TRAX Constr. Co. v. Reminderville

[Cite as TRAX Constr. Co. v. Reminderville, 2021-Ohio-3481.]

IN THE COURT OF APPEALS OF OHIO
ELEVENTH APPELLATE DISTRICT
LAKE COUNTY

TRAX CONSTRUCTION CO., CASE NOS. 2020-L-113
2020-L-127
Plaintiff-Appellee, 2021-L-008

-v-
Civil Appeals from the
VILLAGE OF REMINDERVILLE, Court of Common Pleas

Defendant-Appellee,
Trial Court No. 2018 CV 000184
OHM ADVISORS, et al.,

Defendants-Appellants.

OPINION

Decided: September 30, 2021
Judgment: Affirmed

O. Judson Scheaf, III, Jeffrey A. Yeager, and Elise K. Yarnell, Hahn Loeser & Parks
LLP, 65 East State Street, Suite 1400, Columbus, OH 43215, and Andrew J. Natale
and Aaron S. Evenchik, Hahn Loeser & Parks LLP, 200 Public Square, Suite 2800,
Cleveland, OH 44114 (For Plaintiff-Appellee).

Angela F. Lohan, Village of Reminderville Law Director, 3382 Glenwood Boulevard,
Reminderville, OH 44202 (For Defendant-Appellee).

Michelle A. Thomas, Dickie, McCamey & Chilcote, P.C., 89 Kercheval Avenue, Grosse
Pointe Farms, MI 48236, Paul J. Schumacher and Kristin L. Wedell, Dickie, McCamey
& Chilcote, P.C., 600 Superior Avenue East, Fifth Third Center, Suite 2330, Cleveland,
OH 44115, and George S. Coakley and Richard T. Lobas, Coakley Lammert Co., LPA,
20600 Chagrin Boulevard, Suite 1100, Cleveland, OH 44122 (For Defendants-
Appellants).

CYNTHIA WESTCOTT RICE, J.
 {¶1} Appellants, OHM Advisors (“OHM”), et al., appeal from the judgment of the

Lake County Court of Common Pleas, after a trial by jury, in favor of appellee, TRAX

Construction Co., which awarded appellee $1,061,551.84 in compensatory damages,

$325,000 in punitive damages, and $483,870.53 in attorney fees. We affirm.

{¶2} TRAX is a construction company specializing in excavating, repairing, and

replacing underground utilities. By way of its owner and president, Christopher Valletto,

TRAX contracted with appellee, the Village of Reminderville (“Village”), to perform

underground utility construction work, including a new sanitary-force main, a new water

main, and new storm sewers (“the Project”). The contract bid was for $2,078,000 and

was based upon a specified work schedule which was originally set to commence on June

12, 2017 and finish on October 31, 2017. At a preconstruction meeting, the parties

confirmed that the city of Cleveland and Summit County would be involved in inspecting

and paying for a portion of the work, and that all contractor pay requests and change

orders (work added to or deleted from the original contract) had to be submitted to OHM,

the engineering firm used by the Village, for processing before submission to the Village

for final approval.

{¶3} OHM engineer Chad Lewis assisted OHM in drafting the design. According

to Mr. Lewis, TRAX was entitled to rely upon the plans set forth in the design, in particular

the location of the utilities to be replaced or repaired as depicted in the design. Appellant-

Eugene Esser, an engineer for OHM, acted as the Project Manager and as well as the

contractual liaison between TRAX and the Village (Mr. Esser was designated as the

Village’s engineer outside of his work on the project). Mr. Scott Hines was OHM’s

construction manager and was the main point of contact between TRAX and OHM.

2

Case Nos. 2020-L-113, 2020-L-127, 2021-L-008
According to Mr. Valetto, all communications went through Mr. Hines who was in direct

contact with Mr. Esser.

{¶4} Mr. Esser, along with the Village, were responsible for establishing funding

for the Project. According to the Village’s Mayor, Sam Alonso, the Village relied upon

OHM to properly administer the contract; and, if something noteworthy or important

occurred or failed to occur during the course of the Project, the Mayor maintained the

Village expected OHM to contact him and/or the Village council to discuss such matters.

{¶5} When TRAX began excavation for the Project, it discovered the project

design was flawed; initially, the utilities depicted in the design were not in the location

identified. Mr. Hines subsequently advised TRAX to move further down the line as

depicted on the plan to address what was shown to be an abandoned water line. When

TRAX located this line, it discovered it was not abandoned and, due to certain regulations

relating to excavating live lines, the plan needed to be revised. According to Mr. Valletto,

the postponement required TRAX to remain on the job and incur additional time and

resource costs. OHM, via Mr. Lewis, admitted that TRAX was entitled to rely upon the

design plans, including utility locations. And Mr. Lewis conceded the actual utility locations

were different than those depicted on the design plan.

{¶6} In light of the construction delay, TRAX, via Mr. Jeffrey Busch (TRAX’s

Project Manager), Mr. Valletto, or other representatives, provided OHM, Mr. Hines, Mr.

Esser, and the Village with numerous written correspondences requesting, inter alia,

progress meetings to discuss factors impacting the project due to the postponement(s)

and what was eventually characterized as an “indefinite standby.” Overall, some 16

letters were sent between August 3, 2017 and February 23, 2018 – Ultimately, only two

3

Case Nos. 2020-L-113, 2020-L-127, 2021-L-008
progress meetings were held (the first on October 30, 2017 and the second occurring on

November 28, 2017); and, although on-site verbal communications took place, OHM sent

a written response to only two of TRAX’s letters.

{¶7} After the first issue causing the re-design, Mr. Valleto stated that Mr. Hines

directed TRAX to continue to remain on site to complete the workable aspects of the

Project. And, with respect to TRAX’s concerns about significant additional expenses

accumulating due to the delays and “standbys,” Mr. Valleto asserted Mr. Hines assured

him TRAX would be paid for its additional incurred costs. Although nothing in writing was

offered to confirm this conversation, Mr. Hines assured Mr. Valletto “his word has value.”

TRAX accordingly submitted change orders for the additional work to confirm the changes

and ensure payment. According to Mr. Valletto, however, as of November 28, 2017,

nearly a month beyond the initial, contractual completion date, TRAX had not received

any payment from the Village. Had TRAX been told it was not going to be paid for the

additional time and work, Mr. Valletto stated it would have stopped work immediately.

{¶8} As of late November 2017, Mr. Valletto stated TRAX had explained to the

Village, via letter and verbal exchanges, the problems it was experiencing due to the

inability to move forward. Specifically, TRAX, through Mr. Valletto, advised the Village

and OHM: “we are continually being damaged by our equipment and manpower out there

on the project well beyond the completion time and that we are also financing the project

and financing additional work that we’ve been assured payments on and that’s basically

what we are telling them and that we are tracking these costs.” According to Mr. Valletto,

no representative of the Village or OHM disputed these points. Indeed, during this

timeframe, a point at which construction would be slowed due to potential weather

4

Case Nos. 2020-L-113, 2020-L-127, 2021-L-008
interference, no agent of the Village or OHM advised TRAX to leave the site to avoid

further time-and-resource costs.

{¶9} Considering the lack of payment and additional expenditures, TRAX made

a public-records request asking the Village to produce all files, including emails and text

messages, relating to the changes to the project design, additional-cost claims submitted

by TRAX, and the “positions that exist between the Village and its design engineer.”

TRAX stated it required this information in the event it “must escalate the matter to recover

the compensation due.” TRAX received no response to the request.

