Bgt Holdings LLC v. United States

Summarize
Check Treatment

Related Cases

Case: 20-1084 Document: 55 Page: 1 Filed: 12/23/2020 United States Court of Appeals for the Federal Circuit ______________________ BGT HOLDINGS LLC, Plaintiff-Appellant v. UNITED STATES, Defendant-Appellee ______________________ 2020-1084 ______________________ Appeal from the United States Court of Federal Claims in No. 1:18-cv-00178-PEC, Judge Patricia E. Campbell- Smith. ______________________ Decided: December 23, 2020 ______________________ MILTON C. JOHNS, Executive Law Partners, PLLC, Ma- nassas, VA, argued for plaintiff-appellant. BORISLAV KUSHNIR, Commercial Litigation Branch, Civil Division, United States Department of Justice, Wash- ington, DC, argued for defendant-appellee. Also repre- sented by JEFFREY B. CLARK, ELIZABETH MARIE HOSFORD, ROBERT EDWARD KIRSCHMAN, JR. ______________________ Before PROST, Chief Judge, BRYSON and STOLL, Circuit Judges. Case: 20-1084 Document: 55 Page: 2 Filed: 12/23/2020 2 BGT HOLDINGS LLC v. UNITED STATES BRYSON, Circuit Judge. BGT Holdings LLC appeals from a decision of the United States Court of Federal Claims (“the Claims Court”) dismissing its claims arising from the U.S. Navy’s with- holding of certain government-furnished equipment under a fixed-price contract. The dismissal followed the court’s ruling that BGT had contractually waived its claims of con- structive change through ratification, official change through waiver, and breach for failure to award an equita- ble adjustment. The court also held that BGT insuffi- ciently alleged a breach of the implied duty of good faith and fair dealing. We affirm the dismissal of the breach of good faith and fair dealing claim but vacate the court’s dis- missal of the remaining claims. I A In 2014, BGT contracted with the Navy to construct and deliver a gas turbine generator. The Navy agreed to supply certain government-furnished equipment (“GFE”) that BGT would use to construct the generator. Two of the GFE items identified in the contract—an exhaust collector and engine mounts—are relevant to this appeal because the Navy ultimately did not deliver those items to BGT. The withdrawal of those items and the Navy’s failure to compensate BGT for that withdrawal are the source of the dispute in this case. The contract incorporated various clauses from the Federal Acquisition Regulation (“FAR”). For convenience, we cite to the FAR when referencing those contract clauses. One such clause, the “government property” clause, pro- vides as follows in relevant part: Case: 20-1084 Document: 55 Page: 3 Filed: 12/23/2020 BGT HOLDINGS LLC v. UNITED STATES 3 (d) Government-furnished property. (1) The Government shall deliver to the Contractor the Government-furnished property described in this contract. . . . (2) The delivery and/or performance dates specified in this contract are based upon the expectation that the Government-furnished property will be suita- ble for contract performance and will be delivered to the Contractor by the dates stated in the con- tract. (i) If the property is not delivered to the Contractor by the dates stated in the contract, the Contracting Officer shall, upon the Contractor’s timely written request, consider an equitable adjustment to the contract. ... (3)(i) The Contracting Officer may by written no- tice, at any time— (A) Increase or decrease the amount of Govern- ment-furnished property under this contract; ... (C) Withdraw authority to use property. (ii) Upon completion of any action(s) under para- graph (d)(3)(i) of this clause, and the Contractor’s timely written request, the Contracting Officer shall consider an equitable adjustment to the con- tract. ... (i) Equitable adjustment. Equitable adjustments under this clause shall be made in accordance with the procedures of the Changes clause. However, Case: 20-1084 Document: 55 Page: 4 Filed: 12/23/2020 4 BGT HOLDINGS LLC v. UNITED STATES the Government shall not be liable for breach of contract for the following: (1) Any delay in delivery of Government-furnished property. (2) Delivery of Government-furnished property in a condition not suitable for its intended use. (3) An increase, decrease, or substitution of Gov- ernment-furnished property. 48 C.F.R. § 52.245-1. To summarize, subsection (d)(1) of the government property clause requires the Navy to deliver the designated GFE; subsection (d)(2)(i) provides that the Navy “shall con- sider” an equitable adjustment if it does not deliver the des- ignated GFE by the agreed-upon date; subsection (d)(3)(i) gives the Navy the right to modify its GFE commitments; and subsection (d)(3)(ii) provides that the Navy “shall con- sider” an equitable adjustment if it modifies those GFE commitments. Separately, subsection (i) requires that eq- uitable adjustments be made according to the procedures in the contract’s changes clause. Subsection (i) also pro- vides that neither the Navy’s modifications to its GFE com- mitments nor its untimely delivery of GFE will constitute a breach of the contract. The contract incorporates the standard FAR changes clause for