Finne v. Maryland Casualty Co.

Mitchell, J.

The evidence in this case shows that respondents, plaintiffs, are partners, and on June 1, 1916, were already under contract with the board of regents of the University of Washington to construct a building, known as the Home Economics Building, and complete it by September 12, 1916, with a penalty of $100 for each day’s delay thereafter that would interfere with the use of the class rooms and entrances. On June 1,1916, respondents, by written contract, sublet the lathing and plastering of the building to defendant, Tom Hogart, who was to furnish material and labor, his work to start upon notice from respondents and continue in harmony with the other work on the building, and complete it without delay. Respondents agreed to pay defendant $5,774, as follows: On the 10th of the month, eighty-five per cent of the value of material and labor actually put in the building during the preceding month, according to approved estimates. On June 17, 1916, appellant, Maryland Casualty Company, delivered to respondents a bond assuring performance of the Hogart contract without loss or dam*653age to respondents. The bond, inter alia, contains these words:

“Provided, however, that this bond is executed upon the following express conditions, the performance of each of which shall be a condition precedent to any right of recovery thereon:
“First: That in the event of any default on the part of the principal, a written statement of the particular facts showing such default and the date thereof shall be delivered to the surety by registered mail, at its office in the city of Baltimore, Maryland, promptly and in any event within ten days after the obligee or his representative, or the architect, if any, shall learn of such default; the surety shall have the right within thirty days after the receipt of such statement to proceed, or procure others to proceed, with the performance of such contract.”

Tom Hogart signed the bond as principal. Hogart proceeded with the lathing and plastering (subletting the lathing to one L. E. Nelson) until Saturday, August 19, 1916, when Hogart’s bank account was garnisheed, by reason of which the pay checks given his craftsmen on that day were dishonored. Plasterers could not be had for this work until the checks were paid. Hogart failed to take up the checks, and on August 23,1916, respondents had a conference with the soliciting agent of appellant for Seattle, at that time explaining the situation; and on that same day, by registered mail, sent written notice to appellant at its home office in Baltimore, stating therein financial delinquencies of Hogart with respect to "this contract; that his bank account had been garnisheed; that he was unable to pay or take care of his pay-roll of the last week. The notice further says as follows:

“Mr. Hogart’s men have refused to continue on the job until, they are paid for their last week’s work, and in order to have the job completed it has become necessary for us to take up the checks issued by Mr. Hogart *654last Week, and it appears that we will-have to take care of the pay roll from now on. We are charging these items to the account of Tom Hogart and are looking to your company as surety of his bond to see that we ¿re' reimbursed. ”

At this time, August 23, 1916, the work remaining undone under the Hogart contract included the two entrances to the building. Hogart did not return to work after August 19, 1916, and the work was at a standstill until August 24,1916, when respondents, took up the dishonored cheeks of Hogart and proceeded faithfully with the job, completing it about October 6; 1917, at prices for labor and material as low as pos7 sible. Seattle lawyers for appellant, on August 22, 1916, had notice of the situation, and on .that day nofiT fied the home office by wire that Hogart had probably defaulted, and on August 28, 1916, according to reply instructions, the lawyers requested respondents to furnish a statement of the Hogart account and condition of the contract, which was done on August 29, 1916. Appellant never signified any wish to complete the work, and in no way objected to respondents completing it. Finne and Gjarde, respondents, then brought this action, declaring on the lathing and plastering contract of June 1,1916, as to defendant Hogart, and on the bond as to both Hogart and the Maryland Casualty Company, demanding judgment in the sum of $3,573.25 and interest, alleging that amount to be the cost to appellant in excess of the contract price of $5,774, and some extras amounting to $161.25. Defendant Hogart, in his answer, counterclaimed for extra labor and material in the sum of $3,873.785 while the answer of appellant, Maryland Casualty Company, in addition to substantial denials, alleged affirmative matter (now most strongly relied on) that respondents, without appellant’s consent, failed; to perform *655certain express and enumerated conditions contained in the bond, which it is claimed are conditions precedent to a recovery on the bond. Replies were filed denying the new matter in each answer. There was a trial without a jury, findings and conclusions were made, and judgment was entered for respondents in the sum of $3,016.58 against Hogart, and in the sum of $2,093.68 against the Maryland Casualty Company, the latter amount being also included in the judgment against Hogart; and it is further provided in the judgment that defendants may pay, and take credit on the judgment, the claims of L. E. Nelson for $481.72, and Sam' Hunter & Company for $1,060.95. The Maryland Casualty Company appeals.

