J-S52008-18
NON-PRECEDENTIAL DECISION - SEE SUPERIOR COURT I.O.P. 65.37
SECHRIST CONSTRUCTION, INC., IN THE SUPERIOR COURT
OF
PENNSYLVANIA
Appellee
v.
ROBERT J. HARPSTER,
Appellant No. 1393 MDA 2017
Appeal from the Order Entered September 1, 2017
In the Court of Common Pleas of Cumberland County
Civil Division at No(s): 12-7259
BEFORE: BENDER, P.J.E., MCLAUGHLIN, J., and STRASSBURGER, J.*
MEMORANDUM BY BENDER, P.J.E.: FILED NOVEMBER 20, 2018
Appellant, Robert J. Harpster, appeals pro se from the trial court’s
September 1, 2017 order directing the prothonotary to enter judgment in
favor of Appellee, Sechrist Construction, Inc., in the amount of $129,579.72.1
We affirm.
____________________________________________
* Retired Senior Judge assigned to the Superior Court.
1 We note that “[a]n appeal to this Court can only lie from judgments entered
subsequent to the trial court’s disposition of post-verdict motions….” Stahl
Oil Co., Inc. v. Helsel, 860 A.2d 508, 511-12 (Pa. Super. 2004) (citation
omitted). Although the trial court in the case sub judice directed the
prothonotary to enter judgment on the jury’s verdict upon disposing of the
parties’ post-trial motions, the docket reflects that the prothonotary did not
do so. See Pa.R.A.P. 301(c) (“[A] direction by the lower court that a specified
judgment, sentence or other order shall be entered, unaccompanied by actual
entry of the specified order in the docket, does not constitute an appealable
order. Any such order shall be docketed before an appeal is taken.”); see
J-S52008-18
The trial court provided a thorough summary of the procedural history
and factual background of this case as follows:
In this civil case involving a breach of contract in the construction
of a residence, [Sechrist Construction], a Pennsylvania
corporation engaged in the business of contracting, sued [Mr.
Harpster] for [Mr. Harpster’s] failure to timely pay [Sechrist
Construction] amounts specified in the construction contract and
for [Mr. Harpster’s] alleged interference with [Sechrist
Construction’s] timely completion of its duties under the contract.
[Mr. Harpster] counter-sued [Sechrist Construction] for
unsatisfactory workmanship in the construction of his residence,
which formed the basis of [Mr. Harpster’s] breach of contract
counter-claim against [Sechrist Construction]. A jury trial was
held on March 27-30, 2017, after which the jury found in favor of
[Sechrist Construction] on [its] claim and [Mr. Harpster’s]
counter-claim and awarded [Sechrist Construction] $102,568.96
in damages. Accordingly, this [c]ourt entered an [o]rder in favor
of [Sechrist Construction] on March 30, 2017. Following a post-
judgment motion by [Sechrist Construction] to mold the jury
verdict to include statutory interest, this [c]ourt entered an
[o]rder molding the verdict to include pre[-]judgment interest at
the statutory rate of 6% per annum for a total of $129,579.72 on
August 21, 2017. On August 29, 2017, this [c]ourt denied [Mr.
Harpster’s] [m]otion for [p]ost-[t]rial [r]elief. [Mr. Harpster] filed
a [n]otice of [a]ppeal on September 5, 2017. Pursuant to
Pa.R.A.P. 1925(b), [Mr. Harpster] filed [a] statement of errors
complained of on appeal….8
____________________________________________
also Comment to Pa.R.A.P. 301 (“[A]n appeal is premature where the [c]ourt
directs that a judgment [of] sentence or order be entered in the docket and
the prothonotary fails to do so.”) (citing Friedman v. Kasser, 438 A.2d 1001
(Pa. Super. 1981)). Nevertheless, in similar circumstances where a
prothonotary has failed to enter judgment on the docket in spite of a trial
court’s order to do so, this Court — in the interest of judicial economy — has
elected to “regard as done that which ought to have been done” and
considered the appeal to be properly before it. Stahl, 860 A.2d at 512
(citations and internal quotation marks omitted). We further discern that, as
in Stahl, the docket in the case at bar indicates that both parties received
notice of the trial court’s order for the prothonotary to enter judgment in
Sechrist Construction’s favor. See id. Thus, we will likewise treat this appeal
as being properly before us.
-2-
J-S52008-18
8 [Mr. Harpster] filed a [s]upplemental [Rule] 1925(b)
statement on October 24, 2017. This [c]ourt, pursuant to
an [o]rder dated December 1, 2017, denied consideration
of [Mr. Harpster’s] supplemental [Rule] 1925(b) statement.
[The trial court] subsequently denied [Mr. Harpster’s]
request for reconsideration of [the] December 1, 2017
[o]rder on January 12, 2018. Therefore, the arguments
raised in [Mr. Harpster’s] supplemental [Rule] 1925(b)
statement will not be addressed….
…
[Sechrist Construction’s] evidence in support of its claim for
breach of contract against [Mr. Harpster] was as follows:
[Sechrist Construction] and [Mr. Harpster] entered into a contract
for the construction of [Mr. Harpster’s] home on February 3, 2012.
The contract included specifications for the home to guide how the
project was to be completed, and a “draw schedule” to specify
when and how much [Sechrist Construction] would be paid for its
performance. It also contained language which provided that in
the event of a breach, the non-breaching party could collect 10%
of the remaining balance of the contract from the breaching party
as liquidated damages. [Mr. Harpster] paid the first three draws
to [Sechrist Construction], but withheld payment of the fourth and
final draws.
