The opinion of the Court was drawn up by
Tenney, C. J.Healey and Cahill, the contractors to build and complete the road suitably for the laying of the rails, with certain exceptions, abandoned their operations before the duties undertaken were performed. Cahill being indebted to the plaintiff, was sued by him, and the company was summoned as his trustee, and made disclosure in the original action, by its president, Joseph Eaton, and was charged as such; and judgment was rendered against the principal defendant, and the goods and effects and credits he had in the hands and possession of the company, as trustee. Upon an execution issued thereon, and put into the hands of the sheriff of the county of Kennebec, a demand was made of the trustee for the goods, effects and credits so deposited, within thirty days of the rendition of the judgment. The company were proceeding, by its officers, to deliver certificates of twenty-six shares of their capital stock to the sheriff, who, acting under the direction of the plaintiff’s attorney in the matter, declined to receive the certificates.
So far as the company were entitled to make payment in the stock, it does not appear that any controversy now exists touching the tender thereof. But, in this action, it is contended, that the company was indebted to the principal defendant in cash, at the time of the service of the original writ upon him, and, no cash having been in any manner offered to the sheriff at the time of the demand, the plaintiff is entitled to recover in this action.
A question is presented, and argued by the counsel for the defendants, whether any legal service was made upon the company, as trustee, in the original action. It is contended that there was not, and that the question is open. It appears *304that an attested copy of the original writ was duly left by the officer with the treasurer of the company. By R. S., 1841, c. 114, § 24, where goods are attached, a separate summons shall be delivered to the defendant, or left at his dwellinghouse or flace of last and usual abode, &c. By section 26 of the same chapter, it is provided, “ in all cases where the process is by original summons, as against executors, administrators or guardians, in ejectment, dower, scire facias, error, review, and all other civil actions, wherein the law does not require a separate summons to be left with the defendant, the service thereof, by the proper officer, shall be sufficient, either by his reading the writ or original summons to the defendant, or by giving him in hand, or leaving at his dwellinghouse or place of last and usual abode, a certified copy thereof, &c. By section 43, in suits against corporations, the summons shall be served by leaving a copy of it with the president or clerk, cashier, treasurer, or any general agent or director, as the case may be, of the corporation sued.
Writs against corporations, which are summoned as trustees, shall be served on them as other writs against corporations. R. S., 1841, c. 119, § 8. The provision in section 26, of chapter 114, is general. And the mode of service, pointed out in section 43, relates to the persons on whom the service may be made, and was evidently not designed to change the mode provided in section 26. In comparing section 24 with section 26, it will be seen, that the latter section provides that, when “ the law does not require a separate summons to be left with the defendant,” the service thereof, &e. This shows that the words “ to be left with the defendant” is the same thing as being “ delivered to the defendant, or left at his dwelling-house or place of last and usual abode,” under section 24.
But, if the service was defective in the particular pointed out by the defendants’ counsel, the appearance of the company, and submitting to the jurisdiction of the Court and making disclosure, and judgment being entered, would certainly obviate the defect, so far as the matter is now before us; and it cannot be considered, under the argument in the *305case, that the Court shall render such judgment as the law and facts require, an open question.
The original disclosure was full, and thereupon we are to decide whether the plaintiff can prevail in this action of scire facias. The amount earned by the contractors is not in controversy. But the dispute is, touching the allowance of certain sums, claimed by the company as having been paid, before the service of the original writ; and if any thing was due from the company, was it in cash or stock ?
The contract price for constructing the roads, according to articles of agreement, was the sum of $287,000, including the sum of $29,000 for land damages for the railroad, depots, station-houses, and other buildings. The railroad company contracted that they would settle all land damages, and deduct therefor, from the payment to be paid the contractors, the said sum of $29,000, and it was further agreed and understood that, in the settlement and adjustment of the damages aforesaid, the company shall use all reasonable diligence and dispatch, and, if any delay shall arise in the prosecution of the work, by reason of legal proceedings, in the settlement of said damages, the company shall not be holden for any damages on account thereof.