fixed-price contracts, 48 C.F.R. § 52.243-1. The fixed-price changes clause covers the Navy’s modifications to the method of shipment, the method of packing, the place of delivery, and the “[d]rawings, designs, or specifications” for specially manufactured items. Id. The clause provides that if the Navy makes any of those modifications, the con- tracting officer “shall make an equitable adjustment.” Id. The contract also incorporates a changes clause from outside the FAR that defines “authorized changes” for the entire contract. That clause is unique to the Naval Surface Case: 20-1084 Document: 55 Page: 5 Filed: 12/23/2020 BGT HOLDINGS LLC v. UNITED STATES 5 Warfare Center Carderock Division and is referred to as the NSWCCD changes clause. It states as follows: (a) Except as specified in paragraph (b) below, no order, statement, or conduct of Government per- sonnel who visit the Contractor’s facilities or in any other manner communicates with Contractor per- sonnel during the performance of this contract shall constitute a change under the “Changes” clause of this contract. (b) The Contractor shall not comply with any order, direction or request of Government personnel un- less it is issued in writing and signed by the Con- tracting Officer, or is pursuant to specific authority otherwise included as a part of this contract. The NSWCCD changes clause lists the contact infor- mation for the contracting officer, Mr. John Stefano, and declares that “[t]he Contracting Officer is the only person authorized to approve changes in any of the requirements of this contract.” The clause then warns that “any change at the direction of any person other than the Contracting Officer . . . will be considered to have been made without authority and no adjustment will be made in the contract price to cover any increase in charges incurred as a result thereof.” B We recount the facts according to BGT’s factual allega- tions in its amended complaint, which we accept as true for purposes of the Navy’s motion to dismiss. See Ashcroft v. Iqbal, 556 U.S. 662, 678 (2009). A few months into the contract performance, the Navy procurement team—including Ms. Suzanne Onesti, the procurement manager—informed BGT that the Navy would not deliver the exhaust collector and engine mounts unless BGT provided a “cost savings” to the Navy, i.e., a decrease in the contract price commensurate with the Case: 20-1084 Document: 55 Page: 6 Filed: 12/23/2020 6 BGT HOLDINGS LLC v. UNITED STATES amount BGT would save by not having to procure the ex- haust collector and engine mounts on its own. When asked about cost savings at oral argument, neither the govern- ment nor BGT identified a contract provision giving the Navy the right to demand a cost savings in exchange for supplying the designated items of GFE. BGT declined to offer a cost savings for the exhaust col- lector and engine mounts that were to be provided as GFE. The Navy then notified BGT that the exhaust collector and engine mounts had been reallocated as fleet assets and would no longer be made available to BGT. To continue performing under the contract, BGT purchased those items on the commercial market at a cost of $610,775. BGT then submitted a request for an equitable adjustment for the cost of those items. In early 2017, BGT delivered the com- pleted gas turbine generator to the Navy. The Navy ac- cepted the generator but rejected BGT’s request for an equitable adjustment for the cost of the exhaust collector and engine mounts. According to BGT, the Navy’s request for a cost savings and the Navy’s final notice of GFE withdrawal were com- municated at the direction of the contracting officer, Mr. Stefano. BGT does not allege, however, that the contract- ing officer issued a signed order concerning either commu- nication. Instead, BGT alleges facts that circumstantially con- nect the contracting officer to the GFE negotiations. Ac- cording to BGT, the Navy instructed BGT to direct all communications to Navy employees Ms. Onesti and Ms. Carolyn McCloskey, “the conduits to the larger Navy team.” BGT also alleges that it was the “usual course of performance” for the contracting officer’s decisions to be communicated through Ms. Onesti or Ms. McCloskey. For example, Ms. Onesti communicated a directive that BGT should use its own testing data to size the water treatment system for the gas turbine. Mr. Stefano later Case: 20-1084 Document: 55 Page: 7 Filed: 12/23/2020 BGT HOLDINGS LLC v. UNITED STATES 7 acknowledged that “when Ms. Onesti advised BGT that [the Navy] agreed that the water test results provided by BGT were to be used in sizing water treatment system for the [turbine], it could be construed as being tantamount to acceptance and authorization to proceed with the contrac- tor’s intended revisions.” Furthermore, according to BGT, the contracting officer must have directed the Navy’s communications regarding the exhaust collector and engine mounts because he was the only person with authority to withdraw those GFE items and reallocate them as fleet assets. Relatedly, BGT alleges that the contracting officer “knew