{¶10} On December 12, 2017, nearly six weeks after the original, scheduled

completion date, TRAX sent a letter to Mr. Hines, OHM, and the Village regarding a

change order and pay application which did not account for its completed work. The letter

noted the Village would be in material breach of the contract by failing to timely process

payment requests for work performed. On the same date, Mr. Hines sent TRAX a letter

indicating the Village and OHM would be addressing only an extension of time for the

Project’s completion and nothing else. The letter also stated that, due to, among other

things, the winter weather, the Village was putting a work hold on certain aspects of the

Project.

{¶11} In Mr. Valletto’s view, the representations in Mr. Hine’s letter implied that

unless TRAX cooperated with OHM on its terms, it would not be paid. TRAX

subsequently responded requesting further clarification of the Village’s and OHM’s

intentions and advised the Village if it desired to terminate TRAX for convenience from

the Project (pursuant to the contract), it would need the proper paperwork to minimize the

5

Case Nos. 2020-L-113, 2020-L-127, 2021-L-008
cost. According to Mr. Valletto, TRAX received no written response from either the Village

or OHM and no meeting was arranged or held.

{¶12} On December 27, 2017, TRAX sent the Village and OHM a letter advising

that it had not been paid for base contract work and had been unable to confirm the

processing of pending payment applications. The letter noted that OHM and the Village

represented to TRAX “many weeks ago” that the applications had been submitted but,

given the uncertainty and delay, TRAX was concerned the applications were never sent.

TRAX requested copies of the submission and any related paperwork regarding the

payment applications. The letter also advised that TRAX had sent various letters to the

Village and OHM regarding the absence of required design documents, certain

interferences with work, and additional-cost claims associated with compensable delays.

TRAX noted that despite repeated efforts to mitigate costs, the Village and OHM have

failed and refused to follow the provisions of the original contract and timely process

accurate payment applications. TRAX received no written response to this letter and no

meeting was arranged or held.

{¶13} On January 22, 2018, TRAX, via Mr. Valletto, again wrote the Village and

OHM. That letter advised that the Village’s finance officer’s certificate in the original

contract was $897,000 and TRAX has, or will, surpass that level of costs. TRAX

expressed serious concern regarding the uncertainties surrounding the certified financing

and noted it had endeavored to meet with the Village and OHM but received no response.

TRAX stated it was entitled to a revised certificate showing the entire amount of the

contract bid. Meanwhile, the letter advised TRAX will not work, and is not required to

work beyond the amount certified. TRAX also reminded the Village that it was in breach

6

Case Nos. 2020-L-113, 2020-L-127, 2021-L-008
of the contract relating to its failure to respond to its pending change orders for payment,

as well as the Village’s and OHM’s failure to act which prevented performance under the

contract. If the Village or OHM disputed any change orders, TRAX requested a meeting.

TRAX requested the Village and OHM to respond by the close of business on Friday,

January 26, 2018. Mr. Valletto stated he did not receive a response to this letter and no

meeting was arranged.

{¶14} Mr. Valletto pointed out that the Village finance officer’s certification

essentially ensures that funds are available to pay a contractor for work completed.

Because the project had went in an unexpectedly bad direction for TRAX, Mr. Valletto

and his associates revisited the contract and found the funds certified, $897,000, were

far lower than the $2,078,000 accepted by the Village on TRAX’s bid. He noted this

discovery was “a big alarm button for us.” As such, if TRAX performed more than

$897,000 of actual work, it was at risk of not being paid beyond that amount. Thus, TRAX

requested the Village to recertify the funds to an amount that would be sufficient to cover

expenses to date. Mr. Valletto ultimately admitted he did not fully review the fund-

certification aspect of the contract when he signed it on behalf of TRAX. He also admitted

he would not have signed it had he known the certification was much lower than the bid.

{¶15} On January 29, 2018, OHM sent TRAX a letter, via Mr. Hines, which

reiterated its December 12, 2017 statements. It also requested a written schedule for

when TRAX intended to return to work on the project. TRAX subsequently responded to

this request, stating it could not provide a schedule for returning to work because its

billings have reached the limit of the finance officer’s certificate in the contract. Moreover,

TRAX pointed out that OHM had previously directed it to stop work and, without a

7

Case Nos. 2020-L-113, 2020-L-127, 2021-L-008
recertification, re-commencing work was not possible. In effect, TRAX stated “OHM is

preventing TRAX’s performance and delaying TRAX.” TRAX demanded the Village and

OHM to process its pending pay applications. Mr. Valletto stated he received no response

to this missive.

{¶16} In light of the foregoing, on February 1, 2018, TRAX sent the Village and

OHM a letter advising them that it had filed the underlying complaint and submitted a copy

of the same. TRAX pointed out that, even though it had tried to work with both the Village

and OHM, they essentially ignored all requests for meetings and failed to certify funds for

further payments. TRAX stated it remained ready and willing to discuss the issues, but

no further work would occur on the project. Also, TRAX emphasized that, because the

project had not been recertified and its equipment and materials were sitting idle, the

Village had commenced taking its materials. Mr. Valletto stated TRAX had a surplus of

stone; the Village, however, without TRAX’s permission, began using the materials to

backfill potholes and trenches.

{¶17} In their complaint, TRAX alleged fraud/willful concealment, breach of

contract, and theft/conversion against the Village; and, against OHM and Mr. Esser, it

alleged fraud/willful concealment, negligence, and theft/conversion. The Village filed a

counterclaim against TRAX and a cross-claim against OHM and Mr. Esser, seeking, in

relevant part, indemnity and contribution from OHM and Mr. Esser.

{¶18} Subsequently, on April 11, 2018, the Village issued a funding certificate in

the amount of $2,078,789.55. Later, on May 24, 2018, the Village terminated TRAX for

convenience; at that point, TRAX had been paid $979,509.83 for the work it had

performed.

8

Case Nos. 2020-L-113, 2020-L-127, 2021-L-008
 {¶19} Meanwhile, the Village filed cross-claims against the OHM defendants

seeking indemnity and contribution, with a supplemental cross-claim alleging negligence.

The OHM defendants filed a motion to dismiss the complaint, alleging the economic-loss

rule barred TRAX’s tort claims. The trial court denied the motion and the matter

proceeded to jury trial. TRAX subsequently moved for an order of spoliation and an

adverse evidentiary presumption, asserting Mr. Esser had lost or destroyed a flash drive

containing documents relating to the Project. The trial court denied TRAX’s motion and

issued an order in limine preventing reference to the alleged spoliation as well as the

potential for an adverse inference.

{¶20} Beyond the facts set forth above, Mr. Esser testified that, while acting as

OHM’s project manager, OHM owed TRAX the duties to take ownership of mistakes, to

deal fairly and honestly with it, and to act as a faithful agent, including keeping it fully

informed. Mr. Esser stated that such duties also involve being fully informed and

communicating with a client in various forms such as writing, email, and verbal contact.

He testified that a project manager and engineer has an obligation to be truthful and

neither conceal nor fail to disclose important information. Mr. Esser agreed that the

foregoing standards applied to OHM’s relationship with TRAX, and TRAX was entitled to

rely upon him and OHM to adhere to these standards.

{¶21} Mayor Alonso testified that having the necessary money to fund a project is

important, and TRAX was entitled to be concerned if sufficient funds had not been

secured. He also agreed that if TRAX was on the project longer than expected, through

no fault of its own, it is entitled to the requisite compensation. Moreover, Mayor Alonso

agreed that TRAX kept OHM, at the very least, apprised of the entire time and costs it

9

Case Nos. 2020-L-113, 2020-L-127, 2021-L-008
had incurred on the project. And the mayor testified that the Village would remit payment

to TRAX to the extent “everything looks good” (with respect to payment applications) to

OHM. Mr. Valletto testified that, after the initial hold up due to problematic designs, Mr.

