. government raised its overall price estimate, Korea charged that BAE had

breached the BAE-Korea agreement by failing to use its best efforts to ensure the U.S.

government agreed to the price that Korea and BAE had worked out in advance. BAE

steadfastly denied this, explaining that the U.S. government increased its price for

reasons having nothing to do with BAE and despite its best efforts. Nonetheless, Korea

demanded that BAE pay $43.25 million pursuant to the BAE-Korea agreement.

BAE then filed this action in federal court, seeking a declaration that it had not

breached any obligations to Korea. After the court denied Korea’s motion to dismiss,

Korea answered the complaint and asserted a number of cross-claims against BAE.

Korea also initiated a suit in a Korean court to litigate essentially the same issues. The

district court issued the requested declaratory judgment to BAE but refused to enjoin the

litigation in Korea. This timely appeal followed.

II.

Korea initially grounds its appeal in the forum selection clause contained in the

BAE-Korea agreement. That forum selection clause provides that any dispute arising

8
from or relating to the BAE-Korea agreement “shall be resolved through a litigation and

the Seoul Central District Court shall hold jurisdiction.” Korea claims this is a

mandatory forum selection clause, requiring all litigation to occur in Korea, and thus

requires dismissal of BAE’s suit. BAE maintains that it is permissive, providing that

Seoul, Korea is an appropriate forum for litigation, but not barring litigation elsewhere.

A.

Although the parties agree that we consider this question de novo, and we

traditionally have done so, the more deferential, abuse-of-discretion standard of review

may be appropriate in light of Atlantic Marine Construction Co. v. U.S. District Court,

134 S. Ct. 568 (2013). 4 We need not resolve the correct standard of review here,

however, because the result remains the same under both standards of review.

4
We have treated motions to dismiss based on a forum selection clause as motions
to dismiss for improper venue under Fed. R. Civ. P. 12(b)(3) and reviewed de novo
dismissal of a complaint on the basis of a forum selection clause. See, e.g., Aggarao v.
MOL Ship Mgmt. Co., 675 F.3d 355, 365–66 (4th Cir. 2012). But in Atlantic Marine, the
Supreme Court clarified that a party may not seek to enforce a forum selection clause by
moving to dismiss for improper venue; instead, “the appropriate way to enforce a forum-
selection clause pointing to a . . . foreign forum is through the doctrine of forum non
conveniens.” 134 S. Ct. at 580. In cases not involving forum selection clauses, we have
reviewed dismissals pursuant to the doctrine of forum non conveniens for abuse of
discretion. See, e.g., DiFederico v. Marriott Int’l, Inc., 714 F.3d 796, 799 (4th Cir.
2013). Atlantic Marine thus raises the question of which standard of review applies here
— abuse of discretion (as is typical in forum non conveniens cases), de novo (as is typical
when reviewing dismissals based on forum selection clauses), or some combination of
both. Our sister circuits have taken varying approaches. See Weber v. PACT XPP
Techs., AG, 811 F.3d 758, 768 (5th Cir. 2016) (mixed standard of review); Martinez v.
Bloomberg LP, 740 F.3d 211, 217 (2d Cir. 2014) (not deciding the question).

9
 As a general matter, courts enforce forum selection clauses unless it would be

unreasonable to do so. See M/S Bremen v. Zapata Off-Shore Co., 407 U.S. 1, 15 (1972).

This presumption of enforceability, however, only applies if the forum selection clause is

mandatory rather than permissive. See Albemarle Corp. v. AstraZeneca UK Ltd., 628

F.3d 643, 650–51 (4th Cir. 2010). A mandatory clause requires litigation to occur in a

specified forum; a permissive clause permits litigation to occur in a specified forum but

does not bar litigation elsewhere. Id. A permissive forum selection clause does not

justify dismissal on the grounds that the plaintiff filed suit in a forum other than the one

specified in the clause. See, e.g., Weber v. PACT XPP Techs., AG, 811 F.3d 758, 768

(5th Cir. 2016).

In Atlantic Marine, the Supreme Court held that a defendant seeking to enforce a

forum selection clause that points to a foreign forum should move to dismiss pursuant to

the common-law doctrine of forum non conveniens. See 134 S. Ct. at 580. 5 This doctrine

allows a court to dismiss a case when the original venue is highly inconvenient and an

adequate alternative venue exists. In the typical case, the defendant invoking forum non

conveniens “bears a heavy burden in opposing the plaintiff’s chosen forum.” Sinochem

Int’l Co. v. Malaysia Int’l Shipping Co., 549 U.S. 422, 430 (2007). In particular, the

defendant must prove that an alternative forum is available, adequate, and more

5
Although the Atlantic Marine Court clarified that the “appropriate way” to
enforce such a forum selection clause is through forum non conveniens, it left open the
question of whether a defendant could obtain dismissal under Fed. R. Civ. P. 12(b)(6).
134 S. Ct. at 580 & n.4.