or should have known” of the Navy’s request for a cost savings and the Navy’s threatened withdrawal of GFE because BGT com- municated those issues in progress reports that were regu- larly distributed to the contracting officer. C BGT organized its amended complaint into five counts. Two of those counts, Counts IV and V, are not at issue in this appeal. A fair reading of the allegations in Counts I through III reveals five possible grounds for relief: First, the complaint alleges that the Navy’s decision to withdraw the exhaust collector and engine mounts constituted a constructive change of the GFE provision for which BGT is entitled to an equitable adjustment. Although the contracting officer did not issue a signed order withdrawing those items of GFE, the complaint alleges that the contracting officer rat- ified the Navy’s decision to withdraw those items by real- locating them as fleet assets, thus providing the requisite authority for a constructive change. Second, the complaint alleges that the contracting of- ficer waived the Navy’s rights under the NSWCCD changes clause, thus converting the Navy’s decision to decrease Case: 20-1084 Document: 55 Page: 8 Filed: 12/23/2020 8 BGT HOLDINGS LLC v. UNITED STATES GFE into an official change for which BGT is entitled to an equitable adjustment. Third, the complaint alleges that the Navy breached its contractual duty to deliver the exhaust collector and engine mounts, and that BGT is entitled to contract damages for that breach. Fourth, the complaint alleges that the Navy breached its contractual duty to provide BGT an equitable adjust- ment after failing to deliver those GFE items, and that BGT is entitled to contract damages for that breach. Fifth, the complaint alleges that the Navy breached its implied duty of good faith and fair dealing by intentionally withholding those GFE items and thus obstructing BGT’s performance under the contract. BGT contends that it is entitled to an award of damages for that breach. Under each of its theories of liability, BGT seeks an award of $610,775, the cost BGT incurred in purchasing the exhaust collector and engine mounts on the commercial market. The Claims Court dismissed Counts I through III of BGT’s amended complaint and entered a final judgment on those counts under Rule 54(b) of the Rules of the Court of Federal Claims. BGT Holdings, LLC v. United States, 142 Fed. Cl. 474, 484 (2019). The Rule 54(b) judgment entitled BGT to take an immediate appeal from the dismissal of those counts. The Claims Court consolidated its analysis of BGT’s first two claims—constructive change through ratification and official change through waiver. The court held that neither claim entitled BGT to an equitable adjustment, be- cause “the specific contract language at issue here pre- cludes [BGT’s] arguments relating to ratification and waiver.” Id. at 479–80, 482 (citing the NSWCCD changes clause and subsection (i) of the government property clause). Case: 20-1084 Document: 55 Page: 9 Filed: 12/23/2020 BGT HOLDINGS LLC v. UNITED STATES 9 The court held BGT’s claim of breach for failure to de- liver the exhaust collector and engine mounts to be pre- cluded by subsection (i) of the government property clause, which states that “the Government shall not be liable for breach of contract for . . . [a]n increase, decrease, or substi- tution of [GFE].” Id. at 482–83. Likewise, the court held that the contract precluded BGT’s claim of breach for fail- ure to provide an equitable adjustment, rejecting that claim based on its analysis of BGT’s first two claims. Id. at 482. The court rejected BGT’s final claim, alleging breach of the implied duty of good faith and fair dealing, given the Navy’s right to decrease or withdraw GFE under the con- tract. Id. at 483–84. II On appeal, BGT does not challenge the court’s holding that the government property clause precludes BGT’s claim of breach for failure to deliver the exhaust collector and engine mounts. See 48 C.F.R. § 52.245-1(i) (precluding claims of breach for the increase, decrease, substitution, or delay in delivery of GFE). BGT challenges the dismissal of its remaining claims, however. With respect to rights aris- ing under the contract, BGT argues that it is entitled to an equitable adjustment under both the government property clause and the fixed-price changes clause. In addition, BGT contends that it is entitled to compensation because the government breached its implied duty of good faith and fair dealing by withdrawing GFE items and then refusing to compensate BGT for that withdrawal through an equi- table adjustment. A The most straightforward claim in BGT’s amended complaint is that the Navy breached the government prop- erty clause, 48 C.F.R. § 52.245-1, by failing to provide an equitable adjustment after it withheld the GFE items it had agreed to deliver under the contract. Case: 20-1084 Document: 55 Page: 10 Filed: 12/23/2020 10 BGT HOLDINGS LLC v. UNITED STATES While the Navy was entitled to withdraw GFE under the government property clause, it was not free to do so without consequence. Two subsections of the