Eric Sechrist, the owner of [Sechrist Construction], testified that
[Mr. Harpster] did not follow his advice.16 [Mr. Harpster] insisted
on interviewing all of [Sechrist Construction’s] subcontractors
before they could start work. [Mr. Harpster] made several
changes once the work started. [Mr. Harpster] did work himself
and hired his own subcontractors instead of using [Sechrist
Construction’s] subcontractors on several occasions, which
delayed construction. [Mr. Harpster] was present at the work site
most days, told [Sechrist Construction] and [Sechrist
Construction’s] subcontractors how to do their jobs, and made
them redo work they had already finished.21 [Mr. Harpster] often
insisted on more or different work and changes that caused
unnecessary delay.22 [Eric Sechrist] always accommodated [Mr.
Harpster’s] requests, often paying for changes himself. [Mr.
Harpster’s] interference kept [Sechrist Construction] from
completing the project by the deadline.
16[Eric Sechrist] advised [Mr. Harpster] before the project
began that he should change the grade of the home by filling
-3-
J-S52008-18
the excavation hole and impacting the fill to improve future
drainage of the home; [Mr. Harpster] declined to make
these changes. On cross-examination, [Mr. Harpster]
denied ever having this conversation with [Eric Sechrist].
[Eric Sechrist] also advised [Mr. Harpster] to use soil to
backfill around the garage and front of the house to improve
drainage, but [Mr. Harpster] wanted to use stone and
executed a change order to that effect.
21[Mr. Harpster] made [Sechrist Construction] dig up rocks
and clean them. [Mr. Harpster] made the roofer redistribute
unplaced shingles to different areas of the roof.
22 [Mr. Harpster] changed the type of mortar to be used in
the basement after the mortar had been delivered to the job
site. [Mr. Harpster] would only allow specific pieces of
lumber to be used. [Sechrist Construction] shut down the
project for 1-2 days while awaiting delivery of new trusses
because [Mr. Harpster] would not accept the ones that were
delivered. [Mr. Harpster] wanted different kitchen cabinets
than the ones [Sechrist Construction] would provide, at a
cost of about twice the allowance under the construction
loan. [Sechrist Construction], the waterproofing
subcontractor, and the excavator returned to the jobsite
several times to do additional work when [Mr. Harpster]
wanted to raise the grade of the house.
[Eric Sechrist] received an email from [Mr. Harpster] terminating
him from the job on November 9, 2012. The email stated that
[Sechrist Construction] was forbidden from doing any more work
on the property until further notice. [Eric Sechrist] was instructed
to remove everything, including his tools, from the property. As
a result, [Sechrist Construction] was prevented from further
performance under the contract. Even though [Mr. Harpster]
never released the final two draws, [Eric Sechrist] paid all of his
subcontractors in full for their work.
The manager from [Mr. Harpster’s] lending bank testified that
before the bank would approve any draws on a construction loan,
certain specific portions of the work had to be done on the project
and the bank’s appraiser would have to do an inspection and
authorize release of the funds. The bank’s appraiser testified that
the draw schedule attached to the parties’ agreement was a
boilerplate schedule prepared by the bank, and that the work
necessary to release each draw could vary from builder to builder
-4-
J-S52008-18
depending on how they organized the build timeline. The actual
release of funds under each draw was based upon the appraiser’s
judgment of whether an adequate amount of progress had been
made since the last draw, and not on exactly what was written on
the draw schedule. It is common practice to approve a draw even
if every single item has not been completed at that point. The
appraiser personally inspected the property prior to the release of
each draw, and on October 21, 2012, found that the progress on
the construction was adequate to release the fourth draw to
[Sechrist Construction]. The Fairview [T]ownship35 building
inspector also testified that he inspected the house at various
times during construction and everything was up to code. [Mr.
Harpster] contacted the lender in order to stop payment to
[Sechrist Construction] on the fourth draw. The fourth and fifth
draws were paid directly to [Mr. Harpster].
35The subject property at issue here is located in Fairview
Township.
Darrick Trout, [Sechrist Construction’s] waterproofing technician,
testified that he took extra care and time to apply the
waterproofing membrane to the walls and [gauged] his work as
he went to ensure that every area of the membrane was done
correctly and was the proper thickness. He applied the
waterproofing according to the manufacturer’s warranty, and a
water test showed that there was no water infiltration into the
basement through the membrane. Upon questioning regarding
sagging in the membrane, Mr. Trout testified that sagging in the
material once sprayed is typical where there is extra thickness,
and is not a concern as to the quality of the waterproofing material
or its application.42 Gary Albright, another of [Sechrist
Construction’s] subcontractors who assisted with waterproofing
the foundation and basement, witnessed a water test that was
performed by Tremco.43 No water was infiltrating into the
basement during that test, except where the technician
specifically placed a hose against a non-waterproofed block to
show [Mr. Harpster] how the waterproofing worked. [Eric
Sechrist] personally observed another waterproofing test on the
basement, and no water infiltration was observed at that time.
Any water infiltration or drainage problems on the property that
might have occurred after [Sechrist Construction] stopped work
was the fault of [Mr. Harpster].46 [Sechrist Construction’s]
engineering expert also investigated whether there was water
infiltration in [Mr. Harpster’s] basement in February of 2013 and
again in March 2017. He used two types of moisture readers to
-5-
J-S52008-18
measure the moisture whenever he saw efflorescence. The
moisture levels on the walls’ surface were within or below the
normal range. There was no water infiltration. Any moisture [Mr.
Harpster] experienced could be remedied by applying a coat of
special paint to the walls before finishing the basement.
42Bubbling of the material is also not a concern as long as
the minimum thickness of the material has been met in
those areas.