10
convenient (in light of the public and private interests involved) than the forum selected

by the plaintiff. See DiFederico v. Marriott Int’l, Inc., 714 F.3d 796, 800–01 (4th Cir.

2013).

But that framework is modified, the Atlantic Marine Court explained, in the

context of a valid forum selection clause. Most importantly, a forum selection clause

reverses the presumptions that would otherwise apply: instead of heavily favoring the

plaintiff’s chosen forum and placing the burden on the defendant, the forum selection

clause is “given controlling weight in all but the most exceptional cases,” and the plaintiff

bears the burden of proving why it should not be enforced. See 134 S. Ct. at 581, 583 &

n.8 (internal quotation marks and citation omitted). 6 Atlantic Marine thus “reaffirms

Bremen’s identification of a strong federal public policy supporting the enforcement of

forum selection clauses,” even in the context of forum non conveniens analysis. See

Martinez, 740 F.3d at 219.

Although the Atlantic Marine Court did not expressly hold that only a mandatory

forum selection clause modifies the forum non conveniens framework, the Court’s

rationale makes clear that this is so. See 134 S. Ct. at 581–82 (suggesting the modified

6
The forum selection clause in Atlantic Marine pointed to another domestic forum
rather than (as here) a forum abroad. For that reason, the Atlantic Marine Court centered
its analysis on 28 U.S.C. § 1404(a), pursuant to which a district court may transfer a civil
action to another district, and held a valid forum selection clause modified the framework
for considering a § 1404(a) motion to transfer. However, the Atlantic Marine Court
suggested the traditional analysis under both § 1404(a) and forum non conveniens (where
no forum selection clauses are at issue) is similar. See 134 S. Ct. at 581 & n.6. It also
made clear the forum non conveniens framework must be modified in the same manner in
the presence of a forum selection clause. See id. at 583 n.8.

11
framework applies “when a plaintiff agrees by contract to bring suit only in a specified

forum” (emphasis added)); id. at 583 n.8 (modified framework applies “when the plaintiff

has violated a contractual obligation by filing suit in” another forum). Our sister circuits

appear to have reached the same conclusion. See Weber, 811 F.3d at 768, 775–76 (under

Atlantic Marine, a “mandatory” forum selection clause modifies the forum non

conveniens framework that would otherwise apply); GDG Acquisitions, LLC v. Gov’t of

Belize, 749 F.3d 1024, 1029–30 (11th Cir. 2014) (suggesting Atlantic Marine does not

apply in the context of permissive clauses); cf. Claudio-De Leon v. Sistema Universitario

Ana G. Mendez, 775 F.3d 41, 46 (1st Cir. 2014) (noting in a post-Atlantic Marine

decision that “the threshold question in interpreting a forum selection clause is whether

the clause at issue is permissive or mandatory” (internal quotation marks and citation

omitted)); Martinez, 740 F.3d at 216–17, 227 (discussing Atlantic Marine and concluding

that only “mandatory” clauses are presumably enforceable). This conclusion also accords

with the longstanding notion that only mandatory forum selection clauses enjoy a

presumption of enforceability. See Albemarle Corp., 628 F.3d at 650–51.

Accordingly, determination of whether the forum selection clause here is

permissive or mandatory is critical. If it is mandatory, then Atlantic Marine controls and

BAE bears the burden of proving why it should not be enforced. If it is permissive, then

the traditional forum non conveniens analysis applies and Korea bears a “heavy burden”

in opposing BAE’s alternative forum.

12
 B.

A forum selection clause is permissive unless it contains “specific language of

exclusion.” See Albemarle Corp., 628 F.3d at 651 (quoting IntraComm, Inc. v. Bajaj,

492 F.3d 285, 290 (4th Cir. 2007)) (internal quotation marks omitted). “[A]n agreement

conferring jurisdiction in one forum will not be interpreted as excluding jurisdiction” in

another unless the clause expressly sets forth “specific language of exclusion.”

IntraComm, 492 F.3d at 290 (quoting John Boutari & Son, Wines & Spirits, S.A. v. Attiki

Imps. & Distribs., Inc., 22 F.3d 51, 53 (2d Cir. 1994)) (internal quotation marks omitted).

The forum selection clause at issue here does not contain any “specific language

of exclusion.” Id. Rather, it simply confers jurisdiction on a forum by stating that

disputes “shall be resolved through a litigation and the Seoul Central Court shall hold

jurisdiction.” This clause, as the district court noted, differs significantly from forum

selection clauses found to be mandatory, which provide that a particular place constitutes

the “sole” or “only” or “exclusive” forum.

