— This is an action brought upon an instrument in writing, which is as follows:
*411“Exhibit TB.’
“Enow all men by these presents, that we, John P. Vollmer, of Lewiston, Idaho territory, and H. S. Huson, of Tacoma, state of Washington, are held firmly bound unto Eupert Sehupfer, of Juliaetta, Idaho territory, in the sum of six thousand dollars ($6,000), to be paid to the said Eupert Sehupfer, his executors, administrators, or assigns, for which payment well and truly to be made we bind ourselves, our heirs, administrators, executors, and assigns, jointly and severally, by these presents. Sealed with our seals, and dated this fourteenth day of June, A. D. 1890. The condition of the above obligation is the executing and delivering to J. P. Vollmer by said Eupert Sehupfer of a deed to certain town lots in the town of Juliaetta, Latah county, Idaho territory, bearing date of 14th of June, 1890, which said deed has been executed and delivered. The condition of above obligation is such that if the above bounden obligors shall on or before the first day of January, 1891, construct or cause to be constructed a railroad to said town of Juliaetta, with sidetrack, and on or before May 29, 1891, construct or cause to be constructed a depot adjacent to said sidetrack in the northwest quarter of the southwest quarter of section three (3), township 37 north, range 3 west, Boise meridian, Latah county, Idaho territory, then this obligation be null and void; otherwise to remain in full force and effect. JNO. P. VOLLMEE,
“H. S. HUSON
“Witnesses:
“C. E. HUSON
“C. O. VAN AESDEL.”
Plaintiff had judgment in the district court for $6,000, and interest at ten per cent per annum from January 1, 1891. This appeal is from the judgment and the order denying a .new trial.
The principal contention here is upon the construction of the instrument in writing above set forth. It is contended by the respondent that said writing is an alternative contract for the sale of land, while appellants claim that it is a bond for dhe construction of a railroad, etc. Counsel for respondent has *412presented us with an able, ingenious, and voluminous brief and argument in support of his contention. It will be conceded, we apprehend, that, in construing written instruments of this-kind, the court should endeavor to give them that interpretation which will carry out the intention of the parties as understood by them at the time the writing was executed; and, should there be any ambiguity in the writing, the court will resort to the circumstances under which it was made, and which prompted its execution. Upon its face this writing seems to us to be a bond to secure the performance of certain, services, to wit, the building of a railroad to the town of Juliaetta, in the county of Latah, state of Idaho. The facts, as they appear from the record, are substantially as follows: On the fourteenth day of June, 1890, one Rupert Schupfer was the owner of a certain tract of land in the town of Juliaetta, aforesaid. Being desirous of increasing the value of said land, he made an arrangement with John P. Yollmer, one of the appellants, whereby it was agreed between them that, in consideration of the conveying to him, the said Yollmer, by said Schupfer, of eighty-five lots of land, presumably a portion of the land heretofore mentioned as being owned by(1said Schupfer in the town of Juliaetta, said Yollmer agreed to construct, or cause to be constructed, a railroad to said town of Juliaetta by the first day of January, 1891, and to construct, or cause to be constructed, by the twenty-ninth day óf May, 1891, certain sidetracks and depot. It is conceded that the railroad, depot, and sidetracks were not constructed and completed, by the first day of January, 1891, the time stipulated in the bond or writing, but that they were fully completed by the first day of June, 1891. No objection was ever made-by Schupfer on account of the failure of Vollmer to finish the construction of the railroad, etc., by the time stipulated in the bond. One of the benefits resulting from the construction of the railroad was the construction of the tram-way owned by the respondent, in which construction it is claimed it expended about $25,000, and an increase in value of the real estate of Schupferabout one hundred per cent, as stated. It does not appear that any exception was ever taken by Schupfer to the failure of Yollmer to complete the railroad, etc., within the time speci*413fled. On or about tbe twenty-fifth day of August, 1893, Schupfer assigned said bond to the respondent; and on the twenty-■seventh day of October, 1893, this suit was instituted. This seems to have been the first intimation that respondent had of •any claim against it for failure to complete the work in the time stipulated. The instrument, upon its face, purports to be a bond given by Vollmer and ITuson to secure the performance of certain services to be performed by Vollmer. No part •of the consideration for the services to be performed runs to Huson. There is no description of the lands conveyed, nor of the railroad, etc., to be constructed. In fact, the instalment •contains none of the usual reqaiisites of a contract for the conveyance of land. The land was already conveyed, the contract, so far as Schupfer was concerned, was executed, and the ■consideration paid, and, to secure performance on the part ■of Vollmer, the bond was executed on the part of Vollmer and Huson, wherein the penalty for nonperformance was fixed at $6,000 — a common, ordinarjr business transaction, the anticipated benefits flowing from whicli the obligee had received in full before the assignment of the bond by him to the respondent.
We have examined with much care the most of the cases cited by the respondent, but have found none which militate against the conclusion we have reached. In the case of City of Indianola v. Gulf etc. Ry., 56 Tex. 594, which seems to be one of the cases most confidently relied upon by counsel, there was a failure to complete the road at all in accordance with the agreement. There was no question of time in the Texas case. There was a complete and absolute failure and refusal to complete the road. And the same may be said of the case of Pearson v. Williams, 26 Wend. 630. It nowhere appears in the record that $6,000 was the agreed price of the lots conveyed by Schupfer to Vollmer, or that the sum was the estimated value of said lots. The proposition that the $6,000 expressed in the bond was intended either as the price of the land, if the instrument should be construed as an alternative contract for the sale of land, or as stipulated damages should the writing turn out to be what upon its face it was clearly intended for, to wit, a bond for the building of a railroad, *414while it seems to have obtained lodgment with the district court, we cannot recognize. There is nothing in the complaint that would support a judgment for damages, and it does not. appear that the question of damages was raised or inquired into on the trial. The case was instituted and tried upon the theory that the instrument sued upon is an alternative contract for the sale of land, and it is upon that theory that recovery must be had, if at all. In the case of Railroad Co. v. Alderman, 47 Mo. 349, the court- says: “It is admitted that the road has been built, and that the benefits sought to be derived from it, and which were the inducements that led to the subscription here, accrued; and, when such is the case, a party will not be allowed to shirk a just responsibility on such a pretext”; i. e., that the road was not completed within the stipulated time. This rule is peculiarly applicable to the case under consideration, and with it we are in accord.
It is claimed by appellants that respondent failed to prove-its corporate existence. We do not think that contention is-supported by the evidence. There are some other questions, raised by the record, but we do not deem them essential to a decision of this case. Our conclusion is that the instrument, sued upon is a bond for the performance of the services therein stated, to wit, the constructing of a railroad to the town of . Juliaetta, and construction of certain sidetracks and depot in connection therewith, and that such was intended to be the-. object and purport of the instrument by all the parties thereto . at the time of its execution; that time was not understood or agreed to be of the essence of the contract at the time it was-made by any of the parties; that the condition of the bond . has been fully and entirely filled by the obligors; and that the same was recognized and acquiesced in by the original obligee for two years. The judgment of the district court is. reversed, with directions to enter judgment for defendants» costs to appellants.
Case No. 26, same title as this case, being between same parties, and in relation to same subject matter, was by agreement, of counsel, heard together with this case; and, it being stipulated that the judgment in one case should obtain in both, the-*415same judgment will be entered in each case, except that, there being no necessity for separate appeals from the judgment and the order denying the motion for a new trial, the costs of this-appeal are awarded to respondent.
Morgan, C. J., and Sullivan, J., concur.