43Tremco is the manufacturer of the waterproofing
membrane that was used on [Mr. Harpster’s] home.
46 After [Sechrist Construction] ceased working on the
property, [Mr. Harpster] hired his own subcontractors to fill
the garage and driveway area with materials other than
those initially recommended by [Sechrist Construction].
The manner in which those contractors completed the final
grading of the home only served to exacerbate any drainage
issues.
The Ivany block52 manufacturer testified that [Mr. Harpster] was
provided with the specifications for the generic Ivany block at the
beginning of the project and did not object to its use. He also
stated that the primary difference between generic and
trademarked Ivany block is compression strength.54 Tests done
on the two blocks also reveal that the generic block that was
actually used was superior in quality to the trademarked block
with respect to water absorption.55
52Ivany block is the type of block that was used in the
subject property’s basement.
54The trademarked Ivany block had a compression strength
of 3,000 [pounds per square inch (PSI)] and the generic
block used for the project has 2,200 PSI. The witness stated
that PSI was not relevant to the performance of the block
except in high-rise construction.
55The generic block has a capacity to absorb 11.6 pounds
of water per cubic foot and the trademarked block has an
11.9 [pound] capacity. Although negligibly different in this
case, a lower absorption rate is generally better to prevent
moisture intrusion.
-6-
J-S52008-18
[Mr. Harpster’s] landscaper is a former personal friend of [Mr.
Harpster]. He did excavation work on the property before
[Sechrist Construction] was hired and built drain spouts, finished
the retainer wall, and put in the lawn after [Sechrist Construction]
was no longer on the job. [Mr. Harpster] did not pay him for all
of the work that he did. Robert Ott was a painter that was
originally a subcontractor for [Sechrist Construction], but became
[Mr. Harpster’s] subcontractor as a favor to [Mr. Harpster]
because he knew him personally and to save [Mr. Harpster]
money. He was fired by [Mr. Harpster] after finishing almost all
of his painting work,61 and was not paid the final one-third of what
he was owed by [Mr. Harpster].
61[Mr. Harpster] complained about the paint job and fired
the witness before giving him the chance to correct the
perceived problem.
[Mr. Harpster’s] evidence in support of his counter-claim for
breach of contract against [Sechrist Construction] was as follows:
[Mr. Harpster] testified that [Sechrist Construction] breached the
contract by not providing the trademark Ivany block specified in
the contract,63 not completing the construction of the home, and
performing a myriad of things inadequately under the contract.
There were problems in the construction that [Mr. Harpster]
uncovered on his own and brought to others’ attention to be
corrected.65 There were other problems that [Mr. Harpster] had
to correct by himself.66 [Mr. Harpster] has to constantly run a
dehumidifier in the basement and cannot use the basement.67
Time and completion of construction has not remediated the water
infiltration issue in the basement. Water containment on the
outside of the property also continues to be an issue.
63 [Mr. Harpster] chose the trademarked Ivany block
because of a brochure that [Sechrist Construction] had
provided to him, and getting that exact block was an
important part of the contract.
65The water line had to be moved. The sewer lines in the
basement were hazardously placed. Two roof trusses were
cracked. Rough plumbing had to be moved.
66 [Mr. Harpster] squeegeed water that was pooling on the
sub-floors. He purchased tarps to prevent the sub-floors
from becoming dirty. [Mr. Harpster] hired a subcontractor
-7-
J-S52008-18
to backfill so he could have a driveway and porch due to
originally incorrect grading.
67 [Mr.
Harpster] also stated he observed mold growth in the
basement.
At the time the “termination” email was sent to [Sechrist
Construction], [Mr. Harpster] was still interested in maintaining a
contractual relationship with [Sechrist Construction]. [Mr.
Harpster] did not release the fourth and final draws to [Sechrist
Construction] because portions of the work that were to be
completed before the fourth could be paid were not done,72 and
[Mr. Harpster] did not want to give [Sechrist Construction] any
more money until the water infiltration issue in the basement was
resolved.
72 The final electrical work, installation of kitchen appliances,
and retaining walls were not completed. According to the
draw schedule, these items were to be finished before the
fourth draw was authorized. [Mr. Harpster] understood that
the manufacturer had to be paid before the kitchen cabinets
and tops would be installed. [Sechrist Construction]
testified that it is typical to pay for installation of the kitchen
after it is completed, to make sure the materials are
satisfactory.
[Mr. Harpster’s] expert engineer testified that in November of
2014 and again in March 2015[,] he personally investigated
whether there was water infiltration in [Mr. Harpster’s] basement.
He determined that there was and continues to be moisture in the
basement caused by the voids in the waterproofing membrane,
and not as the result of condensation. He also stated that the final
grading of a house is an integral factor ensuring that water will
drain away from the home effectively and maintaining the
effectiveness of a waterproofing membrane.76
76The final grading of the house was performed by [Mr.
Harpster].
Trial Court Opinion (TCO), 1/19/2018, at 1-2, 5-11 (most footnotes and
citations to the record omitted).
Mr. Harpster presently raises the following issues for our review, which
we have reordered for ease of disposition:
-8-
J-S52008-18
1. Did the trial court commit reversible error and abuse its
discretion and misapply the law by improperly charging the
jury relative to the facts of the case by not setting forth
breach of contract conditions which contributed to a verdict
not supported by the weight of the evidence including:
a. Anticipatory Breach/Repudiation of Contract?
b. Material and Immaterial Breaches of Contract?
c. Clear and Convincing Evidence?
d. Burden of Proof – Oral Modifications of a Written
Contract with No Oral Modification Clause?
e. Damages or Nondisclosure?