government property clause are applicable to withdrawals of GFE. First, under subsection (d)(3)(i) of that clause, the contract- ing officer “may, by written notice, at any time—(A) In- crease or decrease the amount of Government-furnished property under this contract; . . . .” In that event, subsec- tion (d)(3)(ii) requires that the contracting officer “shall consider an equitable adjustment to the contract.” Second, under subsection (d)(2)(i) of the government property clause, if the GFE promised under the contract “is not de- livered to the Contractor by the dates stated in the con- tract, the Contracting Officer shall, upon the Contractor’s timely written request, consider an equitable adjustment to the contract.” Those two subsections cover cases in which GFE is not delivered, either by formal order of the contracting officer or otherwise. In either event, the rem- edy is the same: The contracting officer must consider an equitable adjustment. BGT pleaded facts sufficient to support a claim of breach under the government property clause. Count II of the amended complaint alleges that the Navy’s “refusal to provide an equitable adjustment was a material breach of the Contract.” J.A. 33. Count II also incorporates facts from earlier portions of the amended complaint, including that the Navy withdrew certain GFE items, that BGT was forced to purchase those items on the commercial market because they were not delivered, that BGT requested an equitable adjustment in a timely manner, and that the Navy denied that request. Even assuming that the contracting officer is not chargeable—through ratification or otherwise—with hav- ing ordered the withdrawal of the exhaust collector and en- gine mounts, the Claims Court erred by not considering the pathway to relief under subsection (d)(2)(i) of the govern- ment property clause. That pathway is available Case: 20-1084 Document: 55 Page: 11 Filed: 12/23/2020 BGT HOLDINGS LLC v. UNITED STATES 11 regardless of whether the contracting officer executed a written authorization for withdrawing items of GFE iden- tified in the contract. If relief under subsection (d)(2)(i) were not available, and the contractor could seek relief only under subsection (d)(3)(ii), the government could avoid liability for reneging on its GFE commitments in any case simply by withdraw- ing GFE items without a written notice from the contract- ing officer. The availability of relief under subsection (d)(2)(i) provides a backstop against such a ploy. The government argues that BGT’s claim under sub- section (d)(2)(i) is untenable because the contracting officer was required only to “consider BGT’s request for an equi- table adjustment—not to grant the adjustment to BGT.” Appellee’s Br. 27. 1 Under the government’s theory, the phrase “shall consider” gave the contracting officer discre- tion to grant or deny an equitable adjustment and imposed no duty to grant an adjustment even if BGT could prove financial loss due to the government’s withdrawal of the exhaust collector and engine mounts. We reject the government’s interpretation of the term “shall consider” because it would produce absurd results under the government property clause. See United States v. Winstar Corp., 518 U.S. 839, 907 (1996) (avoiding a con- tract interpretation that “would be absurd”); Keepseagle v. Perdue, 856 F.3d 1039, 1047 (D.C. Cir. 2017) (interpreting an ambiguous contract term in order to avoid an absurd result). To illustrate, assume that the committed GFE in this case had a total value nearing $5 million, well over half of the contract price of $8.25 million. See J.A. 24–25. If the 1 While the government asserted this argument in connection with subsection (d)(3)(ii), its logic would extend to subsection (d)(2)(i) because that subsection also includes the “shall consider” phrase. Case: 20-1084 Document: 55 Page: 12 Filed: 12/23/2020 12 BGT HOLDINGS LLC v. UNITED STATES Navy had withdrawn all GFE, as the contract allows, it would be implausible to posit that the Navy’s only obliga- tion would be merely to “think over” BGT’s request for an equitable adjustment before denying it. It is dubious, to say the least, that the drafters of the FAR’s government property clause, 48 C.F.R. § 52.245-1, envisioned that the government would essentially have an unfettered right to withdraw promised GFE from a contract without conse- quence. The correct interpretation of “shall consider” in this contract setting does not give the government absolute dis- cretion, but instead holds the government to a duty of good faith and reasonableness. See Goldstein v. Johnson & Johnson, 251 F.3d 433, 444 (3d Cir. 2001) (“Ordinary con- tract principles require that, where one party is granted discretion under the terms of the contract, that discretion must be exercised in good faith—a requirement that in- cludes the duty to exercise the discretion reasonably.” (cit- ing the Restatement (Second) of Contracts § 205 & cmt. a)); Walsh v. Zurich Am. Ins. Co., 853 F.3d 1, 14 (1st Cir. 2017) (stating the same under New Hampshire law); Stokes v. DISH Network, L.L.C., 838 F.3d 948, 