Hines directed TRAX to go outside the project limits and proceed with additional work

necessitated by the changes. And, even though, according to Mr. Valletto, OHM had

repeatedly assured TRAX, via both Mr. Esser and Mr. Hines, it would be paid for the

additional time and work, no such payment was promptly or obviously processed.

{¶22} Contrary to Mr. Valletto’s testimony, Mr. Hines testified he did not assure

TRAX it would be paid; instead, Mr. Hines observed that the applications relating to the

change orders would be reviewed and decisions would be made accordingly. During its

case in chief, TRAX submitted an email received in discovery which was written on

December 12, 2017, by Mr. Hines to Terry Bowlin, a technician for OHM. The email

related to TRAX submission of a change order as well as a “winter shutdown.” The email

additionally sought confirmation that certain materials related to the project can be stored

on a baseball field because “[i]t is likely that the rebid will push the project past the start

of the field being used.” When questioned about “the rebid,” Mr. Hines testified

discussions had occurred that suggested TRAX might be pulling off the job. When

pressed on this point, however, Mr. Hines stated that neither he nor OHM had discussed

the possibility of a rebid with either TRAX or the Village. Although Mr. Hines testified no

rebid would occur unless TRAX left the project, he also acknowledged that the winter

months slowed, if not halted work. Further, even though OHM was discussing rebidding

the job, Mr. Hines conceded there was no discussion at that point of terminating the

10

Case Nos. 2020-L-113, 2020-L-127, 2021-L-008
contract for convenience, a contractual tool that would allow either party to sever ties to

the contract without issue or incurring further expense.

{¶23} In December 2017, Mr. Esser was transitioning into retirement and Thomas

Tucker, a senior project manager and engineer for OHM, was assuming his role as Project

Manager on the Project. In a December 22, 2017 email from Mr. Hines to Mr. Tucker (on

which Mr. Esser, Mr. Lewis, and Mr. Bowlin were copied), Mr. Hines recommended they

discuss “Reminderville verbally” because “[i]t is a different animal for which we do not sit

in the zoo keepers chair.” (sic.) Mr. Hines denied writing the email.1 In light of this, OHM

objected to the email’s admission. The trial court, however, overruled the objection, ruling

the jury should be permitted to consider and weigh the import of the email because it was

in OHM’s system, a point counsel for appellants later conceded.

{¶24} Mr. Esser additionally testified that he had removed certain project-related

information on his company-issued computer after he retired. Although Mr. Esser saved

the information to a flash drive, and agreed to save the information during his deposition,

he later deleted it from the flash drive and, according to his testimony, saved it to a

different computer. The information, therefore, whatever it may have been, was ultimately

unavailable.2

{¶25} After each party rested, the trial court entered a directed verdict for OHM on

TRAX’s and the Village’s negligence claims but denied a directed verdict on TRAX’s fraud

claims. The jury ultimately returned a verdict in favor of the Village on TRAX’s fraud

1. Notwithstanding Mr. Hines’ denial at trial, appellants appear to concede he wrote and sent the
message at page 4 of their brief (“On 12/20/17, and in light of TRAX’s escalating complaints and
demands, Hines directed an email to Tucker indicating that they should discuss the [project] ‘verbally’
* * *.”)

2. It was this information that prompted TRAX’s motion regarding spoliation and an adverse inference.
11

Case Nos. 2020-L-113, 2020-L-127, 2021-L-008
claims and in favor of TRAX on the breach of contract claims but awarded zero damages

for the Village’s breach of contract. The jury found in favor of TRAX on the fraud claims

against OHM and Mr. Esser. The jury also found in favor of the Village against OHM and

Mr. Esser on its indemnity cross-claim. The jury found that TRAX’s damages were

caused exclusively by OHM/Esser due to their concealments and fraudulent actions on

which TRAX justifiably relied. OHM and Mr. Esser moved for a judgment notwithstanding

the verdict and a new trial, each of which were denied. As outlined above, the jury and

judge eventually ordered damages and fees in an amount just under $1.9 million. This

appeal follows.

{¶26} Appellants’ first assignment of error provides:

{¶27} “The trial court committed reversible error by denying the motion to dismiss

the complaint (9/13/18 judgment entry), the motion for directed verdict (TTr pp 648-649),

and the motion for JNOV (10/21/20 journal entry) because the economic loss rule barred

all tort claims by plaintiff TRAX against the OHM defendants.”

{¶28} Appellants assert that the trial court erred, as a matter of law, in denying its

various motions because the economic-loss rule barred all TRAX’s tort claims, including

the intentional tort of fraud, because their status as design professionals on the Project

was not a sufficient nexus to substitute for privity under the contract between TRAX and

the Village. Moreover, they argue they owed no general duty under tort law to protect

TRAX from purely economic harm arising out of contractual obligations regarding the

Project’s design because this duty arose and was binding between OHM (and its agents)

and the Village exclusively. In this respect, appellants maintain whatever allegedly

reasonable reliance TRAX had on OHM’s representations cannot serve as a substitute

12

Case Nos. 2020-L-113, 2020-L-127, 2021-L-008
for privity between TRAX and appellants. Finally, appellants contend that, even if the

economic-loss rule does did not bar the fraud claim, Ohio law does not permit a contractor

to evade contractual limitations by pleading fraud grounded upon an alleged breach of an

ethical duty to disclose – the foundation, in appellants’ view, for the jury’s verdict in

TRAX’s favor.

{¶29} Initially, TRAX asserts appellants failed to preserve their arguments vis-à-

vis the economic-loss rule because they (1) did not raise it as to fraud as part of their

motion to dismiss; (2) did not raise it as part of their directed verdict motion; (3) failed to

revisit its directed verdict motion at the conclusion of evidence; and (4) failed to raise the

rule until its final reply in support of its motion for judgment notwithstanding the verdict.

{¶30} With respect to TRAX’s first contention, a review of appellants’ pretrial

motion to dismiss the complaint demonstrates they raised the issue as to all tort claims.

Although they did not specifically use the economic-loss-rule nomenclature, they did

argue the complaint should be dismissed because TRAX was seeking purely economic

damages in tort against OHM and Mr. Esser, parties with whom it had no privity of

contract. In this respect, we conclude the motion to dismiss was sufficient to preserve

the legal issue for appeal.

{¶31} Further, because the issue was preserved, the judgment denying the

dismissal was appealed, and the issue of the application of the economic-loss rule is a

question of law, we additionally conclude, even assuming appellants failed to raise the

issue anew at the points identified by TRAX, the matter was not waived.

{¶32} “The economic-loss rule generally prevents recovery in tort of damages for

purely economic loss.” Corporex Dev. & Const. Mgmt Inc. v. Shook, Inv., 106 Ohio St.3d

13

Case Nos. 2020-L-113, 2020-L-127, 2021-L-008
412, 2005-Ohio-5409, ¶6. “‘[T]he well-established general rule is that a plaintiff who has

suffered only economic loss due to another’s negligence has not been injured in a manner

which is legally cognizable or compensable.’” Chemtrol Adhesives, Inc. v. Am. Mfrs. Mut.