2. Did the trial court commit reversible error and abuse its
discretion and misapply the law by not disclosing in its
entirety an ex parte [i]n [c]amera discussion with a juror
who[] expresse[d] confusion about ongoing testimony,
raise[d] other issues and question[ed] the fairness of the
court system?
3. Did the trial court commit reversible error and abuse its
discretion and misapply the law by permitting [Sechrist
Construction’s] attorney to mislead the jury and the trial
court with untrue and misleading statements which
contributed to a verdict not supported by the weight of the
evidence?
4. Did the trial court commit reversible error and abuse its
discretion and misapply the law through molding the jury
verdict and awarding [Sechrist Construction] pre-judgment
interest not supported by an amount determinable nor to be
determined from the terms and conditions of the contract?
Mr. Harpster’s Brief at 9-10.
In Mr. Harpster’s first issue, he claims that the trial court “improperly
charg[ed] the jury relative to the facts of the case by not setting forth breach
of contract conditions which contributed to a verdict not supported by the
weight of the evidence.” See id. at 55 (emphasis omitted). In its Rule
-9-
J-S52008-18
1925(a) opinion, the trial court determined that no relief was due, as
“[n]either party raised an objection to any of the jury instructions in their final
form, either before or after the jury was charged.” TCO at 13 (footnote
omitted). We agree.
Our Supreme Court has recently explained:
In order to preserve a jury-charge challenge for appellate review,
a party must either: (1) lodge a contemporaneous objection on
the record, or (2) make requested points for charge part of the
record pursuant to Pa.R.C.P. 226(a), obtain an explicit trial court
ruling upon the challenged instruction, and raise the issue in a
post-trial motion.
Jones v. Ott, 191 A.3d 782, 789 (Pa. 2018) (plurality) (internal citations
omitted).
Further, even if a jury-charge challenge is properly preserved in one of
the above-stated ways, “[w]hen a trial judge directly asks for any objections,
counsel must directly state them, explicitly or by reference to prior recorded
objections, on pain of waiver.” Id. at 792. Our Supreme Court expounded,
“when the trial court specifically asks whether a party objects to a given
charge, it is reasonable to expect that counsel will in fact object or remind the
court of a previously offered instruction rather than abandon the point.” Id.
It added that, “an issue preserved at one stage (as in a submitted and ruled-
upon point for charge) can be waived at another stage (such as by denying
that there are any objections or by failing to include the issue in subsequent
briefing).” Id. (citations omitted).
- 10 -
J-S52008-18
Here, in his brief, Mr. Harpster does not point us to where he preserved
this claim at trial. Moreover, after the trial court gave its jury instructions,
the following exchange occurred:
[The trial court]: Counsel, do you have any corrections or
additions to my jury instructions?
[Mr. Harpster’s counsel]: No, Your Honor.
[Sechrist Construction’s counsel]: No, Your Honor.
N.T. Trial, 3/30/2017, at 53.2 Mr. Harpster did not directly state or refer to
any prior objections when asked by the trial court if he had any corrections or
additions to the jury instructions. Accordingly, we conclude that Mr. Harpster
waived any issues challenging the trial court’s jury instructions.3
In his second issue, Mr. Harpster argues that the trial court erred “by
not disclosing in its entirety an ex parte [i]n [c]amera discussion with a juror
who[] expresse[d] confusion about ongoing testimony, raise[d] other
issues[,] and question[ed] the fairness of the court system[.]” Mr. Harpster’s
Brief at 80 (emphasis omitted). Mr. Harpster states that the trial court
“misrepresented the contents of the discussion to Mr. Harpster’s counsel[,]”
and that “[t]he trial transcript with [the juror] was not provided by the [t]rial
[c]ourt until May 2, 2017[,] which did not afford Mr. Harpster’s counsel the
____________________________________________
2 We note that Mr. Harpster was represented by counsel at trial.
3 We also reject Mr. Harpster’s arguments that we should not strictly enforce
the waiver doctrine due to, inter alia, judicial misconduct, unorthodox
procedure utilized by the trial court, and/or detrimental effects on the jury.
See Mr. Harpster’s Brief at 7-8. Mr. Harpster has not demonstrated that any
of those circumstances occurred.
- 11 -
J-S52008-18
opportunity to question the juror, request his removal, and prevent prejudicial
impacts on the other jurors.” Id. at 80, 81 (internal citations omitted).
With respect to this issue, the trial court explained that “[d]uring the
trial, one of the jurors indicated through the [c]ourt’s bailiff to the [c]ourt that
he was having some trouble understanding what was going on and expressed
that he wanted to be able to ask questions.” TCO at 25 (footnote omitted).4
The trial court described that, “[a]fter this [c]ourt consulted with the parties’
attorneys, [Sechrist Construction’s] attorney requested that the [c]ourt do an
in camera interview of the juror to ensure that he was able to understand
English and perform his duties adequately.” Id. (footnote omitted)
Thereafter, “[b]oth parties agreed that the [c]ourt would interview the juror
on the record to establish the nature of his questions and to determine
whether he was fit to serve.” Id. (footnote omitted). Before questioning the
juror, the trial court stated to counsel:
[The trial court]: Okay. I am going to grant the request for me to
put something on the record with this juror. That being said, I am
going to lead him to a certain extent that it doesn’t open the door
for him to be asking other questions that aren’t pertinent. I just
want to be make sure [sic] that he is able to serve and that he
understands what is happening in court even if he doesn’t always
understand confusing terms by attorneys, which some people
have trouble talking about. So I will just ask him that my tipstaff
made me aware that he had some questions about what was going
on in court. I will reiterate that no juror can ask questions during
the trial, and then I will ask him if he is able to hear okay and
understand, basically, if he is able to hear what is going on and
understand basically the English language. I am trying to think of
another way to say it, but understand what the attorneys are
____________________________________________
4 This juror made this indication on the second day of the four-day trial.
- 12 -
J-S52008-18
saying even if he has questions about the substance of it all.