952 (8th Cir. 2016) (stating the same under Colorado law). Moreover, the FAR demands that the contracting officer exercise impartiality, fairness, and equitable treatment when considering re- quests for equitable adjustments. See 48 C.F.R. § 1.602-2 (“Contracting officers shall . . . (b) Ensure that contractors receive impartial, fair, and equitable treatment; . . . .”). The government’s interpretation of “shall consider” would in- vite subversion of that responsibility. Accordingly, we vacate the dismissal of BGT’s claim that the Navy breached its duty to provide an equitable ad- justment after it failed to deliver the exhaust collector and engine mounts. On remand, the Claims Court must deter- mine whether BGT is entitled to an equitable adjustment as fair compensation for the failure to deliver those GFE items. Case: 20-1084 Document: 55 Page: 13 Filed: 12/23/2020 BGT HOLDINGS LLC v. UNITED STATES 13 B Apart from subsection (d)(2)(i) of the government prop- erty clause, BGT argues that it is entitled to an equitable adjustment under either subsection (d)(3)(ii) of the govern- ment property clause or the fixed-price changes clause. The Claims Court rejected that claim on the ground that the Navy’s withdrawal of GFE was not communicated in a writing signed by the contracting officer, as required by the NSWCCD changes clause, and therefore was not compen- sable under the contract. 2 In response, BGT argues that the Navy’s withdrawal of the exhaust collector and engine mounts constituted a con- structive change to the contract because that withdrawal was ratified by the contracting officer after the fact. In the alternative, BGT argues that the Navy’s withdrawal of those GFE items constituted an official change to the 2 The government argues that BGT waived its claim for an equitable adjustment based on a constructive change because the amended complaint did not contain a citation to the changes clause, 48 C.F.R. § 52.243-1. Rule 9(k) of the Rules of the Court of Federal Claims, on which the gov- ernment relies, requires a party pleading a claim founded on a contract to identify the substantive provisions of the contract on which the party relies or annex to the com- plaint a copy of the contract, indicating the relevant por- tions. BGT annexed a copy of the contract to its amended complaint, and its claim of constructive change effectively identified the changes clause as the source of its asserted right to an equitable adjustment. See J.A. 31. Moreover, the government waived this argument by not raising it be- fore the Claims Court. The government’s only reference to Rule 9(k) before the Claims Court related to the govern- ment property clause, not the changes clause. See J.A. 180. Case: 20-1084 Document: 55 Page: 14 Filed: 12/23/2020 14 BGT HOLDINGS LLC v. UNITED STATES contract because the Navy waived any requirement that the change be approved in writing by the contracting of- ficer. 3 1 To demonstrate a constructive change, a plaintiff must show (1) that it performed work beyond the contract’s re- quirements, and (2) that the additional work was ordered, expressly or impliedly, by the government. Bell/Heery v. United States, 739 F.3d 1324, 1335 (Fed. Cir. 2014). As to the second element, the directive ordering the additional work must come from an individual having actual author- ity to bind the government. RMA Eng’g S.A.R.L. v. United States, 140 Fed. Cl. 191, 234 (2018) (citing Winter v. Cath- dr/Balti Joint Venture, 497 F.3d 1339, 1344 (Fed. Cir. 2007)). A clause that explicitly and exclusively assigns modification authority to a contracting officer ensures that other employees are not deemed to have implied authority to modify the contract. Winter, 497 F.3d at 1346. In this case, the NSWCCD changes clause assigned modification authority exclusively to the contracting officer. As a result, 3 Because both parties treat the NSWCCD changes clause as applicable to the withdrawal of the GFE in this case, we accept that premise for purposes of the changes clause arguments. It is not clear, however, that the changes clause applies with full force to a case such as this one, in which the government is not directing the contrac- tor to make changes but is unilaterally making the changes itself. In that setting, it makes little sense to say that the contractor should not undertake to make changes other than as directed in a written order by the contracting of- ficer, since the contractor has no way to decline to make a change that was made unilaterally by the government, whether directed by the contracting officer or otherwise. Case: 20-1084 Document: 55 Page: 15 Filed: 12/23/2020 BGT HOLDINGS LLC v. UNITED STATES 15 other Navy employees, including Ms. Onesti, did not have actual or implied authority to modify the contract. BGT does not allege that Ms. Onesti or any other Navy employee acted with actual or implied authority when com- municating the Navy’s decision to withdraw the exhaust collector and engine mounts. Instead, BGT alleges ratifi- cation as a substitute for actual authority. See Northrop Grumman Sys. Corp. v. United