Ins. Co., 42 Ohio St.3d 40, 45 (1989), quoting Nebraska Innkeepers, Inc. v. Pittsburgh–

Des Moines Corp., 345 N.W.2d 124, 126 (Iowa 1984). This rule stems from the

recognition of a balance between tort law, designed to redress losses suffered by breach

of a duty imposed by law to protect societal interests, and contract law, which holds that

“parties to a commercial transaction should remain free to govern their own

affairs.” Chemtrol, supra, at 42; see, also, Floor Craft Floor Covering, Inc. v. Parma

Community Gen. Hosp. Assn., 54 Ohio St.3d 1, 7 (1990), quoting Sensenbrenner v. Rust,

Orling & Neale Architects, Inc., 236 Va. 419, 425 (1988). “‘Tort law is not designed * * *

to compensate parties for losses suffered as a result of a breach of duties assumed only

by agreement. That type of compensation necessitates an analysis of the damages which

were within the contemplation of the parties when framing their agreement. It remains the

particular province of the law of contracts.’” Floor Craft, supra, at 3, quoting

Sensenbrenner, supra.

{¶33} In effect, the economic-loss rule separates contract and tort claims by

preventing a plaintiff from bringing a tort claim when the matter is properly resolved in

contract. See Corporex, supra, at ¶6. The crucial difference between the law of tort and

contracts is the source of the duty imposed. Contractual duties emanate from bargained-

for agreements between specific parties who allocate risks and benefits. See Floor Craft,

supra, at 7. Alternatively, tort duties arise from public policy considerations. That is,

“[t]ort law offers redress for losses suffered by reason of a breach of some duty imposed

14

Case Nos. 2020-L-113, 2020-L-127, 2021-L-008
by law to protect the broad interests of social policy.” Morgan v. Mikhail, 10th Dist.

Franklin Nos. 08AP-87 and 08AP-88, 2008-Ohio-4598, ¶62, citing Floor Craft, supra. Put

simply, the law of tort protects people and property from injury, while the law of contract

protects parties’ bargained-for expectations. Morgan, supra.

{¶34} If a plaintiff suffers only economic losses, a court must consequently

determine the source of the duty that forms the basis of the action. See Corporex, supra,

at ¶10. A plaintiff may pursue such a tort claim if it is “based exclusively upon [a] discrete,

preexisting duty in tort and not upon any terms of a contract or rights accompanying

privity.” Corporex, supra at ¶9. Consequently, the economic-loss rule would not bar a

plaintiff from bringing a tort where the tort duty is independent of the contract. The issue,

therefore, is whether, irrespective of the substantive evidence presented at trial,

appellants had a duty not to defraud TRAX which was independent of the contract giving

rise to TRAX’s involvement in the Project. We hold such a duty exists.3

{¶35} The societal interest in protecting people from fraud is fundamental and

reflected by the civil and criminal liability imposed for such acts or omissions. Hanamura-

Valashinas v. Transitions by Firenza, LLC, 11th Dist. Lake No. 2019-L-089, 2020-Ohio-

4888, ¶37. No societal interest is served by promoting either the concealment of material

facts with the intent to mislead or the affirmative flow of information not genuinely believed

by its source to be true. Hence, we hold public policy is best served by acknowledging

an independent duty not to commit fraud and leaving open the potential of an intentional

3. It is important to note that the seminal economic loss rule cases cited by appellants concern
negligence claims, not intentional torts, such as fraud. See Corporex, supra; Floor Craft, supra; Chemtrol
Adhesives, Inc., supra. In this respect, those cases are factually different than this matter, which alleged
an intentional tort – a matter outside the economic loss rule to the extent it is premised upon a duty
independent of the contract at issue.
15

Case Nos. 2020-L-113, 2020-L-127, 2021-L-008
tort suit to loom over a party considering actual fraud. This conclusion is consistent with

other cases with similar fact patterns. See Eysoldt v. ProScan Imaging, 194 Ohio App.3d

630, 2011-Ohio-2359, ¶21 (1st Dist.) (“the economic-loss doctrine does not apply to

intentional torts.”); Hanamura-Valashinas, supra (wherein this court concluded the

falsification of billing statements violated a duty independent of the construction

agreement and so provided grounds for a claim of fraud not barred by the economic-loss

rule); see also Windsor Med. Ctr., Inc. v. Time Warner Cable, Inc., 5th Dist. Stark No.

2020CA00085, 2021-Ohio-158, ¶27 (fraud claims are “exempt” from the economic-loss

doctrine). We therefore conclude the trial court did not err, as a matter of law, in denying

the pretrial motion to dismiss; the motion for directed verdict; and its motion for judgment

notwithstanding the judgment as the economic loss rule did not bar TRAX’s fraud claim.

{¶36} With the foregoing in mind, appellants suggest the fraud claim was

improperly premised upon the breach of ethical obligations, which, in their view, cannot

serve as the basis for imposing an actionable duty of care under the law. Regardless of

the accuracy of this legal premise, any alleged breach of ethical standards (which were

addressed at length during Mr. Esser’s and Mr. Lewis’ cross-examination) was not the

basis of the intentional tort. Rather, as discussed above, the obligation not to commit

fraud, which the jury determined appellants violated, was the independent source out of

which liability was premised.

{¶37} We recognize that TRAX went to great lengths to illustrate how the OHM

defendants’ acts or omissions violated professional duties; still, this testimony was elicited

prior to the trial court’s granting appellants’ motion for directed verdict on TRAX’s

negligence claim. In other words, the testimony may have been initially offered to help

16

Case Nos. 2020-L-113, 2020-L-127, 2021-L-008
establish the OHM defendants were negligent in their management of the Project.

Because, however, that claim was subsequently dismissed, it was no longer material to

that theory. Still, the testimony was probative to the extent it served to establish that the

OHM defendants were not operating above professional reproach throughout their

administration of the Project. In this respect, the fraud claim was not premised upon an

ethical duty of disclosure, but evidence of the alleged breach of that duty (or other

professional obligations) provides evidence of potential fraud. Because the basis of

liability was the breach of the independent duty not to commit fraud, not the breach of

professional ethical duties, appellants’ suggestion is without merit.

{¶38} Finally, appellants further argue that if this court determines the economic-

loss rule does not bar TRAX’s fraud claims, the professional-design community will suffer

the peril of significantly increased business-related costs and be exposed to heightened

litigation risks which, in many cases, could be frivolous. The specter of the slippery slope

does not dissuade this court’s position. Fraud is an intentional tort which requires

heightened pleading requirements and, as with any intentional tort, proof. Furthermore,

a plaintiff can bring a fraud claim without subverting contract law because the viability of

such a claim depends only upon a defendant’s conduct, not the type of damage or the

existence of an underlying contract. In this respect, professional designers need only

meet the standard of care they owe all clients and adhere to the general duty not to

defraud in order to avoid exposure to liability. In short, the best way to minimize the costs

and burdens identified by appellants is to require the party with the best access to

information to disclose the information. An otherwise innocent, nonbreaching party

17

Case Nos. 2020-L-113, 2020-L-127, 2021-L-008
should not bear the burden of trying to police potentially deceitful conduct that society, as

a whole, detests.

{¶39} Appellants’ first assignment of error lacks merit.

{¶40} For their second assignment of error, appellants allege:

{¶41} “The trial court committed reversible error by denying the motion for directed

verdict (TTr pp 648-649) and the motion for JNOV (10/21/20 journal entry) with respect

to plaintiff TRAX’s fraud claims because TRAX failed to present competent and credible

evidence on every essential element.”

{¶42} Initially, when the court denies a motion for a directed verdict at the close of

a plaintiff's case-in-chief, the disappointed party must renew the motion at the close of all

the evidence in order to preserve it for appeal. See Chem. Bank of New York v. Neman,

52 Ohio St.3d 204, 207 (1990) (finding that a plaintiff “waived any claim of error in the

denial of the directed verdict by failing to renew his motion at the close of all evidence”).