That’s how I’m going to pose it to him, okay?
So I will do that. Let’s take our recess now and then I will try to
get with that juror before we proceed.
[Sechrist Construction’s counsel]: Thank you, Your Honor.
[Mr. Harpster’s counsel]: Thank you, Your Honor.
N.T. Trial, 3/28/2017, at 135.
During the trial court’s questioning of the juror, the juror indicated that
he “understand[s] ninety-nine percent [of] whatever is going on.” Id. at 136.
He elaborated that he “understand[s] completely what is going on. But
sometimes I would like to ask questions like to all of this – the Defendant, the
Plaintiff, their lawyers, they have been in this case for years, since 2012, but
right now we are like, what, second day? You see, and right now we are
deeply involved in this way.” Id. at 136-37. He expressed that “something
is wrong with the system” because jurors freed O.J. Simpson, and Steve Avery
“was sentenced in 1985 for 32 years, and only in 18 years he was freed with
a DNA test because of jurors again.” Id. at 138-39.5
Nevertheless, the juror agreed he could be objective:
[The trial court]: I hear you objecting to the way that the justice
system is set up, and I understand your objections. I just want
to make sure that you understand though that it is my job to tell
you what the law is, and so you would have to follow what the law
is. Do you think that you would be able to follow what the law is?
[The juror]: (unintelligible)
[The trial court]: You will?
____________________________________________
5 Steve Avery was the subject of the Netflix documentary “Making a Murderer.”
- 13 -
J-S52008-18
[The juror]: One hundred percent.
[The trial court]: Okay.
[The juror]: For sure. I am obedient, so whatever the law I will
[sic].
[The trial court]: And you are willing to do that even though you
can’t ask questions of the attorneys and their witnesses?
[The juror]: For sure, yeah. I am completely fine with it.
[The trial court]: Okay, great.
[The juror]: I am completely fine.
[The trial court]: Thank you. Do you have anything else that you
need to tell me about in terms of anything, any reason that you
feel that you can’t serve or otherwise?
[The juror]: No. I can serve. I didn’t say that I can’t serve.
[The trial court]: I just want to make sure.
[The juror]: Completely. And I will be as objective as one hundred
percent.
Id. at 140-41.
When the trial court reconvened with the parties’ attorneys after recess,
it explained:
[The trial court]: I was able to speak with that juror on the record
and he indicated that he has a degree from [Harrisburg Area
Community College]. I think he also indicated that he has an
engineering degree. Did I get that right, Vicky?
[Court Reporter]: Yes, Your Honor.
[The trial court]: So he had an engineering degree [sic]. He is
able to understand English just fine. He is completely fine. His
issue was that he said that he didn’t like that basically everybody
surrounding the case has more knowledge, that jurors are not
allowed to ask questions, whereas everybody else can. And I
explained to him that that was the law in Pennsylvania, and I
asked him, if he would make sure, that he would be able to follow
the law, and if he was having issues with hearing anything,
- 14 -
J-S52008-18
anything of that sort. So he told me he was able to follow the law,
and he would be absolutely obedient to the law as I give it to him.
So, that’s the end of that.
Ready?
[Mr. Harpster’s counsel]: Yes, Your Honor.
[Sechrist Construction’s counsel]: Yes, Your Honor.
Id. at 142-43.
We do not agree that the trial court “misrepresented” the contents of its
discussion with the juror. See Mr. Harpster’s Brief at 80. The gist of the
conversation was that the juror wanted to ask questions and expressed that
our justice system had flaws, but indicated he adequately understood what
was going on at trial and stated that he would be objective. The trial court
conveyed just that to counsel. Further, as the trial court discerned, “neither
party asked to see the transcript of the conversation nor objected to the
service of the juror.” TCO at 26 (footnote omitted). Thus, we likewise deem
this issue waived. See Jones, 191 A.3d at 787 (“In order to preserve an
issue for appellate review, a litigant must place a timely, specific objection on
the record. Issues that are not preserved by specific objection in the lower
court are waived.”) (citations omitted).6
____________________________________________
6Mr. Harpster also suggests that the trial court committed reversible error by
not permitting jurors to ask questions during trial. See Mr. Harpster’s Brief
at 81-82. He argues that, “[a]s a result of [the t]rial [c]ourt’s misapplying
Pennsylvania [l]aw, it eliminated the opportunity for [the juror[’s] wanting to
ask questions] and potentially other jurors to ask questions for evaluating and
weighing the evidence.” Id. at 82-83. Again, Mr. Harpster has waived this
argument. As Sechrist Construction points out, “the [j]udge twice repeated
- 15 -
J-S52008-18
In his third issue, Mr. Harpster argues that the trial court erred “by
permitting [Sechrist Construction’s] attorney to mislead the jury and the
[t]rial court with untrue and misleading statements which contributed to a
verdict not supported by the weight of the evidence[.]” Mr. Harpster’s Brief
at 86 (emphasis omitted). Focusing on Sechrist Construction’s closing
argument, Mr. Harpster contends that “Sechrist [Construction’s] counsel
pursued a pattern of misconduct from opening statement through final
argument with cavalier and baseless statements about Mr. Harpster’s
character, testimony, and counterclaim and ‘kicking individuals off the job’….”