The facts above stated are supported by a preponderance of the evidence and so found by the trial court, as' well as the following additional facts: Tom Hogart’s' counterclaim was established to the extent of $318.07 and no more; there were extras in the amount of $161.25; there was a balance of $481.72 due L. E. Nelson for lathing under his subcontract with Hogart, for which claim had been filed with the board of regents; there was a claim of $1,060.95 due Sam Hunter & Company for material furnished before default of Hogart, for which notice of delivery was given and claims filed with the board of regents; and the totail cost to respondents was $9,472.50, which included $1,-125.50, consisting of expenditures after Hogart’s default or because of failure to file claims for work or material furnished Hogart, and hence no liability against respondents. The judgment of $2,093.68 against the company is arrived at by taking from the whole cost of $9,472.50 the sum of $1,125.50, made up of claims for which respondents are not liable and cost of construction to them after Hogart’s default, which leaves $8,347, from which last amount take the Hogart *656counterclaim, allowed, of $318.07, thus leaving $8,-028.93, from which subtract $5,774 (the original Hogart contract price), plus extras of $161.25, equalling $5,935.25, thus finally leaving $2,093.68. So that the judgment complained of provides only enough to pay what had already been paid on Hogart’s account before default or was unpaid at that time and supported by proper lien notices filed, and does not cover the cost of any work or material after Hogart’s default, nor of either work or material furnished Hogart or Nelson where there was no lien or claim notice filed, and hence no liability therefor against respondents and their bondsman to the board of regents. It is also to be noticed that respondents had, prior to Hogart’s default, paid him $5,400, a large portion of which, without question, was expended on the building.

Appellant alleges a large number of errors, but for the sake of clearness and order reduces them to five, as follows:

(1) “The failure of respondents to permit appellant to complete the job after Hogart’s default is a breach of a condition precedent; it goes to the essence of the contract and defeats respondents’ cause of action.”

Appellant calls attention to the provision of the bond, above referred to, with reference to the performance of each express condition thereof as a condition precedent to any right of recovery and reciting that, in case of default, written statement of facts showing default and date thereof shall be delivered to the surety by registered mail, etc., and “the surety shall have the right within thirty days after the receipt of such statement to proceed, or procure others to proceed, with the performance of such contract.” As already seen, the notice and statement were promptly given by registered mail to the company at its home *657office, and again within ten days furnished to the company’s attorneys, who were, by specific directions of the company, acting for the purpose of getting such statement. But appellant also contends that, without any waiver on the part of the company, the respondents assumed control and completed the work after Hogart’s default, thereby violating a-condition precedent and defeating recovery. All discussion of this latter point is manifestly out of the way, because, as already seen, the judgment reflects no burden or liability on account of respondents’ completing the job. This provision of the bond only reserved to the surety the option to complete the work, exercise of which, or the lack of it, could in no sense, under the issues of this case, modify or change the rights and obligations of the parties as they existed at the time of the default. No prejudice is shown.

(2) “The failure of the respondents to retain the 15 per cent reserve balance released the appellant.”