At the close of evidence, the OHM defendants moved for a directed verdict only on the

Village’s claims against them. They did not renew their motion against TRAX and, in this

respect, the arguments, as they relate to the trial court’s initial denial of the motion for

directed verdict are forfeited. Nevertheless, because the arguments asserted in the

motion for judgment notwithstanding the verdict challenge the same points, namely,

TRAX’s proof, we shall address them accordingly.

{¶43} The elements of a claim of fraudulent concealment requires sufficient,

credible evidence of the following elements:

{¶44} “(a) a representation or, where there is a duty to disclose, concealment of

a fact, (b) which is material to the transaction at hand, (c) made falsely, with knowledge

18

Case Nos. 2020-L-113, 2020-L-127, 2021-L-008
of its falsity, or with such utter disregard and recklessness as to whether it is true or false

that knowledge may be inferred, (d) with the intent of misleading another into relying upon

it, (e) justifiable reliance upon the representation or concealment, and (f) a resulting injury

proximately caused by the reliance.” (citation omitted). Groob v. KeyBank, 108 Ohio

St.3d 348, 2006-Ohio-1189, ¶47.

{¶45} Appellants first contend there was no fiduciary relationship between the

OHM defendants and TRAX. At most, they concede an arm’s-length business

relationship existed between the parties; this, however, does not rise to a fiduciary

relationship. While appellants are correct that the parties’ business relationship was not

a special relationship rising to a fiduciary association, this does not undermine TRAX’s

proof on the first element of fraud.

{¶46} Generally, in business transactions, each party is presumed to have the

opportunity to ascertain relevant facts, and therefore, neither party has an obligation to

disclose material information to the other. Blon v. Bank One, 35 Ohio St.3d 98, 101

(1988). A duty to disclose arises in business dealings, however, when the parties are in

a fiduciary relationship, both parties to the transaction understand that a special trust or

confidence has been reposed, or full disclosure is necessary to dispel misleading

impressions that are or might have been created by partial revelation of the facts. Id.; see,

also, Word of God Church v. Stanley, 2d Dist. Montgomery No. 07-CV-4467, 2011-Ohio-

2073, ¶26-27; Gator Dev. Corp. v. VHH, Ltd., 1st Dist. Hamilton No. C-080193, 2009-

Ohio-1802, ¶28; Levy v. Seiber, 12th Dist. Butler Nos. CA2015-02-019, CA2015-02-021,

and CA2015-02-030, 2016-Ohio-68, ¶31. For instance, a party must speak upon failing

“‘to exercise reasonable care to disclose a material fact which may justifiably induce

19

Case Nos. 2020-L-113, 2020-L-127, 2021-L-008
another party to act or refrain from acting, and the nondisclosing party knows that the

failure to disclose such information to the other party will render a prior statement or

representation untrue or misleading.’” State v. Warner, 55 Ohio St.3d 31, 54, (1990),

quoting Miles v. McSwegin, 58 Ohio St.2d 97, 100 (1979)

{¶47} Furthermore, we recognize that “the mere failure to disclose a fact is not

equivalent to concealment, which implies a purpose or design.” Jenkins v. Clark, 7 Ohio

App.3d 93, 101 (2d Dist.1982). “Silence[, however,] will constitute a misrepresentation *

* * if the circumstances are such that the law recognizes a duty to speak.” Schulman v.

Wolske & Blue Co., L.P.A., 125 Ohio App.3d 365, 372 (10th Dist.1990); see also Miles,

supra, at 99 (an action for fraud may be based upon “the failure of a party to a transaction

to fully disclose facts of a material nature where there exists a duty to speak.”) Put

differently, “within the context of the law of fraud, where there is a duty to disclose, silence

alone may constitute concealment.” PYA/Monarch, Inc. v. Horner, 72 Ohio App.3d 791,

793 (3d Dist.1991). Under the circumstances, the jury could conclude that full disclosure

was necessary to dispel misleading or false impressions created by partial revelation of

facts on OHM’s behalf such that a duty to disclose was created. See Stanley, supra.

{¶48} At trial, although Mr. Hines testified he never assured Mr. Valletto the

change orders, which occurred as a result of design problems, would be paid, Mr. Valletto

testified to the contrary. Mayor Alonso testified that if OHM approved payments, the

Village would pay. As of November 28, 2017, almost a month after the originally

scheduled completion date, Mr. Valletto stated TRAX had not received any payment.

And, on December 12, 2017, TRAX again inquired into the processing of payment

applications; Mr. Hines responded that OHM would only discuss extensions of the

20

Case Nos. 2020-L-113, 2020-L-127, 2021-L-008
completion date and nothing else. Mr. Valletto stated that had he known TRAX would not

be paid (or, by circumstantial implication, payment would be such a strenuous process),

it would have stopped work instead of incurring greater expense.

{¶49} Mr. Esser recognized that, acting as the Project’s manager, OHM owed

TRAX various duties: “integrity, honor, and the dignity of the engineering profession”; the

obligation to issue truthful statements; and to deal fairly and honestly and to keep TRAX

fully informed regarding the Project. Moreover, TRAX continued to work in reliance on

Mr. Hines’ assurances of payment. It regularly communicated its concern with the lack

of transparency regarding payment and/or the payment application process. If there were

issues internal to OHM’s ability to approve the applications, it was obligated to notify

TRAX or, at least, respond to TRAX’s repeated inquiries regarding payment as well as

the Project’s overall status.

{¶50} Also, an email, sent by Mr. Hines (or some agent of OHM) to the

transitioning project manager in December 2017, stated that the former must speak to the

latter “verbally” to discuss the Project. This suggests that OHM desired to avoid a “paper

trail” regarding the Project’s progress and ultimate completion – matters to which TRAX

never had access (despite numerous inquiries directed at both OHM and the Village) and

never would have access due to its eventual termination for convenience in favor of a

third-party contractor, Trimor. Trimor is a company owned by a friend and former

business associate of Mr. Esser.

{¶51} The evidence was sufficient to establish that OHM did not fully and

accurately disclose the inner-workings of the change order/payment application process,

yet full disclosure would have dispelled any misleading impressions on behalf of TRAX.

21

Case Nos. 2020-L-113, 2020-L-127, 2021-L-008
There was also sufficient evidence that TRAX could have been terminated for

convenience much earlier, saving it significant time and resources; instead, due to OHM’s

failure to disclose material points regarding the Project’s direction and progress as well

as TRAX’s reliance on Mr. Hines’ representations vis-à-vis payment, it remained on site,

expecting to complete the work at OHM’s direction. TRAX presented adequate, credible

evidence to establish OHM misrepresented or concealed facts, material to the Project

and its work, that were made either falsely or with reckless disregard to the truth or falsity

and the reasonable inferences that could be drawn from the misrepresentation(s) or

concealment(s).

{¶52} Next, appellants contend TRAX failed to establish direct evidence of

fraudulent intent.

{¶53} Initially, TRAX was not required to provide direct evidence of intent to

defraud. Courts have noted that establishing fraudulent intent by direct evidence is

difficult; as a result, circumstantial evidence may be used to establish intent to defraud.

Doyle v. Fairfield Mach. Co., 120 Ohio App.3d 192, 208 (11th Dist.1997); Davis v. Sun

Refining & Mktg. Co., 109 Ohio App.3d 42, 56 (2d Dist.1996).