Contrary to Korea’s suggestion, the use of “shall” in the clause does not render it

mandatory. As we explained in IntraComm, the use of “shall” in a forum selection clause

is not dispositive, because, in context, the clause may still “permit[] jurisdiction in one

court but . . . not prohibit jurisdiction in another.” Id. (discussing Excell, Inc. v. Sterling

Boiler & Mech., Inc., 106 F.3d 318, 321 (10th Cir. 1997)). Nor does holding the clause

permissive render it, as Korea suggests, “meaningless and redundant.” Appellant’s

Opening Br. at 30. Korea contends this is so because the BAE-Korea agreement “could

always be enforced in the Korean courts.” Id. at 29–30. But Korea fails to explain why

13
the Seoul Central District Court in particular would necessarily hold jurisdiction absent

this clause. 7

Because the clause here is permissive, the modified framework outlined in Atlantic

Marine does not apply, there is no presumption in favor of enforceability, and we proceed

with a traditional forum non conveniens analysis. Pursuant to that analysis, Korea bears

the burden of proving, inter alia, that its proposed alternative forum (the Seoul Central

District Court) is more convenient in light of the public and private interests involved.

See DiFederico, 714 F.3d at 800–01. Korea does not even attempt to do this.

Accordingly, we agree with the district court that the BAE-Korea agreement’s permissive

forum selection clause provides no basis for dismissing this action.

III.

Korea also contends that the district court erred in refusing to accord it immunity

from suit under the Foreign Sovereign Immunities Act, 28 U.S.C. §§ 1602 et seq. (FSIA).

That statute provides that “a foreign state shall be immune from the jurisdiction of the

7
Korea’s heavy reliance on Sterling Forest Assocs. v. Barnett-Range Corp., 840
F.2d 249 (4th Cir. 1988), overruled on other grounds by Lauro Lines S.R.L. v. Chasser,
490 U.S. 495 (1989), is misplaced. In that case, we found mandatory a very different
clause that stated, “the parties agree that in any dispute jurisdiction and venue shall be in
California.” Id. at 250–52 (emphasis added). As other circuits have explained, “where
venue is specified with mandatory or obligatory language, the clause will be enforced;
where only jurisdiction is specified, the clause will generally not be enforced unless there
is some further language indicating the parties’ intent to make venue exclusive.” Paper
Express, Ltd. v. Pfankuch Maschinen GmbH, 972 F.2d 753, 757 (7th Cir. 1992); accord
K & V Sci. Co. v. BMW, 314 F.3d 494, 499 (10th Cir. 2002).

14
courts of the United States” unless one of the enumerated exceptions applies. 8 28 U.S.C.

§ 1604. BAE maintains that the district court properly exercised jurisdiction, because

two FSIA exceptions apply here: the waiver exception and the commercial activity

exception. We review applications of the FSIA de novo. Wye Oak Tech., Inc. v.

Republic of Iraq, 666 F.3d 205, 212 (4th Cir. 2011).

The FSIA waiver exception states:

A foreign state shall not be immune from the jurisdiction of
courts of the United States . . . in any case . . . in which the
foreign state has waived its immunity either explicitly or by
implication, notwithstanding any withdrawal of the waiver
which the foreign state may purport to effect except in
accordance with the terms of the waiver . . . .

28 U.S.C. § 1605(a)(1) (emphasis added).

“Waiver under the FSIA is rarely accomplished by implication,” and “the implicit

waiver provision of § 1605(a)(1) must be construed narrowly.” See In re Tamimi, 176

F.3d 274, 278 (4th Cir. 1999). In enacting the FSIA, however, Congress provided three

examples of implicit waivers. See H.R. Rep. No. 94-1487, at 18 (1976), as reprinted in

1976 U.S.C.C.A.N. 6604, 6617; S. Rep. No. 94-1310, at 17–18 (1976). These three

examples “involve circumstances in which the implicit waiver is unmistakable” and so

the FSIA exception applies. See Tamimi, 176 F.3d at 278–79. One of these unmistakable

8
The parties do not dispute that both the Republic of Korea and its Defense
Acquisition Program Administration (its instrumentality) are “foreign states” within the
meaning of the FSIA. We agree. See 28 U.S.C. § 1603 (defining “foreign state” under
the FSIA).

15
implicit waivers occurs when “a foreign state has filed a responsive pleading in a case

without raising the defense of sovereign immunity.” Id. at 278.