The bond says:

“and shall also retain that portion if any, which such contract specifies the obligees shall or may retain of the value of all work performed or materials furnished in the prosecution of such contract . . . until the complete performance by the principal of all the terms. ’ ’

Now, remembering appellant’s obligation is to assure the performance of Hogart’s contract with respondents, notice must he kept of the terms of that contract, among which is the following: A payment of eighty-five per cent to he made to the party of the first part (Hogart) of the value of labor and materials actually incorporated into said work, on approved estimates on the 10th day of each month during the preceding month. The contract does not provide for payment to the contractor, as the work progressed, of *658eighty-five per cent of- the money earned, measured by the contract-price, but of the “value of labor and materials actually incorporated into said work on approved estimates.” Hogart was working as subcontractor under a lump-sum contract, and if it bo true that his contract price was too low, the payment of -eighty-five per cent of value actually put into the job would lead to just such difficulty as we find here, for it appears.from the evidence that the contractor spent op the job $600 more than he received, and still, at the time of his default, there were unpaid large sums against this work.

In the case of Northwestern Nat. Bank v. Guardian Casualty & Guaranty Co., 93 Wash. 635, 161 Pac. 473, we held, in line with earlier decisions of this court therein referred to, that this contractor’s reserve constitutes a trust fund for creditors, and that the surety has the right of subrogation to that balance should he be compelled to pay creditors, and also that he has the right to prevent its dissipation; and, continuing, we said in-that case, quoting from Maryland Casualty Co. v. Washington Nat. Bank, 92 Wash. 497, 159 Pac. 689:

“His expectation when he goes on the bond is plain; the principal may squander eighty per cent, leaving the surety at the mercy of the creditors, but there is at least twenty that loitt be applied to the creditors in spite of him. This amount, originally reserved to protect merely the creditors, is a collateral security of the principal available to the paying surety.”

It is plain that fifteen per cent of this contract price has not been squandered; but more than that amount, indeed, more than the contract price with extras added, has been used to pay creditors, every dollar of which diminished the bonding company’s liability by just that much. Appellant insists on the rule “of strict right of law,” but in the case of Manhattan Co. v. United *659States Fidelity & Guaranty Co., 77 Wash. 405, 137 Pac. 1003 (in which a number of earlier, cases of this court are reviewed), the rule is announced that a compensated surety on a building contract is not released unless something is done to his prejudice, and that payments during the progress of the work in excess of the amount due, where they are necessary to protect the property from lien claims of laborers, the amount of which is not questioned, will not release the surety. In all good reason, the respondents here occupy just as strong position as the owner of the building would, because, it being a public building, they are required to fufnish bond themselves to take care of all claims for labor and material going into the building. Respondents are in no sense interlopers, but in that conduct of theirs now complained, of were only protecting themselves, and it is significant that appellant neither pleads nor attempts to show any loss whatever on account of that conduct. All that respondents have paid, or are obligated to pay, for what had been done at the time of Hogart’s default, appellant has indemnified them against.

• (3) “The surety was released by increasing the contract price more than 10 per cent without its consent.”

As to this, appellant, is in error. Extras'were added only to the extent of $161.25, which is quite another matter from that of the work costing largely in excess of $5,774, which the surety company agreed should be the cost to respondents.

(4) “Respondents cannot recover for claims not already paid by them.”

This refers to the claim of L. E. Nelson on the lathing subcontract filed with the board of regents for $481.72, and the claim of Hunter & Company for ma*660terial furnished Hogart and Nelson before default, for which notice of delivery was given and claim filed with the hoard of regents for $1,060.95, both of which claims are mentioned in the judgment, which provides that the appellant may pay them and take credit on the judgment. The fairness of each of these claims was established at the trial without objection, and even now their correctness is unchallenged. The surety company was obligated to indemnify and protect respondents, who were under contract to construct a public building for the hoard of regents of the university, and they must he held aware that, in such cases, respondents were under a bond, according to Rem. Code, § 4326, for the “faithful performance of their work and the full protection of the state against mechanics ’ and other liens: . . .”

(5) “ The surety should be credited with the amount of Hogart’s counterclaim.”

This refers to the counterclaim of $3,873.78, alleged in Hogart’s answer, and involves a question of fact, upon which a lot of testimony was submitted. An examination of it convinces us that it is not established by a preponderance of the evidence, other than the $318.07 allowed by the trial court, to which extent the judgment is less than it otherwise would be.

Judgment affirmed.

Main, C. J., Fullerton, Parker, and Tolman, JJ., concur.