Id. at 88. Once again, we deem this claim waived.
Mr. Harpster says that he preserved this issue “in [his] post-trial
motions, post-trial supporting brief Appendix A (19 pages), [Rule] 1925(b)
[statement,] and … the [t]rial [c]ourt’s review of the record for misconduct.”
Id. at 86-87. However, Mr. Harpster does not claim that he made any timely
objections at trial when Sechrist Construction made any of the at-issue
statements during closing argument. See Jones, 191 A.3d at 787 (citations
omitted). Thus, this claim is also waived.
In his last issue, Mr. Harpster avers that the trial court erred “by molding
the jury verdict award to include pre-judgment interest on an amount not
determinable or to be determined by the contract for incomplete work and
____________________________________________
this legal position [that jurors were not permitted to ask questions during
trial], both before and after she had the conversation with [the juror], and
[Mr.] Harpster’s counsel did not object to or challenge the trial court’s stated
position.” Sechrist Construction’s Brief at 23-24 (citations omitted).
- 16 -
J-S52008-18
outstanding allowances owed by Sechrist [Construction].” Mr. Harpster’s Brief
at 73-74 (citation omitted). We disagree.
“Our review of an award of pre-judgment interest is for abuse of
discretion.” Cresci Const. Services, Inc. v. Martin, 64 A.3d 254, 258 (Pa.
Super. 2013) (citation omitted). However, “a court has discretion to award
or not award pre[-]judgment interest on some claims, but must or must not
award pre[-]judgment interest on others.” Id. (citations, internal quotations
marks, and original brackets omitted).
In more detail, our Supreme Court has explained,
even where a party’s right to the payment of interest is not
specifically addressed by the terms of a contract, a nonbreaching
party to a contract may recover, as damages, interest on the
amount due under the contract; again, this Court refers to such
interest as pre[-]judgment interest. The purpose of awarding
interest as damages:
is to compensate an aggrieved party for detention of money
rightfully due him or her, and to afford him or her full
indemnification or compensation for the wrongful
interference with his or her property rights. The allowance
of interest as an element of damages is not punitive, but is
based on the general assumption that retention of the
money benefits the debtor and injures the creditor.
Many jurisdictions have enacted statutory provisions for interest
as damages. In 1988, in Fernandez [v. Levin, 548 A.2d 1191
(Pa. 1988),] this Court adopted Section 354 of the Restatement
(Second) of Contracts as the law of this Commonwealth with
respect to the recovery of interest as damages in breach of
contract actions. Section 354, titled “Interest As Damages,”
provides:
(1) If the breach consists of a failure to pay a definite sum
in money or to render a performance with fixed or
ascertainable monetary value, interest is recoverable from
- 17 -
J-S52008-18
the time for performance on the amount due less all
deductions to which the party in breach is entitled.
(2) In any other case, such interest may be allowed as
justice requires on the amount that would have been just
compensation had it been paid when performance was due.
Restatement (Second) of Contracts § 354. In adopting Section
354, we stated:
For over a century it has been the law of this Commonwealth
that the right to interest upon money owing upon contract
is a legal right. That right to interest begins at the time
payment is withheld after it has been the duty of the debtor
to make such payment.
With regard to pre[-]judgment interest, we have explained,
interest has been defined to be a compensation allowed to the
creditor for delay of payment by the debtor, and is said to be
impliedly due whenever a liquidated sum of money is unjustly
withheld. However, as prerequisites to running of pre[-]judgment
interest, the debt must have been liquidated with some degree of
certainty and the duty to pay it must have become fixed. Thus,
even where the terms of a contract do not expressly provide for
the payment of interest, a nonbreaching party has a legal right to
recover interest, as damages, on a definite sum owed under the
contract.
Furthermore, as is the case with an award of contractual interest,
an award of pre[-]judgment interest under Section 354(1) is not
subject to a court’s discretion.
TruServ Corp. v. Morgan’s Tool & Supply Co., Inc., 39 A.3d 253, 263-64
(Pa. 2012) (internal footnotes, quotation marks, original brackets, and some
citations omitted).
Here, the trial court awarded pre-judgment interest, explaining that “the
parties had a contract which provided that certain amounts were to be paid
by [Mr. Harpster] in exchange for performance by [Sechrist Construction] over
several different time periods for the construction of [Mr. Harpster’s] home.”
- 18 -
J-S52008-18
TCO at 14 (footnote omitted). It added that “[t]he contract also included
reciprocal provisions that in the event of a breach, liquidated damages in the
amount of ten percent (10%) of the remaining balance of the contract would
be paid by the breaching party to the non-breaching party.” Id. (footnote
omitted). It concluded that “[t]hese amounts were certain and determined
by the parties at the time of contracting, and were clearly expressed by the
terms of the contract. Furthermore, at trial, the parties stipulated that
$102,568.96 was the correct amount of damages for purposes of [Sechrist
Construction’s] claim, not including statutory interest.” Id. (footnotes
omitted).
We agree that Sechrist Construction should receive pre-judgment
interest. Sechrist Construction claims that Mr. Harpster owes it a total of
$102,568.96, as set forth below:
a. Fourth draw due $ 78,854.00
b. Final draw due $ 39,427.00
c. Balance due on unpaid change orders $ 5,893.39
Subtotal $124,174.39
Less credit for work not completed
and unused allowance credits $ 30,929.88
Balance due: $ 93,244.51
10% Liquidated Damages $ 9,324,45
TOTAL DUE $102,568.96
Sechrist Construction’s Brief at 8.