The plaintiff insists that the contract price was really the sum of $258,000, and the company were to settle the land damages. The company, on the other hand, insist that the whole sum of $29,000 should, in making up the payments made by the company, be allowed as paid. We think neither ground the. correct one. As we have seen, the company were to be diligent in the settlement and adjustment of these damages, so that the contractors should not be delayed. And we see no reason for any objection to the allowance of such sum, on this account, as was actually paid before the service of the process upon the trustee. It was paid, and, by the contract, was to be deducted from the full" contract price.
. The balance of the land damages cannot be treated as actually paid by the company, when no part thereof had been paid. They were bound to pay these damages, if the road *306was constructed, to the owners of the land, and unless payment was made seasonably, or the company had acquired title to the land, or had obtained license in some mode, the contractors might also be liable. It was not certain that the trustee would pay the balance. The portion of .the $29,000, as land damages, hot paid at the time of the service of the' writ upon the company, cannot be treated as a payment in this process.
The treasurer of the company paid to the contractors on October 10, 1854, the day on which the trustee was served with the writ, the sum of $11,067,55. There is no evidence, whatever, that he had not knowledge of this service before the payment was made. The exact time of the service being stated in the return, is to be regarded earlier than the payment on the same day, without evidence of the particular time of day when the money was paid. Fairfield v. Paine, 23 Maine, 498. This payment cannot injuriously affect the plaintiff.
It is provided in the contract, that, on or about the first day of each month, the engineer shall estimate the quantity of work done, and give a certificate of the same, and, within ten days after the presentation of such certificate, the corporation will pay the contractors, in whose favor such certificate may be given, eighty per cent, of the amount then due for work specified in such certificate, and when the whole of the work contracted for shall have been accepted as completed according to the contract, the balance due shall be paid to the contractors.
In looking at the monthly estimates and payments, as they appear by the disclosure, it is manifest that, for a large portion of the time, the company paid in cash eighty, pér cent, found due by the certificates of the engineer. It is' hence contended by the plaintiff that the company waived the right to make payment in stock, to the amount that they were authorized to do; and that the money was paid instead of stock, and the substitution cannot now be recalled.
By the contract, the contractors bound themselves to receive in payment $75,000 in stock at par value; and twenty *307per cent, of the contract price, which was to be withheld each and every month, till the completion of the road, as security for the fulfilment of the contract on the part of the contractors, was to make a part of this sum, and to be paid in stock. This obligation to take, in the whole, §15,000 in stock, was never directly cancelled or modified. The contract is silent as to the time when stock should be paid in discharge of that portion of the monthly indebtedness, to be paid in stock. The sums due at the end of each month materially varied one from another. It was hardly to be expected that a stock certificate would be made each month for the exact sum which was to be so paid. If the company were willing to pay the eighty per cent, in cash, on each monthly certificate, it cannot now be treated as an-act which binds the company absolutely. No consideration was paid therefor by the contractors; and it is in evidence that the stock in the market was far below par. We cannot doubt that the company were willing to pay, and the contractors were willing to receive, the part to be paid monthly, in cash; and, afterwards, that stock certificates should be delivered, in accordance with the stipulations in the articles of agreement.
. According to the views expressed in the foregoiug remarks, at the time of the service of the writ upon the trustee, the contractors had received more than six thousand one hundred and fifty dollars, in cash, which the company were entitled to pay in stock. But, at the same time, more than eight thousand five hundred dollars was due in stock from the company. From this sum, deducting the excess of cash actually paid, leaves a balance payable in stock, due the contractors, of a sum not exceeding two thousand three hundred and seventy dollars, which is short of that offered by the officers of the company to the sheriff who made the demand on the execution. The twenty-six shares of the stock are to be regarded as in the sheriff’s hands, for the benefit of the plaintiff.
Judgment for the defendants.
Rice, Appleton, Cutting, Mat and Goodenow, JJ., concurred.