States, 140 Fed. Cl. 249, 277 (2018) (analyzing ratification as a substitute for actual au- thority within the context of constructive change); see also Winter, 497 F.3d at 1346; Restatement (Third) of Agency § 4.01 (2006) (“Ratification is the affirmance of a prior act done by another, whereby the act is given effect as if done by an agent acting with actual authority.”). According to BGT’s amended complaint, the contract- ing officer ratified the Navy’s informal decision to decrease the GFE because the contracting officer had knowledge of that decision from submitted progress reports and affirmed that decision by reallocating the exhaust collector and en- gine mounts as fleet assets. Assuming that a constructive change did occur, BGT has a plausible path to a remedy under either subsection (d)(3)(ii) of the government prop- erty clause or the fixed-price changes clause. See NavCom Def. Elecs., Inc. v. England, 53 F. App’x 897, 900 (Fed. Cir. 2002) (noting that the remedy for a constructive change is “an equitable adjustment under the ‘changes’ provision of the contract” (quoting Ets-Hokin Corp. v. United States, 420 F.2d 716, 720 (Ct. Cl. 1970))). In dismissing BGT’s claim of constructive change, the Claims Court did not reach the merits of BGT’s ratification theory, i.e., whether BGT alleged sufficient facts to support a plausible claim of constructive change through ratifica- tion. See BGT Holdings, 142 Fed. Cl. at 479–82. Rather, the court held that BGT had contractually waived its right to assert ratification by agreeing to the NSWCCD changes clause. Id. at 481–82. The court noted that the NSWCCD Case: 20-1084 Document: 55 Page: 16 Filed: 12/23/2020 16 BGT HOLDINGS LLC v. UNITED STATES changes clause warned BGT not to comply “with any order, direction or request” from anyone other than the contract- ing officer and that it put BGT on notice that “no adjust- ment will be made in the contract price to cover any increase in charges incurred as a result” of unauthorized orders. Id. at 482. According to the court, that unambigu- ous language precludes ratification, and by agreeing to that clause, BGT waived its right to assert ratification in future litigation. Id. BGT argues that the language of the NSWCCD changes clause does not address ratification and thus does not preclude a finding of ratification in this case. We agree. Our decision in Winter v. Cath-dr/Balti Joint Venture, 497 F.3d 1339 (Fed. Cir. 2007), provides strong support for BGT’s argument on this issue. The changes clause in the contract at issue in Winter is quite similar to the NSWCCD changes clause in this case. And in spite of the changes clause in Winter, we effectively endorsed the possibility of ratification in Winter by remanding the case for a more de- tailed analysis of the plaintiff’s ratification theory. The government argues that Winter is distinguishable because the changes clause in that case contained addi- tional language stating that unauthorized modifications would not bind the government “unless formalized by proper contractual documents executed by the Contracting Officer prior to completion of this contract.” Winter, 497 F.3d at 1345. According to the government, that clause provided a contractual basis for the plaintiff’s ratification theory in Winter that is not present here. Second, the gov- ernment points out that contract-based waiver was not as- serted in the Winter case. As a result, the government argues that Winter did not resolve the issue of contract- based waiver. We disagree with the government’s first argument. The “unless” clause in Winter did not grant the contracting officer in that case any additional authority to ratify Case: 20-1084 Document: 55 Page: 17 Filed: 12/23/2020 BGT HOLDINGS LLC v. UNITED STATES 17 changes relative to the contracting officer’s authority in this case. It is clear that none of the contract provisions in this case—including the NSWCCD changes clause and sub- section (d)(3)(i) of the government property clause—re- strict the contracting officer’s authority to ratify an unauthorized change after the fact. If anything, relative to this case, the “unless” clause in Winter had the effect of lim- iting ratification authority by specifying the circumstances in which the contracting officer could ratify a prior action by an unauthorized government employee. The contract in Winter is thus not distinguishable from the contract in this case in a way that undermines BGT’s ratification argu- ment. As for the government’s second argument, it is true that Winter did not address contractual waiver and thus does not represent binding precedent as to that issue. Nonetheless, by recognizing the availability of ratification in the face of contract provisions similar to those in this case, Winter at least casts doubt on the proposition that contract language that is silent as to ratification, such as the language in the NSWCCD changes clause, is sufficient to bar a contractor’s ratification theory. In light of our decision in Winter, the language of the NSWCCD changes clause, and the contract as a whole, we hold that BGT did