BAE initiated this lawsuit against Korea in November 2014. Korea moved to

dismiss the action in September 2015 but did not raise the sovereign immunity defense in

that motion. On February 18, 2016, after the district court denied Korea’s motion to

dismiss, Korea filed an answer to BAE’s complaint and several counter-claims against

BAE. This was Korea’s first responsive pleading. See Fed. R. Civ. P. 7 (an answer to a

complaint is a “pleading,” but a motion to dismiss is not); 28 U.S.C. § 1608(d) (outlining

timeline under FSIA for a foreign state to file “an answer or other responsive pleading”).

In this initial pleading, Korea failed to assert sovereign immunity but instead asserted

counter-claims against BAE for breach of contract, fraud, and negligent

misrepresentation. In sum, by February 18, 2016, this litigation had been ongoing for

over a year, Korea had not asserted a sovereign immunity defense, and Korea had filed a

responsive pleading in the form of an answer and counter-claims. It thus appears that

Korea impliedly waived its sovereign immunity defense.

Resisting this conclusion, Korea notes that it filed an amended answer and

counter-claims on March 10, 2016, in which it did refer to FSIA. Korea added the

following sentence in its amended answer and counter-claims:

Moreover, Defendants deny that the act upon which BAE
TSS bases its claim — Defendants’ demand for payment of
the amount of the bid bond required by Korean law — falls
within the commercial activities exception of the Foreign
Sovereign Immunities Act.

16
Although it referred to the FSIA in this amended answer and counter-claims, even then

Korea did not raise the FSIA as an affirmative defense. Rather, Korea simply denied

engaging in commercial activity under the FSIA.

Even assuming this statement in the amended answer sufficed to invoke FSIA

protections, Korea cannot defeat a holding of implied waiver unless its amended answer

and counter-claims rendered its initial answer and counter-claims irrelevant. Korea

contends that this is the case, because an amended pleading generally supersedes the

original, rendering the original of no legal effect. See Appellants/Cross-Appellees

Response/Reply Br. at 32–33 (citing Young v. City of Mount Ranier, 238 F.3d 567, 572

(4th Cir. 2001)). Regardless of the ordinary effect of an amended answer on the original

answer, a court cannot ignore the original answer for FSIA waiver purposes.

Korea’s proposed interpretation — that only the latest amended answer matters for

purposes of asserting sovereign immunity under FSIA — stands in tension with the

statutory text, which states that a foreign state cannot withdraw an implied waiver once it

is made. See 28 U.S.C. § 1605(a)(1); see also Flota Maritima Browning de Cuba, S.A. v.

Motor Vessel Ciudad de la Habana, 335 F.2d 619, 621, 625 (4th Cir. 1964) (in pre-FSIA

case, finding that Cuba waived its immunity “when it filed answers . . . without

suggesting its immunity,” because “once the immunity is waived . . . it cannot be

revived”). Korea’s interpretation could lead to absurd results, where a foreign state could

avoid implied waiver simply by obtaining permission from a court to file an amended

pleading.

17
 We reject such an interpretation. Instead, we hold, as our sister circuits have, that

filing a responsive pleading generally provides the last opportunity to assert sovereign

immunity. See Haven v. Polska, 215 F.3d 727, 731 (7th Cir. 2000) (“If a sovereign files

a responsive pleading without raising the defense of sovereign immunity, then the

immunity defense is waived.”); Drexel Burnham Lambert Grp. Inc. v. Comm. of

Receivers for Galadari, 12 F.3d 317, 326 (2d Cir. 1993) (“[T]he filing of a responsive

pleading is the last chance to assert FSIA immunity if the defense has not been

previously asserted.”); Canadian Overseas Ores Ltd. v. Compania de Acero del Pacifico

S.A., 727 F.2d 274, 277 (2d Cir. 1984) (describing a responsive pleading as “the point of

no return for asserting foreign sovereign immunity”); cf. Princz v. Republic of Germany,

26 F.3d 1166, 1174 (D.C. Cir. 1994) (“[A]n implied waiver depends upon the foreign

government’s having at some point indicated its amenability to suit.” (emphasis added)). 9

Here, Korea participated in the litigation for over a year, including by filing a

motion to dismiss and a responsive pleading, without giving any indication it asserted

sovereign immunity. For that reason, it waived its immunity defense, and the district

court had jurisdiction. The fact that Korea never “raise[d] the defense of sovereign

9
In an earlier case, the D.C. Circuit rejected claims of implicit waiver when Iran
failed to assert immunity in its initial answer but then asserted immunity in a subsequent
answer. See Foremost-McKesson, Inc. v. Islamic Republic of Iran, 905 F.2d 438, 442–44
(D.C. Cir. 1990). However, the court stressed the unusual nature of that case, where the
first answer did not respond substantively to the complaint but rather noted the complaint
must proceed in another forum, which it then did. See id. at 443.

18
immunity,” even in its amended answer and counter-claims, but rather only asserted its

actions did not qualify for the commercial activity exception, supports this conclusion. 10

IV.