{¶54} With this in mind, TRAX presented evidence that it sent numerous written

communications to OHM and the Village; neither OHM nor the Village directly or

materially responded to TRAX’s concerns regarding payment applications, processing of

change orders, deadline extensions, or the status of the Project. Although OHM offered

testimony that on-site, verbal conversations occurred regularly, the substance of these

conversations is relatively unknown. Furthermore, the letters routinely sought meetings

with OHM and the Village – only two progress meetings, however, occurred throughout

22

Case Nos. 2020-L-113, 2020-L-127, 2021-L-008
TRAX’s time on the Project. Moreover, Mr. Esser testified he was OHM’s designated

contractual contact with TRAX as well as the Project Manager; he additionally testified he

did not agree with TRAX’s representations (in its letters) regarding its concerns that there

were significant design errors in OHM’s plans. Still, he did not contact any TRAX

representative to discuss the matter.

{¶55} Additionally, TRAX contacted OHM (including Mr. Esser) and stated it was

concerned with expenses relating to unforeseen delays on the Project and costs

associated with its idle equipment. And, although Mr. Esser stated he was unsure why

TRAX could not continue with “other work” during the idle time, he agreed that TRAX was

entitled to notice that either OHM or the Village did not believe it was entitled to

compensation for the idle time. No such communication occurred.

{¶56} Further, eventually, in late December, TRAX notified OHM and the Village

it considered itself on “indefinite standby” by being forced to finance costs of extra work

due to delays and other interferences; notwithstanding these remarkable concerns, TRAX

received no response. From these points, the jury could infer appellants intended to

keep information regarding the Project from TRAX and keep it on the Project as long as

it could without processing its paperwork or financing the additional work or idle time.

This is a particularly strong inference given that OHM admittedly disagreed with some of

TRAX’s concerns, but did not reach out, let alone meet with its representatives despite

multiple requests.

{¶57} Moreover, during his deposition, Mr. Esser stated he had information on his

company lap-top and he would provide the same to TRAX. This information, whatever it

was, was never produced and was ostensibly lost. Even though the content of the

23

Case Nos. 2020-L-113, 2020-L-127, 2021-L-008
information was unknown, TRAX and Mr. Esser were aware of its existence, TRAX was

told Mr. Esser would produce it, and it was never produced and potentially lost. The jury

could draw the circumstantial inference that, in light of these and other points, the

information was intentionally lost.

{¶58} Additionally, a December 17, 2017 email sent by Mr. Hines to Mr. Tucker,

after Mr. Tucker was installed as Project Manager, stated the former wished to speak with

the latter regarding the Project. It also stated, however, that communication should be

verbal rather than written. The jury could infer that this email was an effort to avoid the

creation of a paper trail regarding OHM’s strategy regarding further administration of the

Project. Mr. Hines denied writing the email, but OHM ultimately admitted the message

came from OHM’s server. In light of OHM’s reluctance to respond to TRAX’s numerous

letters regarding change orders, payment, delay, and concerns on idle equipment and

time, this email could be reasonably viewed to show an intent to deceive or conceal

material information from TRAX regarding its status on the Project.

{¶59} Regarding TRAX’s justifiable reliance, Mr. Esser, Mr. Lewis, and Mr. Hines

agreed that TRAX was entitled to rely upon OHM’s designs and representations as well

as its professional duty to be honest and respond appropriately to TRAX’s written

concerns. And Mr. Valletto testified Mr. Hines stated TRAX had the right to rely upon

payment in relation to payment applications and change orders. Although Mr. Hines

disputed he made any such assurance, the jury was entitled to weigh the testimony and

elected to believe TRAX’s evidence. There was thus sufficient, credible evidence on the

element of reasonable and justifiable reliance.

24

Case Nos. 2020-L-113, 2020-L-127, 2021-L-008
 {¶60} Finally, appellants claim TRAX failed to establish damages proximately

resulting from the foregoing elements. Appellants essentially claim TRAX only

established “contract damages,” not “fraud damages.” We find this distinction of little

import.

{¶61} Initially, TRAX, via its Exhibit 33, provided the following evidence of

damages:

{¶62} Outstanding Line Items and Pay: $65,459.47; Request Discrepancies

Retainage Owed: $82,852.25; Change Order Amounts Owed: $308,021.27; Claims

Submitted Including Home Office, Stand-By: $590,218.85; Estimated Interest Owed:

$15,000.00. These damages totaled $1,061,551.84.

{¶63} This court has held that even if a plaintiff seeks damages against one party

for a breach of contract, that plaintiff may still recover against another party in tort, even

if the damages overlap. Kent State Univ. v. Bradley Univ., 11th Dist. Portage No. 2017-

P-0056, 2019-Ohio-2088, ¶78. Specifically, this court, adopting the reasoning of the First

and Twelfth Appellate Districts, observed “‘“the mere existence of a plaintiff’s inchoate

cause of action against one party for breach of contract does not foreclose an action in

tort against another party for all damages suffered by reason of the latter’s inducement of

such a breach.”’” Id., quoting Ginn v. Stonecreek Dental Care, 12th Dist. Fayette No.

CA2016-10-014, 2017-Ohio-4370, ¶16, quoting Davison Fuel & Dock Co. v. Pickands

Mather & Co., 54 Ohio App.2d 177 (1st Dist.1977). Accordingly, even if the calculated

damages were initially a function of a breach of contract, they were still recoverable in tort

to the extent TRAX met its burden that they were also a proximate result of appellants’

actions.

25

Case Nos. 2020-L-113, 2020-L-127, 2021-L-008
 {¶64} Moreover, the trial court instructed the jury that: “There may be more than

one proximate cause of the damages. The fact that some other cause combined with the

acts or omissions of a defendant in producing damage does not relieve a defendant from

liability so long as the plaintiff proves that the conduct of a defendant was a substantial

factor in producing the harm.” Appellants did not object to this instruction and, because

it reasonably reflects the law set forth above, we hold TRAX established, by a

preponderance of the evidence, that the damages were a proximate result of appellants’

acts or omissions.

{¶65} Finally, and notwithstanding the foregoing points, appellants cite cases

which suggest that fraud claims require definitive proof of damages separate from and in

addition to economic damages attributable to a breach of contract. See Textron Fin.

Corp. v. Nationwide Mut. Ins. Co., 115 Ohio App.3d 137, 150-153 (9th Dist.1996);

Strategy Group for Media, Inc. v. Lowden, 5th Dist. Delaware No. 12 CAE 03 0016, 2013-

Ohio-1330, ¶30-31; Dayton Children’s Hosp. v. Garrett Day, LLC., 2d Dist. Montgomery

No. 28047, 2019-Ohio-4875, ¶106-107. The first two of these cases involve fraud and

contract claims against same defendant; and in the third, although various defendants

were named, the court indicated the plaintiffs were unable to establish an independent

duty beyond the contract. These cases are therefore not analogous to the instant matter.

Here, the overlap between TRAX’s breach of contract claim against the Village and fraud

damages sought against appellants relate to distinct actors and, therefore, the breach of

contract claim does not bar the damages claimed resulting from appellants’ alleged fraud.

{¶66} Appellants’ second assignment of error is without merit.

{¶67} Appellants’ third assignment of error provides:

26

Case Nos. 2020-L-113, 2020-L-127, 2021-L-008
 {¶68} “The trial court clearly erred by denying a JNOV (10/21/20 Journal Entry)

with respect to punitive damages and attorney fees awarded to TRAX because the

awards were legally untenable and TRAX failed to satisfy the onerous burden of proof.”

{¶69} When reviewing a ruling on a motion for judgment notwithstanding the

verdict, we must construe the evidence most strongly in favor of the nonmoving party,

and where there is substantial evidence to support that side of the case, upon which

reasonable minds could reach different conclusions, the motion must be overruled.

Pelletier v. Rumpke Container Serv., 142 Ohio App.3d 54, 60 (1st Dist.2001). “Neither

the weight of the evidence nor the credibility of the witnesses is for the court’s

determination in ruling upon either motion.” Id.

