2018 IL App (1st) 161704
FIRST DIVISION
No. 1-16-1704
OAK FOREST PROPERTIES, LLC, ) Appeal from the Circuit
) Court of Cook County,
Plaintiff and Counterdefendant-Appellee, ) Municipal Department.
)
v. ) No. 11 M6 3809
)
RER FINANCIAL, INC. and MAURICE RODGERS, ) Honorable
) Robert J. Clifford
Defendants and Counterplaintiffs-Appellants. ) Judge presiding.
JUSTICE GRIFFIN delivered the judgment of the court, with opinion.
Presiding Justice Mikva and Justice Pierce concurred in the judgment and opinion.
OPINION
¶1 Plaintiff Oak Forest Properties, LLC and RER Financial, Inc. (RER Financial) entered
into a commercial lease agreement. Plaintiff agreed to divide one of its building units into two
spaces and RER Financial agreed to lease one of the two spaces once the unit was divided. After
multiple modifications to the lease agreement and disputes over delays in construction and
inspection, the parties’ contractual relationship broke down. Defendant exercised its option to
terminate the lease agreement and the parties sued each other in the circuit court of Cook
County.
¶2 Plaintiff filed a complaint against defendants RER Financial and Maurice Rodgers for
breach of contract, breach of guaranty and unjust enrichment. Defendants filed a two-count
counterclaim for breach of contract alleging that plaintiff failed to timely divide the commercial
No. 1-16-1704
unit and leased another commercial unit in the same strip mall to a competing business.
Defendants also sought the return of RER Financial’s security deposit. Both parties asked the
trial court to award attorney fees to the “prevailing party” as provided by the lease agreement.
¶3 Following a two week bench trial, the trial court ordered plaintiff to return RER
Financial’s security deposit and denied all of the parties’ remaining claims. The trial court ruled
that each party was responsible for its own attorney fees because neither party had prevailed in
the litigation. We affirm.
¶4 BACKGROUND
¶5 Plaintiff, a landlord that operates a strip mall in Oak Forest, Illinois, and RER Financial, a
franchisee of a consumer tax preparation business, entered into a commercial lease agreement.
Plaintiff agreed to divide one of its building units into two spaces and to bear its own
construction costs. RER financial agreed to lease one of the two spaces and accepted
responsibility for the interior construction of its space, once the unit was divided.
¶6 The lease agreement required plaintiff to finish construction before RER Financial started
its interior build-out, but the parties discarded the requirement and combined their efforts to both
divide the unit and build-out the interior space. The parties agreed to use the same contractor and
a single building permit for all of the construction work. The parties’ contractual relationship
broke down. Following multiple modifications to the lease agreement and disputes over delays in
construction and inspection, RER Financial exercised its option to terminate the lease agreement
if plaintiff failed to deliver possession of the property by a date certain.
¶7 Plaintiff filed a complaint in the circuit court of Cook County against RER Financial and
individual defendant Maurice Rodgers, who had personally guaranteed the lease agreement. The
complaint pleaded three causes of action: breach of contract, breach of guaranty and unjust
2
No. 1-16-1704
enrichment. Plaintiff sought damages in an amount of $167,385. Defendants filed a two count
counterclaim for breach of contract. In count I, defendants alleged that plaintiff’s failure to
timely divide the unit interrupted their business operations and caused them to suffer lost
revenue. Defendants sought $120,827 in damages. In count II, defendants alleged that plaintiff
leased a unit to a competing tax preparation business and sought damages in an amount to be
determined at trial. Defendants also sought the return of RER Financial’s security deposit
($3403.60). Both parties asked the trial court to award attorney fees and costs to the prevailing
party. Unable to settle the case, the parties proceeded to trial.
¶8 Following a two week bench trial, the trial court ruled that both parties had succeeded in
defeating each other’s claims: RER Financial had properly exercised its option to terminate the
lease agreement and plaintiff had not breached the lease agreement. The trial court described the
parties’ contractual relationship as “a rather hellacious scenario” and denied all but one of their
claims: the security deposit claim. The trial court ordered plaintiff to return RER Financial’s
security deposit because “the contract [called] for the return of the security deposit” and despite
two weeks of lay and expert testimony, the parties’ offered “absolutely no evidence about any
damage to the unit that would warrant the keeping of the security deposit.” The trial court ruled
that both parties were responsible for their own attorney fees:
“I don’t see simply the return of the security deposit under these particular
circumstances as the defendant necessarily prevailing to the extent that he should
be awarded attorney’s fees *** [i]t simply is not substantial enough to make that
- or warrant an award of attorney’s fees *** each party is responsible for their
own fees.”
Defendants appeal this ruling.
3
No. 1-16-1704
¶9 ANALYSIS
¶ 10 The issue on appeal is whether the trial court erred when it ruled that each party was
responsible for its own attorney fees because no party prevailed in the case.