Although Korea largely relies on its forum selection clause and immunity

arguments, it also challenges on the merits the grant of summary judgment to BAE. The

district court concluded that Korea had no cause of action for an asserted breach of the

BAE-Korea agreement. We review the district court’s grant of summary judgment de

novo. Aikens v. Ingram, 811 F.3d 643, 647 (4th Cir. 2016).

A.

We briefly recap the undisputed facts underlying this claim. When Korea sought

to upgrade the avionics systems of its fleet of fighter planes, the United States insisted

that this upgrade could only occur through an FMS transaction, in which the U.S.

government retained control over price. Perhaps in recognition of the U.S. government’s

complete control over the FMS contract, Korea attempted to pre-determine its costs. To

that end, Korea entered into an agreement with BAE in which, in exchange for being

named as Korea’s preferred contractor, BAE agreed to put forth its “best effort” to ensure

the pricing to which BAE and Korea had agreed was accepted by the United States and

included in the agreement between the two governments. Although the United States and

Korea entered into a preliminary FMS contract, negotiations between them ultimately

10
Because we agree with BAE that the waiver exception applies, we do not
consider the commercial activity exception.

19
collapsed due to price differences. Korea claims that BAE did not use its best efforts to

ensure the U.S. government agreed to the price that BAE and Korea had worked out in

advance. BAE maintains that the U.S. government increased its cost estimate based on

“historical experience” with “previous F-16 upgrade programs” and that “no part of this

cost increase was the result of [BAE’s] actions.” Appellee/Cross-Appellant’s

Response/Opening Br. at 15. The principal issue for declaratory judgment purposes,

however, is not whether BAE failed to use its best efforts to advocate for a certain price,

but rather whether Korea can enforce its agreement with BAE (including this “best

effort” obligation) in light of U.S. national security interests.

We agree with the parties that this question turns on the relationship between the

BAE-Korea agreement and the FMS transaction and whether enforcement of the BAE-

Korea agreement would impact U.S. national security interests. Korea claims that the

BAE-Korea agreement relates to, but is entirely distinct from, the FMS transaction.

According to Korea, its agreement with BAE imposes obligations on BAE and Korea that

have “no impact on the U.S. government or its national security.” Appellant’s Opening

Br. at 49. BAE maintains that because the BAE-Korea agreement is intimately linked to

the government-to-government transaction and purports to influence its outcome, it

impacts U.S. national security and so is unenforceable. Appellee/Cross-Appellant’s

Response/Opening Br. at 28.

In Trimble, we explained that, where the U.S. government mandates use of the

FMS format (as opposed to a direct purchase by a foreign government from a U.S.

contractor via the DCS process), that requirement “reflects the national security interests

20
of the United States.” 484 F.3d at 707. We reasoned that a foreign state will not be

permitted “to gain an advantage of the DCS program in a situation where United States

policy (and the statutory scheme chosen to effectuate that policy) explicitly precludes a

DCS arrangement.” See id. We thus concluded that a foreign state participating in an

FMS transaction cannot sue the U.S. contractor under the theory that the foreign state is a

third-party beneficiary of the contract between the U.S. government and the U.S.

contractor. Recognizing such a cause of action “would allow the foreign purchaser to

hold the contractor directly liable for the purchased goods, a level of accountability that

may be achieved [only] through a DCS sale.” Id.

In sum, Trimble teaches that a foreign state cannot sue a U.S. contractor if doing

so would undermine the FMS structure and afford the foreign state advantages only

available in a direct purchase DCS transaction between a foreign state and a U.S.

contractor.

The district court concluded that Korea’s lawsuit would do just that. The court

reasoned that the BAE-Korea agreement is “inextricably intertwined” with the FMS

transaction. In reaching this conclusion, it relied on the fact that the explicit purpose of

the BAE-Korea agreement was to establish the technical specifications and prices that

BAE would then support for inclusion in Korea’s eventual FMS agreement with the U.S.

government. If BAE failed to adequately advocate for inclusion of those terms in an

inter-governmental deal, and that failure delayed conclusion of such a deal, the BAE-

Korea agreement subjected BAE to “punishment” in the form of a $43.25 million

payment. And, as the district court noted, the BAE-Korea agreement “automatically

21
terminate[d]” once the two governments reached an FMS agreement. Given these facts,

we agree that the BAE-Korea agreement is intimately linked to the FMS transaction: in

essence, it subjects BAE to potential liability if Korea is dissatisfied with developments

in the government-to-government FMS negotiations.

B.