- 19 -
J-S52008-18
Mr. Harpster specifically claims that the amounts for “incomplete work
and outstanding allowances owed by Sechrist [Construction]” are not
determinable from the contract, thereby precluding an award of pre-judgment
interest. Mr. Harspter’s Brief at 73-74. He states that “[t]he value of Sechrist[
Construction’s] incomplete work could not be determined by the contract and
specifications[,]” id. at 74 (unnecessary capitalization and citations omitted),
and “Sechrist [Construction] failed to provide invoices, estimates, or
established market prices to substantiate outstanding construction funds
‘allegedly’ owed for all completed and incomplete work.” Id. at 75.
We deem instructive Burkholder v. Cherry, 607 A.2d 745 (Pa. Super.
1992). In Burkholder, a contractor sued homeowners to recover money due
under a residential construction contract. Id. at 746. The contract price set
forth in the contractor’s complaint was $64,185.00, and the contractor also
claimed $3,589.19 for “extras” purportedly ordered by the homeowners. Id.
The contractor conceded that the homeowners already paid $35,301.75 of the
total amount due, leaving a purported balance of $32,472.44. Id. The
contractor subsequently amended the complaint to add an alternate count in
quantum meruit, in which he claimed that the homeowners received benefits
in the amount of $19,618.95. Id. The homeowners later filed a counterclaim
for damages, averring that the contractor’s work was incomplete and
defective. Id. Following trial, the jury returned a verdict in the amount of
$18,000.00 in favor of the contractor. Id. The trial court thereafter molded
the verdict to include $5,154.14 in pre-judgment interest. Id.
- 20 -
J-S52008-18
The homeowners filed an appeal challenging, inter alia, the trial court’s
award of pre-judgment interest. Id. On appeal, the homeowners argued that
“it is impossible to determine whether the recovery allowed by the jury was
for quantum meruit or based on the price established by the contract[,]” and
that “the jury may have allowed some or all of [the homeowners’]
counterclaim and, if so, the amount of the claim was unascertainable.” Id. at
747. In response, we determined, “[w]hether the damages were based on
the terms of the contract or on quantum meruit, it is clear that the owners
have had the use of the contractor’s money since the date on which it was
due. The amount owed, moreover, was sufficiently ascertainable so that a
tender could have been made.” Id. at 748. Thus, we held that “where, as
here, the claim is for work done and services rendered, the claimant is entitled
to recover pre-judgment interest.” Id. Moreover, we noted that “the amount
of the claim is not rendered unascertainable, for purposes of determining
whether pre-judgment interest is recoverable, merely because the breaching
party has asserted a counterclaim. Otherwise, a breaching party could always
defeat a claim for pre-judgment interest by filing a counterclaim.” Id.
In the case sub judice, Sechrist Construction’s claim is likewise for work
done and services rendered. It is also clear that Mr. Harpster has had the
benefit of Sechrist Construction’s money since it came due in 2012. We also
conclude that the amount due was no less ascertainable than the amount in
Burkholder. To the extent Mr. Harpster challenges the evidence (or lack
thereof) that Sechrist Construction proffered to support the value of its claim,
- 21 -
J-S52008-18
we remind Mr. Harpster that the parties stipulated to the amount of damages
Sechrist Construction was seeking at trial, and the jury awarded that exact
amount. See TCO at 14. Accordingly, the trial court did not err in awarding
pre-judgment interest to Sechrist Construction.
Finally, Mr. Harpster filed an application for relief pursuant to Pa.R.A.P.
2155(b), requesting that we order Sechrist Construction to reimburse him
$1,014.00, because Sechrist Construction requested that Mr. Harpster include
its exhibits in the reproduced record, and he purports that 348 pages of those
exhibits were superfluous for purposes of this appeal. We decline to grant Mr.
Harpster’s request for reimbursement.
Rule 2155 sets forth:
(a) General rule. Unless the parties otherwise agree the cost of
reproducing the record shall initially be paid by the appellant, but
if the appellant considers that parts of the record designated by
the appellee for inclusion are unnecessary for a determination of
the issues presented the appellant may so advise the appellee and
the appellee shall advance the cost of including such parts. If the
appellee fails to advance such costs within ten days after written
demand therefor, the appellant may proceed without reproduction
of the parts of the record designated by appellee which the
appellant considered to be unnecessary.
(b) Allocation by court. The cost of reproducing the record shall
be taxed as costs in the case pursuant to Chapter 27 (fees and
costs in appellate courts and on appeal), but if either party shall
cause material to be included in the reproduced record
unnecessarily, the appellate court may on application filed within
ten days after the last brief is filed, in its order disposing of the
appeal impose the cost of reproducing such parts on the
designating party.
Pa.R.A.P. 2155.
- 22 -
J-S52008-18
Here, the record indicates that Mr. Harpster initially filed an application
for relief on March 23, 2018, requesting that this Court order Sechrist
Construction to provide “advance payment for all challenges of [Sechrist
Construction’s] Designation of Additional Parts to be Reproduced pursuant to
Rule 2155 which are deemed to be unnecessary, duplicative, and overly
burdensome.” See Mr. Harpster’s Application for Relief, 3/23/2018, at ¶ 9.7
In that request, he did not allege that he had previously made a demand for
advance payment on Sechrist Construction pursuant to Rule 2155(a).