¶ 11 The parties dispute the applicable standard of review. Defendant argues that we review
the trial court’s decision de novo, while plaintiff contends that the applicable standard of review
is an abuse of discretion. Mirar Development, Inc. v. Kroner, 308 Ill. App. 3d 483, 485 (1999)
(whether the trial court properly applied the law when it denied attorney fees presented a legal
question that the appellate court reviewed de novo); Peleton, Inc. v. McGivern's Inc., 375 Ill.
App. 3d 222, 226 (2007) (whether a party prevailed in the trial court involves an application of
the facts to the law). Because the trial court applied the terms of the lease agreement to the facts,
we review the trial court’s ruling for an abuse of discretion. Peleton, 375 Ill. App. 3d at 226.
¶ 12 Illinois follows the “American rule,” which prohibits a prevailing party from recovering
its attorney fees from the losing party absent an express statutory or contractual provision. Forest
Preserve District of Cook County v. Continental Community Bank & Trust Company, 2017 IL
App (1st) 170680, ¶ 31. Accordingly, contracts that provide for an award of attorney fees to the
prevailing party are in derogation of common law and must be strictly construed. Id. The lease
agreement here contained a provision allowing the “prevailing party” in a lawsuit to recover
reasonable attorney fees and costs.
¶ 13 A prevailing party is one that is successful on a significant issue and achieves some
benefit in bringing suit. Peleton, 375 Ill. App. 3d 227; Powers v. Rockford Stop-N-Go, Inc., 326
Ill. App. 3d 511, 518 (2001) (plaintiff did not prevail where the issue was not significant relative
to either the value of the remaining claims, their complexity, or the time devoted to the other
4
No. 1-16-1704
issues at trial). Where, as here, a dispute involves multiple claims and both parties have won and
lost on different claims, it may be inappropriate to find that either party is the prevailing party.”
Timan v. Ourada, 2012 IL App (2d) 100834, ¶ 29 citing Powers, 326 Ill App. 3d at 518.
¶ 14 Defendants argue that the trial court improperly inserted a “magnitude test” into the
Lease Agreement’s attorney fees provision and incorrectly applied that test because the
successful return of a security deposit is a per se significant issue. Defendants cite Naperville
South Commons, LLC v. Nguyen, 2013 IL App (3d) 120382 in support of their argument that the
trial court erred in denying their request for attorney fees.
¶ 15 We hold that the trial court did not err when it ruled that the return of RER Financial’s
security deposit was not significant in relation to the parties’ unsuccessful claims. The case was a
draw and the return of the security deposit was not a significant issue. Powers, 326 Ill. App. 3d at
515 citing Raffel v. Medallion Kitchens of Minnesota, Inc., 139 F.3d 1142, 1147 (7th Cir. 1998)
(trial court did not abuse its discretion in deciding not to award attorney fees where the case was
essentially a draw). In terms of the relative value, complexity and time devoted to the issues at
trial, the security deposit issue simply did not compare to the parties’ breach of contract issues.
Powers, 326 Ill. App. 3d at 518.
¶ 16 Plaintiff and defendants asked the trial court to award damages in the amounts of
$167,385 and $120,827, respectively. The value of the security deposit was $3403.60. While the
complex breach of contract issues were litigated over the course of a two week bench trial that
included expert testimony, the security deposit issue was simplistic and the trial court returned
the security deposit because it had “no evidence whatsoever about any damage to the unit ***
that would warrant keeping the security deposit.” The record clearly indicates that the parties
focused their time and efforts on proving and defending their respective breach of contract
5
No. 1-16-1704
claims, not the security deposit claim.
¶ 17 We reject defendants’ argument that the trial court improperly included a new term or
“magnitude test” into the attorney fees provision of the lease agreement. The significant issue
test is the means by which Illinois courts determine whether a party prevailed in a case and is
entitled to attorney fees. Peleton, 375 Ill. App. 3d at 227. We also reject defendant’s invitation to
hold that the return of a security deposit is a significant issue per se. In a case involving multiple
claims for relief, the significant issue test is a comparative analysis: significance is determined
by weighing the relative value and complexity of the issues presented and the amount of time the
parties devoted to each issue. No single claim is significant in and of itself.
¶ 18 We also find that defendants’ reliance on Naperville is misplaced. That case involved a
landlord that lost its forcible entry and detainer action because “the tenant owed nothing at the
time of the five-day notice.” Naperville, 2013 IL 120382, ¶ 17. The trial court awarded attorney
fees to the tenant as the prevailing party. Naperville makes no mention of a security deposit and
involved the landlord’s single unsuccessful claim for unpaid rent. We have no such situation
here, where the parties filed multiple competing claims and lost all but one.
¶ 19 Accordingly, the trial court did not err when it determined that an award of attorney fees
in favor of either party was not warranted.
¶ 20 CONCLUSION
¶ 21 We affirm the judgment of the circuit court of Cook County.
¶ 22 Affirmed.
6