If enforced as Korea seeks, the BAE-Korea agreement would undermine the FMS

structure in two critical ways. First, it would undermine the FMS dispute settlement

provisions. The FMS structure strictly circumscribes the availability of litigation. A

foreign state cannot sue the United States for failure to perform pursuant to the sovereign-

to-sovereign agreement, including with respect to price. The foreign state’s only recourse

is to consult with the U.S. government. See SAMM Fig. C5.F4 § 7.2. Nor can a foreign

state sue the U.S. contractor retained by the U.S. government to fulfill an FMS contract,

because the foreign state does not contract directly with that contractor for the goods and

services the contractor ultimately supplies (via the U.S. government) to the foreign state.

See Trimble, 484 F.3d at 707. The FMS structure thus shields a U.S. contractor, such as

BAE, from liability. Pursuant to the separate BAE-Korea agreement, Korea nonetheless

seeks to impose liability on BAE for allegedly failing to use best efforts to prevent a price

increase by the U.S. government in FMS government-to-government negotiations.

Permitting Korea to impose such liability would run counter to the FMS structure.

Second, enforcement of the BAE-Korea agreement would undermine the control

the United States retains in all FMS transactions over price. Under federal law, the

foreign state must pay whatever it costs the U.S. government to supply the requested

22
goods or services. See 22 U.S.C. § 2762(a) (authorizing President to engage in FMS

transactions if the foreign government agrees “to pay the full amount of such contract

which will assure the United States Government against any loss on the contract”); see

also SAMM § C9.3.1 (noting that, subject to certain exceptions identified in the AECA,

“[t]he FMS program must be managed at no cost to the [U.S. government]”).

Relatedly, in an FMS transaction, the U.S. government also retains control over

negotiations with the U.S. contractor, including with respect to price. See Defense

Federal Acquisition Regulations Supplement (DFARS), 48 C.F.R. §§ 1–99, 200–299,

225.7303(a) (The U.S. government “[p]rice[s] FMS contracts”). The United States even

decides whether and to what extent the foreign sovereign participates in negotiations with

the U.S. contractor. See id. § 225.7304(d) (noting that, as a general matter, “the degree of

[foreign government] participation in contract negotiations [with the U.S. contractor] is

left to the discretion of the [U.S. government]”). Applicable regulations outline all that is

required of the U.S. government in responding to objections of a foreign sovereign to

prices demanded by the U.S. contractor. See id. § 225.7304(h) (“If [a foreign

government] requests additional data concerning FMS contract prices,” the U.S.

government shall “provide sufficient data to demonstrate the reasonableness of the price,”

which may include “an explanation of any significant differences between the actual

contract price and the estimated contract price included in the initial” government-to-

government deal).

Because the U.S. government retains control over price in an FMS transaction, a

foreign state generally has no cause of action — against anyone — if the price demanded

23
by the U.S. government increases over time. If a foreign state does not wish to abide by

this limitation, it need not, and should not, enter into an FMS transaction. 11

Moreover, enforcement of the BAE-Korea agreement here would subvert the FMS

structure and congressional directives as to all FMS transactions. It would provide a

foreign state with a cause of action against a U.S. contractor if the price of the FMS

transaction exceeded initial expectations, because the foreign state could always claim the

U.S. contractor did not use its best efforts to keep prices down. Thus, although

enforcement of the BAE-Korea agreement as Korea seeks would not “control” the FMS

transaction price in a strict sense (i.e., it would not dictate what the U.S. government

ultimately charges Korea, nor would it dictate what BAE charges the U.S. government),

it would nevertheless allow a foreign state to recover from a U.S. contractor if the cost of

the FMS transaction exceeded initial estimates. Accordingly, it would import a benefit

available only in a direct purchase, DCS transaction, into an FMS transaction. In a DCS

transaction, the foreign state may negotiate a fixed price with the U.S. contractor, such

11
We are also unpersuaded by Korea’s argument that the BAE-Korea agreement is
akin to an offset arrangement and is thus enforceable. In an FMS transaction, the foreign
state and U.S. contractor may negotiate offsets, which are “the entire range of industrial
and commercial benefits provided [by contractors] to foreign governments as an
inducement or condition to purchase military supplies or services.” DFARS Procedures,
Guidance, and Information 225.7303-2 (May 2015),
https://www.acq.osd.mil/DPAP/dars/dfarspgi/current/index.html (last visited March 5,
2018). Korea claims that offsets are enforceable and that the BAE-Korea agreement is
“similar to an offset agreement” in that it is “an ancillary contract between the foreign
purchaser and the contractor related to an FMS transaction.” Appellant’s Opening Br. 52
n.10. Even if offsets are enforceable, we view them as distinct. Offsets, unlike the BAE-
Korea agreement, do not undermine the FMS structure. Instead, offsets are mere
inducements offered by U.S. contractors to the foreign state to convince the foreign state
to purchase military goods and services in the first place.