{¶70} Punitive damages are designed to punish tortfeasors for losses caused by

actual malice and to deter similar conduct in the future. Whetsone v. Binner, 146 Ohio

St.3d 395, 2016-Ohio-1006, ¶15. Ohio law is well settled that punitive damages are

available for personal injury or property loss caused by malice or “‘“intentional, reckless,

wanton, willful and gross acts.”’” Rubeck v. Huffman, 54 Ohio St.2d 20, 23 (1978),

quoting Columbus Fin., Inc. v. Howard, 42 Ohio St.2d 178, 184 (1975), quoting the

appellants’ brief. Further, “[a]ttorney fees are proper when the court has awarded punitive

damages.” Boaeuf v. Memphis Station, L.L.C., 8th Dist. Cuyahoga No. 105799, 2018-

Ohio-745, ¶15.

{¶71} The trial court charged the jury accordingly:

{¶72} “Punitive damages may be awarded against the defendants as a

punishment to discourage others from committing similar wrongful acts. You are not

required to award punitive damages to TRAX Construction Company, and you may not

27

Case Nos. 2020-L-113, 2020-L-127, 2021-L-008
do so unless you find that TRAX Construction Company has met its burden to prove by

clear and convincing evidence that: (A) Defendants’ actions demonstrated actual malice;

or (B) Defendants’ actions demonstrated aggravated or egregious fraud.” The instruction

defined actual malice (a state of mind characterized by hatred, ill will, or a conscious

disregard for the rights and safety of others which creates the great possibility of

substantial harm), aggravated fraud (where fraud is accompanied by malice or ill will or if

it is particularly gross or malicious), and clear and convincing evidence (evidence

producing in the minds of the jurors a firm belief or conviction about the facts to be

proved).

{¶73} Appellants initially claim the punitive damages award fails because TRAX

failed to establish the requisite proof of fraud. As we previously concluded TRAX met its

burden on the predicate claim of fraud, appellants’ argument in this respect fails.

{¶74} The evidence adduced at trial could allow the jury to find, by clear and

convincing evidence, that appellants willfully, intentionally, or maliciously misrepresented

or concealed material facts that proximately cause the damages sought. The jury could

reasonably conclude that OHM kept TRAX on the Project, without transparently

communicating with it and/or ignoring its entreaties to discuss payment, change orders,

as well as the Project’s general direction. Appellants draw our attention to allegedly

misleading arguments made during closing that they claim improperly invited the jury to

engage in conspiratorial, inferential leaps. As just noted, there was sufficient testimonial

evidence to support TRAX’s fraud claim and, from this evidence, the jury could have

reasonably premised its determination that it was entitled to punitive damages, either

through a finding of actual malice or aggravated fraud. As we may not consider the weight

28

Case Nos. 2020-L-113, 2020-L-127, 2021-L-008
of the evidence or witness credibility when reviewing the denial of a JNOV, we conclude

TRAX advanced sufficient evidence to support the jury’s award of punitive damages and

the trial court’s order of attorney fees.

{¶75} Appellants’ third assignment of error lacks merit.

{¶76} Appellants’ fourth assignment of error provides:

{¶77} “The trial court committed reversible error by denying a motion for directed

verdict (TTr pp 785-786; 1/27/20 Judgment Entry) and a subsequent motion for JNOV

(10/21/20 Journal Entry) on VOR’s [The Village’s] legally defective cross-claim for

indemnification.”

{¶78} Appellants assert the trial court erred in denying its motion for directed

verdict and its motion for judgment notwithstanding the verdict on the Village’s indemnity

claim because the jury did not find it liable as a common tortfeasor and, even though it

was found liable for breach of contract, the jury awarded zero damages. As a result,

appellants assert their derivative claim for indemnification must fail as a matter of law.

{¶79} “Indemnity arises from contract, either express or implied, and it is the right

of a person, who has been compelled to pay what another should have paid, to require

complete reimbursement.” Worth v. Aetna Cas. & Sur. Co., 32 Ohio St.3d 238, 240

(1987). Implied indemnification “‘arises in favor of a person who without any fault on his

part is exposed to liability and compelled to pay damages on account of the negligence

or tortious act of another, the former having a right of action against the latter for

indemnity, provided they are not joint tort-feasors * * *.’” Maryland Cas. Co. v. Frederick

Co., 142 Ohio St. 605, 607 (1944), quoting 31 Corpus Juris., 447, Sec. 47.

29

Case Nos. 2020-L-113, 2020-L-127, 2021-L-008
 {¶80} First of all, the evidence demonstrated that although the Village and TRAX

entered into the contract for TRAX to be the underground utility contractor on the Project,

Mayor Alonso testified the OHM defendants oversaw the Project and dealt directly with

TRAX. There was no dispute that Mr. Esser was the Project Manager up through

December 2017 and Mr. Hines was the on-site contact between TRAX and OHM.

Moreover, the Mayor indicated that all payments the Village owed TRAX were considered

and approved by OHM prior to the Village releasing payment. Given the factual nature

of the relationship the Village had with TRAX, the jury’s determination that if the Village

was found liable for damages relating to the contract, it should be entitled to

indemnification from OHM is reasonable.

{¶81} In this matter, the Village is not a joint or common tortfeasor. And, while the

Village was found liable for breach of contract, the jury concluded that, given the context

of the case, TRAX suffered no damages that were the natural and probable result of the

Village’s breach. As such, the Village was responsible for no compensatory or punitive

damages. Because the Village was deemed to owe TRAX nothing, TRAX cannot pursue

the Village for damages and, as a result, the Village would never need to exercise its right

to indemnification. The indemnification verdict, therefore, has no effect. This, however,

does not imply the trial court erred in denying OHM’s motion for JNOV on the

indemnification verdict. Simply because the verdict has no practical effect does not mean

the jury erred in rendering it; it simply means the issue of indemnification, in light of the

zero damages award, is moot.

{¶82} As a general matter, courts will not resolve issues that are moot. In re

Brown, 10th Dist. Franklin No. 03AP-1205, 2005-Ohio-2425, ¶15. Actions are moot “when

30

Case Nos. 2020-L-113, 2020-L-127, 2021-L-008
they are or have become fictitious, * * * hypothetical, academic or dead. The distinguishing

characteristic of such issues is that they involve no actual genuine, live controversy, the

decision of which can definitely affect existing legal relations. * * * ‘A moot case is one

which seeks to get a judgment on a pretended controversy, when in reality there is none,

or a decision in advance about a right before it has been actually asserted and contested,

or a judgment upon some matter which, when rendered, for any reason cannot have any

practical legal effect upon a then-existing controversy.’” Grove City v. Clark, 10th Dist.

Franklin No. 01AP-1369, 2002-Ohio-4549, ¶11, quoting Culver v. Warren, 84 Ohio App.

373, 393 (7th Dist.1948). The issue identified by OHM is merely academic and presents

a point which we can offer no meaningful remedy. We therefore conclude the issue raised

under this assignment of error is moot, and the trial court did not err in denying OHM’s

motion for JNOV on the Village’s indemnification claim.

{¶83} Appellants’ fourth assignment of error lacks merit.

{¶84} Appellants’ final assignment of error provides:

{¶85} “The trial court committed reversible error by refusing to order a new trial

(10/21/20 Journal Entry) on TRAX’s fraud claims and VOR’s [the Village’s] indemnity

cross-claim because the jury verdict was against the great weight of the evidence and

was the product of instructional error and attorney misconduct.”