On March 30, 2018, Sechrist Construction filed a response, in which it
stated that “[t]o the extent [Mr. Harpster] can identify particular exhibits that
are duplicative, [Sechrist Construction] would consider withdrawing its
designation of those exhibits to be reproduced as part of the Reproduced
Record.” See Sechrist Construction’s Response, 3/30/2018, at ¶ 3. In fact,
it even declared that, “[t]o the extent that exhibits attached to [Sechrist
Construction’s c]omplaint duplicates exhibits referenced in [Mr. Harpster’s]
designation of the record…, [it] is willing to withdraw its designation of those
documents to the extent they are duplicative.” Id. at ¶ 5. It also averred
that Mr. Harpster “did not request advance payment from [Sechrist
Construction]. … This is the first [Sechrist Construction] is learning of [Mr.
____________________________________________
7 Sechrist Construction had designated the following as additional parts of the
reproduced record: (1) all exhibits to its complaint; (2) all additional parts of
the trial transcript to make a complete copy of the trial transcript; and (3) all
of its exhibits admitted into evidence at trial. See Sechrist Construction’s
Designation of Additional Parts of Record Pursuant to Pa.R.A.P. 2154(a),
3/15/2018 (single page).
- 23 -
J-S52008-18
Harpster’s] alleged objections.” Id. at ¶ 8. Further, Sechrist Construction
represented that “[i]t is specifically denied that [Mr. Harpster] has
appropriately identified the exact costs [he] is requesting [Sechrist
Construction] to advance. Therefore, it is impossible for [Sechrist
Construction] to comply with the Rules until [he] provides a reasonable
calculation of the requested additional costs to be advanced.” Id. As an
exhibit to its response, Sechrist Construction attached a letter it sent that
same day to Mr. Harpster. Therein, it explained to Mr. Harpster that, “since
you have pointed out that you believe certain of those documents are
unnecessary, it is incumbent upon you to … advise [Sechrist Construction] of
the exact amount of the additional cost that the reproduction of those
additional documents will generate so that we can forward a check advancing
such costs to you pursuant to Rule 2155(a).” Id. at Exhibit A. It also asked
Mr. Harpster to “provide … a calculation of the additional costs you contend
will be incurred to produce the additional documents including an identification
of the specific documents you contend are duplicative and/or unnecessary.
Assuming you provide us with a reasonable calculation of such costs and
identify the documents, we will consider whether or not to withdraw those
designations.” See id.
On April 12, 2018, we denied Mr. Harpster’s application for relief in a
brief, per curiam order. On June 18, 2018, Mr. Harpster filed his brief and the
reproduced record. Following briefing by the parties, Mr. Harpster filed the
August 14, 2018 application for relief currently pending before us, requesting
- 24 -
J-S52008-18
that we order Sechrist Construction to reimburse him $1,014.00, for
designating allegedly unnecessary documents in the reproduced record. He
reiterates his complaints that some exhibits are duplicative, and claims that
Sechrist Construction referenced only a few pages of its exhibits in its brief.
See Application for Relief, 8/14/2018, at ¶ 5 (“The request to reproduce all
[of Sechrist Construction’s] exhibits was overly burdensome and duplicative.
To illustrate a few examples: [Mr. Harpter’s] Exhibit A incorporated [Sechrist
Construction’s] Exhibits 1, 2, & 10….”) (emphasis in original); id. at ¶ 7
(“[Sechrist Construction] requested that [Mr. Harpster] reproduce all [of its]
exhibits and referenced only 9 pages throughout its brief.”). In this
application, Mr. Harpster does not acknowledge Sechrist Construction’s March
30, 2018 letter.
On August 16, 2018, Sechrist Construction filed a response, claiming
that Mr. Harpster “failed to respond to counsel’s March 30, 2018 letter and
proceeded to reproduce all designated parts of the record. Had [Mr.] Harpster
responded to counsel’s March 30 letter, Sechrist [Construction] would have
had the benefit of considering whether or not to move forward with including
all parts of the additional designation and paying for the costs associated
therewith.” See Sechrist Construction’s Response, 8/16/2018, at ¶¶ 6, 7.
According to Sechrist Construction, Mr. Harpster instead “made a unilateral
decision to include all parts and incur the cost associated therewith, which was
not a cost imposed on him by Sechrist [Construction]….” Id. at ¶ 8. Sechrist
Construction argues that “[t]his is not the procedure contemplated by the
- 25 -
J-S52008-18
Rules….” Id. at ¶ 9. Mr. Harpster did not subsequently file a reply to Sechrist
Construction’s answer, or contest the allegation that he did not respond to the
March 30, 2018 letter.
We agree with Sechrist Construction that Mr. Harpster is not due any
relief. At the outset, the record reflects that Mr. Harpster did not attempt
whatsoever to comply with Pa.R.A.P. 2155(a), or cooperate with Sechrist
Construction. Sechrist Construction indicated its willingness to withdraw
certain documents and compromise with Mr. Harpster, but Mr. Harpster
apparently chose to ignore it. Had Mr. Harpster responded to Sechrist
Construction, he likely could have avoided producing certain documents in the
first place. Further, pursuant to Rule 2155(a), Mr. Harpster’s initial remedy
consisted of advising Sechrist Construction that he viewed certain documents
as unnecessary and seeking for it to advance the cost of including such parts.
See Pa.R.A.P. 2155(a), supra. In the absence of advance payment by
Sechrist Construction, Mr. Harpster should not have produced the documents
he considered duplicative and/or unnecessary. He chose not to comply with
that Rule, despite Sechrist Construction’s referring him to it. See Sechrist
Construction’s Response, 3/30/2018, at Exhibit A. Accordingly, we deny Mr.
Harpster’s August 14, 2018 application for relief.
Order affirmed.
- 26 -
J-S52008-18
Judgment Entered.
Joseph D. Seletyn, Esq.
Prothonotary
Date: 11/20/2018
- 27 -