24
that it knows how much money it will owe. In an FMS transaction, by contrast, a foreign

government that objects to price increases may only consult with the U.S. government or

withdraw from the transaction.

C.

In its Amicus brief — which supported neither party on the issue of whether the

BAE-Korea agreement is enforceable — the United States suggests that “Korea is not

seeking to reorder the FMS statutory structure.” Br. for the United States as Amicus

Curiae at 6. Partly for that reason, it concludes that national security concerns “do not

prohibit enforcement of the [best efforts] provision at issue here.” Id. at 1–2, 6. 12

As an initial matter, the Government’s mere assertion that “Korea is not seeking to

reorder the FMS statutory structure” is overly simplistic. Under Trimble, we focus on

whether enforcement of the BAE-Korea agreement would undermine the FMS structure

established by Congress. The Government’s brief does not meaningfully engage with

this issue: it fails to even mention the statute authorizing FMS transactions (AECA), the

12
The United States did not participate in this case in the district court or in the
oral argument or original briefing in this court. However, after oral argument, we invited
the Government to provide a brief setting forth its views on two questions. First, we
asked the Government to address an issue in Korea’s appeal (Fourth Circuit No. 17-
1041): whether, in the Government’s view, permitting Korea to enforce its agreement
with BAE would “run counter to United States national security interests.” Second, we
solicited the Government’s view on the issue pursued by BAE in its cross-appeal (Fourth
Circuit No. 17-1070): whether a permanent anti-suit injunction “is warranted in light of
any United States national security interests.”

25
regulations governing such transactions (DFARS), the key manual with which FMS

transactions must comply (SAMM), or the standard terms used in FMS agreements. 13

The Government also suggests that enforcement would not undermine the FMS

structure, because Korea seeks compensation “only for BAE’s own alleged failure to use

best efforts,” and “is not here reneging on a commitment to settle disputes with the

United States using government-to-government negotiation.” Amicus Br. at 6.

Functionally, however, Korea does precisely this — it seeks to hold BAE liable for

higher prices demanded by the United States in the government-to-government

negotiation. The record makes this connection plain: one day after the U.S. government

announced a price increase, Korea demanded payment from BAE.

Finally, although we take seriously the Government’s views, we note that the

Government in its brief only concludes national security interests do not prohibit

enforcement of the “best effort” provision in the particular agreement and circumstances

presented here. The same might not be true, the Government suggests, the next time

around. See Amicus Br. at 1–2, 5 n.2. This provides no guidance to industry actors and

suggests that courts must consider the distinct national security implications of each and

13
Instead, the Government’s effort to distinguish Trimble rests entirely on factual
differences between Trimble and the case at hand. These factual differences are certainly
relevant. But even more important and more relevant here are concerns at the center of
the Trimble holding that the foreign government’s lawsuit runs counter to the statutory
and regulatory structure underpinning FMS transactions — something the Government
largely fails to address.

26
every contract that, like the BAE-Korea agreement here, relates to (but is technically

separate from) an FMS transaction. That approach is unworkable. 14

In sum, although we appreciate the Government’s assistance, we do not find its

reasoning with respect to the enforceability of the “best effort” clause to be persuasive.

V.

Finally, BAE claims the district court erred by failing to impose a permanent anti-

suit injunction barring the Korean government from bringing suit in Korea to enforce the

BAE-Korea agreement. After the district court granted summary judgment in favor of

BAE, it lifted a preliminary injunction it had previously imposed. The court concluded

that if South Korea “proceed[ed] with its claims against BAE in its own courts, BAE may

defend against the claims by asserting any claim or issue preclusion that this judgment

may afford it under Korean law.” We review denial of the permanent anti-suit injunction

for abuse of discretion. See Lone Star Steakhouse & Saloon, Inc. v. Alpha of Virginia,

Inc., 43 F.3d 922, 939 (4th Cir. 1995).

Although a district court with jurisdiction over the parties may prohibit them from

proceeding with a lawsuit in a foreign country, the court should use that power

“sparingly.” Microsoft Corp. v. Motorola, Inc., 696 F.3d 872, 881 (9th Cir. 2012)

14
Moreover, the harm the Government suggests might arise from holding
unenforceable “best efforts” clauses like the one at issue here — i.e., “influencing allied
countries to look elsewhere for some military purchases,” Amicus Br. at 3 — is one
Korea never raised in this lengthy litigation involving numerous briefs and oral
arguments.