{¶86} Appellants first argue the trial court improperly instructed the jury on TRAX’s

burden of proof; in their view, the proper standard for civil fraud is “clear and convincing

evidence,” not the lower, general civil proof of a “preponderance of the evidence.” We do

not agree.

31

Case Nos. 2020-L-113, 2020-L-127, 2021-L-008
 {¶87} “A party seeking an equitable remedy, such as declaratory judgment,

reformation or rescission of a contract, must prove a fraud claim with clear and convincing

evidence, while a party seeking a monetary remedy must prove fraud by

the preponderance of the evidence.” Andrew v. Power Marketing Direct, Inc., 10th Dist.

Franklin No. 11AP-603, 2012-Ohio-4371, ¶47, citing Household Finance Corp. v.

Altenberg, 5 Ohio St.2d 190 (1966), syllabus; see, also, Rider v. Rider, 11th Dist. Trumbull

No. 98-T-0202, 2000 WL 522349, *2 (Mar. 31, 2000) (“Since the present case does not

involve equitable relief but, instead, is an ordinary action at law for money damages based

upon fraud, the proper standard of proof is ‘preponderance of the evidence.’”). In this

case, because TRAX sought monetary damages, i.e., a legal remedy, the trial court

correctly instructed the jury the standard of proof is a “preponderance of the evidence.”

{¶88} Next, appellants assert the jury’s verdict on TRAX’s fraud claim is against

the manifest weight of the evidence.

{¶89} “[A]n appellate court will not reverse a judgment as being contrary to the

weight of the evidence as long as there is some competent, credible evidence supporting

the judgment.” In re Kangas, 11th Dist. Ashtabula No. 2006-A-0084, 2007-Ohio-1921,

¶81. The manifest-weight standard of review is the same in a civil case as in a criminal

case. Eastley v. Volkman, 132 Ohio St.3d 328, 2012-Ohio-2179, ¶17.

{¶90} When applying the manifest-weight standard of review, the reviewing court

reviews the entire record, “‘weighs the evidence and all reasonable inferences, considers

the credibility of witnesses and determines whether in resolving conflicts in the evidence,

the [finder of fact] clearly lost its way and created such a manifest miscarriage of justice

that the [judgment] must be reversed and a new trial ordered.’” Id. at ¶20,

32

Case Nos. 2020-L-113, 2020-L-127, 2021-L-008
quoting Tewarson v. Simon, 141 Ohio App.3d 103, 115, (9th Dist.2001). “The finder of

fact is entitled to believe all, part, or none of the testimony of any witness.” River Oaks

Homes, Inc. v. Twin Vinyl, Inc., 11th Dist. Lake No. 2007-L-117, 2008-Ohio-4301, ¶27.

{¶91} “Under the manifest weight standard of review, we are ‘guided by a

presumption’ that the fact-finder’s findings are correct.” Terry v. Kellstone, Inc., 6th Dist.

Erie No. E-12-061, 2013-Ohio-4419, ¶13, citing Seasons Coal Co. v. Cleveland, 10 Ohio

St.3d 77, 79-80 (1984). See also Eastley, supra, at ¶21. We must make “‘every

reasonable presumption * * * in favor of the judgment and the finding of facts.’

” Id., quoting Seasons Coal Co. at 80, fn. 3. “‘If the evidence is susceptible of more than

one construction,’” we are “‘bound to give it that interpretation which is consistent with the

* * * judgment [and] most favorable to sustaining the * * * judgment.’” Eastley,

supra, quoting Seasons Coal Co., supra.

{¶92} As discussed under appellants’ second and fourth assignments of error, the

jury’s verdicts on TRAX’s fraud count and the Village’s indemnification count are

supported by sufficient, credible evidence. OHM, via its representatives, presented

competing testimony and attempted to explain the reasons why the Project went in a

direction which led to the underlying suit. The jury was able to evaluate OHM’s, Mr.

Esser’s, the Village’s and TRAX’s acts and omissions. In doing so, if found OHM and Mr.

Esser liable for fraud and determined that the Village was entitled to indemnification, to

the extent such was required. We cannot conclude the jury lost its way or the result of the

trial resulted in a manifest miscarriage of justice.

{¶93} Finally, appellants claim TRAX’s counsel and the Village’s counsel

embraced a “scorched earth” strategy during closing by launching personal attacks on

33

Case Nos. 2020-L-113, 2020-L-127, 2021-L-008
witnesses, creating false flags, asserting baseless conspiracy theories, and requesting

the jury to draw negative inferences against them. Appellants assert this strategy was

designed to mislead, influence, and inflame the jury in way that would compel a verdict

against them. In this respect, appellants contend the jury did not render a verdict based

upon the evidence, but accepted counsels’ invitation to make its decision on passion and

bias. We do not agree.

{¶94} Appellants point to various phrases used by TRAX’s counsel they deem

troublesome, e.g., “cone of silence,” “missing” flash drive, “snowed fraud in the

courtroom,” “liar,” and “took advantage of the small guy.” Although counsel may not

comment on his or her personal belief regarding the evidence, these comments, when

viewed in relationship to the closing as a whole, do not rise to the level of misconduct.

Indeed, a review of counsels’ respective closings reveal little in the way of any

grandstanding or commentary that might be considered unfair or prejudicial. In effect,

appellants overstate the purported problematic content counsels’ rhetoric and argument

in closing.

{¶95} Moreover, appellants assert that TRAX’s counsel improperly asserted Mr.

Esser engaged in the spoliation of evidence, in violation of a pre-trial motion in limine. In

closing, counsel does mention that Mr. Esser failed to provide certain evidence that was

previously on an OHM thumb drive and connects this point to other evidence which

supported TRAX’s theory that the OHM defendants were fraudulently concealing material

information from it. Still, no objection was leveled at this line of argument and appellants

did not renew their motion in limine at trial. It is axiomatic in Ohio that “[a] motion in limine

is tentative and precautionary in nature, reflecting the court’s anticipatory treatment of an

34

Case Nos. 2020-L-113, 2020-L-127, 2021-L-008
evidentiary issue at trial. * * * Finality does not attach when the motion is granted. * * *

(Citations omitted.)” Defiance v. Kretz, 60 Ohio St.3d 1, 4 (1991). Thus, “a motion in

limine is a prospective order and makes no determination as to the ultimate admissibility

of the evidence.” Krosky v. Ohio Edison Co., 20 Ohio App.3d 10 (9th

Dist.1984), paragraph five of the syllabus. As there was no renewed objection, we

decline to find error in counsels’ angle of argumentation.

{¶96} “‘“A [party] may freely comment in closing argument on what the evidence

has shown and what reasonable inferences the [party] believes may be drawn

therefrom.”’” Torres v. Concrete Designs, 8th Dist. Cuyahoga Nos. 105833 and 106493

2019-Ohio-1342, ¶19, quoting Peffer v. Cleveland Clinic Found., 8th Dist. Cuyahoga No.

94356, 2011-Ohio-450, ¶27, quoting State v. Clay, 181 Ohio App.3d 563, 2009-Ohio-

1235, ¶47 (8th Dist.). In our view, counsels’ comments during closing were not so

suspect or inflammatory to justify a finding of misconduct. We therefore conclude that the

verdict, which was explained via post-trial jury interrogatories, was based not upon

counsels’ closing, but upon the evidence submitted during the trial.

{¶97} Appellants’ fifth assignment of error lacks merit.

{¶98} For the reasons discussed in this opinion, the judgment of the Lake County

Court of Common Pleas is affirmed.

MARY JANE TRAPP, P.J.,

MATT LYNCH, J.,

concur.

35

Case Nos. 2020-L-113, 2020-L-127, 2021-L-008