not contractually waive its ratification theory. The contract in this case does not mention “ratifi- cation.” Nor does the contract otherwise expressly limit the contracting officer’s authority to ratify prior actions that were not made in full compliance with procedures required by the contract. Contrary to the government’s contention, the NSWCCD changes clause simply does not address the fact pattern of ratification—an unauthorized employee communicating a change in the first instance, and the con- tracting officer taking affirmative steps to confirm that change. Case: 20-1084 Document: 55 Page: 18 Filed: 12/23/2020 18 BGT HOLDINGS LLC v. UNITED STATES Accordingly, we vacate the dismissal of BGT’s claim that the Navy’s decision to decrease GFE was a construc- tive change through ratification. We remand for the Claims Court to determine whether BGT pleaded facts suf- ficient to support its ratification theory and, if so, whether BGT can prove that the contracting officer ratified the withdrawal of the exhaust collector and engine mounts. 2 In addition to pleading ratification, BGT alleges that the contracting officer waived the requirement that changes be made only through a signed writing, thus mak- ing the Navy’s decision to withdraw GFE an official change under the contract. If BGT prevails on its theory of official change through waiver, it would have a plausible path to a remedy under either subsection (d)(3)(ii) of the government property clause or the fixed-price changes clause. BGT asserts that the contracting officer waived the Navy’s rights under the NSWCCD changes clause through a pattern of conduct. In particular, BGT alleges that the contracting officer, by virtue of his position of authority, knew of the Navy’s right to make changes exclusively through a signed writing. BGT further alleges that the contracting officer relinquished that right when he author- ized the withdrawal of GFE—which only he had the au- thority to do—and did so other than through a signed, written order. Finally, BGT alleges that the contracting officer waived that right when he characterized a previous communication from Ms. Onesti as being “tantamount to acceptance and authorization” of a requested operating procedure. As with BGT’s claim of constructive change, the Claims Court did not address whether BGT alleged sufficient facts to support a plausible claim of change through waiver. See BGT Holdings, 142 Fed. Cl. at 479–82. Rather, the court dismissed BGT’s claim of waiver for the same reasons it dismissed BGT’s claim of constructive change: It held that Case: 20-1084 Document: 55 Page: 19 Filed: 12/23/2020 BGT HOLDINGS LLC v. UNITED STATES 19 BGT had contractually waived its right to assert waiver by agreeing to the NSWCCD changes clause, which was “un- ambiguously and diametrically opposed” to BGT’s waiver theory. Id. at 481–82. BGT argues that the language of the NSWCCD changes clause does not address waiver and thus does not preclude its waiver theory. The government takes the op- posite position. Neither party cites precedent that is di- rectly relevant to the issue. And our decision in Winter did not address the type of waiver theory that BGT asserts. We hold that BGT did not contractually waive its waiver theory. The NSWCCD changes clause has nothing to say about the fact pattern of waiver, i.e., an authorized individual with knowledge of a contract right taking ac- tions that evince an intent to abandon that right. The NSWCCD changes clause warns BGT not to com- ply with any order “unless it is in writing and signed by the Contracting Officer.” To be sure, that language addresses actions by the contracting officer, an authorized individual with knowledge of contract rights. But the purpose of that language is to warn BGT to disregard orders from unau- thorized personnel, not to prevent the contracting officer (or some other high-level official) from intentionally waiv- ing the government’s rights as to how changes must be or- dered. The government argues that BGT’s waiver theory con- tradicts the NSWCCD changes clause because that clause “unambiguously states that any directive by unauthorized Government personnel ‘will be considered to have been made without authority.’” Appellee’s Br. 21. Relatedly, the government argues that BGT’s waiver theory would con- tradict the settled principle that actions by unauthorized government employees do not bind the government. The government’s arguments miss the point. BGT is not asserting that lower-level employees waived the Navy’s Case: 20-1084 Document: 55 Page: 20 Filed: 12/23/2020 20 BGT HOLDINGS LLC v. UNITED STATES rights. Nor could it make such an assertion, because the doctrine of waiver assumes that the individual committing waiver has authority to waive a right in the first instance. See Molton, Allen & Williams, Inc. v. Harris, 613 F.2d 1176, 1178 (D.C. Cir. 1980) (analyzing “whether the gov- ernment agent dealing with appellant had authority to and in fact did waive [a contract] provision”); Globe Indem. Co. v. United States, 102 Ct. Cl. 21, 38 (1944) (holding that the government’s