27
(internal quotation marks and citation omitted). Our sister circuits have outlined at least

two approaches for determining if a foreign anti-suit injunction is warranted: the

“liberal” test and the “conservative” test. Both weigh factors favoring an injunction

against the effect of an injunction on international comity. 15 The principal difference is

that the liberal approach accords less weight to international comity concerns. See

Allendale Mut. Ins. Co. v. Bull Data Sys., Inc., 10 F.3d 425, 431 (7th Cir. 1993). But

international comity remains a significant consideration, even in courts endorsing the

liberal approach. See E. & J. Gallo Winery v. Andina Licores S.A., 446 F.3d 984, 990–

91, 994 (9th Cir. 2006) (under the liberal standard, a court must perform a “detailed

analysis” to determine whether the impact on international comity would be “tolerable”).

In our view, no matter which approach provides the appropriate framework, the

district court did not abuse its discretion in denying BAE’s petition for a permanent anti-

suit injunction. BAE’s contention to the contrary rests on two rationales.

First, BAE claims the Korean litigation threatens the district court’s jurisdiction,

because “the U.S. court system is the proper venue for the dispute,” and, absent an

injunction, BAE “face[s] the possibility of an inconsistent judgment” in Korea, which

“could be enforced in [Korea] or potentially third countries.” Appellee/Cross-

Appellant’s Response/Opening Br. at 40. We agree that a district court may, in certain

circumstances, impose an anti-suit injunction to protect its own jurisdiction, even where

15
Under both approaches, the court also examines, as a threshold inquiry, whether
the parties and issues in the two disputes are the same. On appeal, neither BAE nor
Korea contend that the two disputes are not the same.

28
(as here) it has already rendered its judgment. In that context, the injunction serves to

protect the integrity of the district court order in case the foreign forum fails to give res

judicata effect to the district court judgment. See Paramedics Electromedicina

Comercial, Ltda v. GE Med. Sys. Info. Techs., Inc., 369 F.3d 645, 654 (2d Cir. 2004).

But parallel proceedings are common, and an anti-suit injunction is not appropriate

every time parallel proceedings may occur and litigation in the U.S. court concludes first.

See Laker Airways Ltd. v. Sabena, Belgian World Airlines, 731 F.2d 909, 928 n.54 (D.C.

Cir. 1984) (“[A] showing of harassment, bad faith, or other strong equitable

circumstances should ordinarily be required” for a district court to impose an anti-suit

injunction in order to protect an existing judgment). Otherwise, such injunctions would

be commonplace rather than extraordinary. Here, the Korean litigation is not particularly

vexatious or oppressive; indeed, the forum selection clause in the BAE-Korea agreement

contemplates (but does not require) litigation in Korea. In sum, we conclude that

jurisdictional grounds provide an unconvincing justification for an anti-suit injunction.

BAE also claims an injunction is necessary in order to protect U.S. national

security interests. Here, BAE has more solid footing. We have concluded that

enforcement of the BAE-Korea agreement runs counter to U.S. national security

concerns, and we agree that enforcement by a Korean court may threaten those same

concerns. But BAE goes even further, suggesting it would be inconsistent to allow the

enforceability of the BAE-Korea agreement to be litigated in Korea after holding, as we

do here, that enforcement runs counter to national security interests. See Appellee/Cross-

Appellant’s Response/Opening Br. at 32–33. That line of reasoning is too simplistic,

29
because it ignores international comity concerns that must always be considered in

determining whether to issue an anti-suit injunction.

International comity counsels us to give effect, if possible, to the judgments of

foreign courts in order to strengthen international cooperation. See Hilton v. Guyot, 159

U.S. 113, 163–64 (1895). Here, these comity concerns are near their peak. Even courts

following the liberal framework recognize that comity concerns are far greater where an

injunction would bar a foreign sovereign (rather than a private party) from litigating a

dispute in its own courts. See Allendale, 10 F.3d at 428 (suggesting an injunction barring

the French government “from litigating a suit on a French insurance policy in a French

court” would be “an extraordinary breach of international comity”); see also Microsoft,

696 F.3d at 887; Kaepa, Inc. v. Achilles Corp., 76 F.3d 624, 627 (5th Cir. 1996). Indeed,

an anti-suit injunction here would impinge on the sovereignty of the Korean courts (to

hear the case) and the Korean government (to litigate it). And it would do so on a

permanent basis, raising even graver comity concerns. Because anti-suit injunctions

against foreign sovereigns are so unusual, no circuit precedent (and little out-of-circuit

precedent) exists to guide courts in analysis of this issue.

Given all of these circumstances, we can hardly conclude the district court abused

its discretion by declining to impose an anti-suit injunction. 16

16
Our conclusion in this regard is bolstered by the response of the United States as
Amicus in this case. In its brief, the Government’s answer to our second question was
unequivocal — an anti-suit injunction is not warranted. Indeed, the Government urged us
not to impose an anti-suit injunction, partly due to international comity concerns.

30
 VI.

For the foregoing reasons, the judgment of the district court is in all respects

AFFIRMED.

31