engineer and architect did not have author- ity to waive certain contract rights). Rather, BGT is assert- ing that the contracting officer waived the Navy’s rights, which does not contradict the settled principle that actions by unauthorized government personnel cannot bind the government. See Winter, 497 F.3d at 1344. Because we disagree with the Claims Court’s ruling that BGT’s waiver theory was precluded by the contract, we vacate the dismissal of BGT’s claim of official change through waiver. We remand for the court to determine whether BGT pleaded facts sufficient to support its waiver theory and, if so, whether the contracting officer waived the requirement that changes be made only by a written order of the contracting officer. C The final claim for relief in BGT’s amended complaint is that the Navy breached its implied duty of good faith and fair dealing by intentionally withholding the exhaust col- lector and engine mounts and by communicating its deci- sion to withhold those GFE items in an unsanctioned manner. BGT alleges that the Navy’s conduct frustrated BGT’s ability to perform its contractual obligations by forc- ing it to incur $610,775 in excess costs. In dismissing BGT’s claim, the Claims Court consid- ered the express language of the contract, which gives the Navy the ability to decrease or withdraw GFE and pre- cludes a claim of breach for such actions. BGT Holdings, 142 Fed. Cl. at 483–84 (citing subsections (d)(3)(i)(A), Case: 20-1084 Document: 55 Page: 21 Filed: 12/23/2020 BGT HOLDINGS LLC v. UNITED STATES 21 (d)(3)(i)(A)(C), and (i)(3) of the government property clause). As a result, the court held that the Navy’s with- drawal of GFE did not violate its implied duty of good faith and fair dealing. Id. We agree with the Claims Court that the implied duty of good faith and fair dealing provides no basis for extra- contractual relief in this case. The contract unquestionably gives the Navy the right to decrease or withdraw GFE. BGT cannot use the doctrine of good faith and fair dealing to complain of the very conduct that the contract expressly permits. See Precision Pine & Timber, Inc. v. United States, 596 F.3d 817, 831 (Fed. Cir. 2010) (“The implied duty of good faith and fair dealing cannot expand a party’s contractual duties beyond those in the express contract or create duties inconsistent with the contract’s provisions.”). For the reasons set forth in parts II-A and II-B above, the contract itself provides other avenues of relief for BGT that preempt the need to invoke the doctrine of good faith and fair dealing. BGT’s complaints regarding the Navy’s practice of communicating directives other than through the contracting officer’s signed writing are fully addressed by BGT’s alternative theories for relief under the govern- ment property clause and the fixed-price changes clause as we have construed them. See Hickcox-Huffman v. US Air- ways, Inc., 855 F.3d 1057, 1066 (9th Cir. 2017) (“[Appel- lant] has sufficiently alleged that [appellee] breached an express provision of terms of transportation and thus need not rely on this interpretive doctrine [of good faith and fair dealing].”); Cruz v. FXDirectDealer, LLC, 720 F.3d 115, 125 (2d Cir. 2013) (finding good faith and fair dealing redun- dant “when a breach of contract claim, based upon the same facts, is also pled”); CFS Int’l Cap. Corp. v. United States, 118 Fed. Cl. 694, 701 (2014) (same). Moreover, be- cause the application of the “shall consider” language in the government property clause already imposes a duty of good faith on the Navy, there is no justification for invoking an Case: 20-1084 Document: 55 Page: 22 Filed: 12/23/2020 22 BGT HOLDINGS LLC v. UNITED STATES extra-contractual duty of good faith that would be redun- dant of the duty imposed by that clause. Although BGT relies on the doctrine of good faith and fair dealing as a separate ground for relief, that claim is based on the same set of facts as BGT’s other claims. The contract itself defines the parties’ respective rights in light of those facts. If the contract had expressly authorized the Navy to withdraw the GFE without consequence, the par- ties’ rights would be settled by the contract, and the duty of good faith and fair dealing would have no role to play in resolving this dispute. Because we interpret the contract to provide BGT a mechanism for obtaining compensation for the withdrawal of GFE, BGT’s rights are likewise gov- erned by the contract, and the doctrine of good faith and fair dealing cannot be employed to readjust those rights. We therefore affirm the dismissal of BGT’s claim of breach of good faith and fair dealing. III In sum, we vacate the Claims Court’s dismissal of BGT’s claims of constructive change through ratification, official change through waiver, and breach for failure to provide an equitable adjustment, and we remand on those claims for further proceedings consistent with this opinion. We affirm the Claims Court’s dismissal of BGT’s claim of breach of the implied duty of good faith and fair dealing. No costs. AFFIRMED IN PART, VACATED IN PART, AND REMANDED