(dissenting):
The plaintiffs are the owners of adjoining parcels of land situate on the northerly side of Twenty-second street, extending easterly from the easterly side of Thirteenth avenue, in the city of Mew York. Pursuant to a general scheme of improvement of the Morth river water front from Bloomfield street to Twenty-third street, in the interest of commerce and navigation, plans were duly adopted by the department of docks and ferries, and further approved by the commissioners of the sinking fund, in conformity with sections 817 and 819 of the Greater Mew York charter (Laws of 1897, chap. 378, as amd. by Laws of 1901, chap. 466.) Upon these plans certain proposed changes were shown which included dredging and bulkheading work to be done in both Thirteenth avenue and Twenty-second street. On October 17,1902j the city acquired title by condemnation to the property on the southerly side of Twenty-second street, as well as to the bulkhead on the westerly side of Thirteenth avenue between Twenty-second and Twenty-third streets, whereof the Erie railroad was then in possession, it being also the lessee of plaintiffs’ premises. On Movember 6,1902, the city entered into a contract with the defendant R. G. Packard Company, whereby the latter was to dredge the land south of the southerly line of Twenty-second street, and also northerly a distance of thirty-five feet from said southerly line. The dredging was to be done to a depth of thirty feet below mean low-water level, the elevation of the land prior thereto being about four feet above that level. West Twenty-second street was a regularly paved public street, and was sixty feet in width.
The work under this contract was begun on or about January 1, 1903. During its progress, and as a direct result of the operation of the dredge entirely within the line of the city’s property and on the street (for the line of the dredging never, came any nearer than *584twenty-five-feet to the line of the plaintiffs’ property), and because of the nature of the soil on the plaintiffs’ property (which was made ground, composed of dirt and rubbish), there fell into the excavation made by the dredging operations a.quantity of plaintiffs’ land about equal in width on the surface to the'depth-to which the excavation had been carried, which varies from twenty to thirty feet. All this occurred without the contractor ever encroaching on or digging into the plaintiffs’ property.
With respect to this work so done the following facts appear: (1) To carry out the plan of dock improvement duly approved it was necessary to build a bulkhead on the southerly side of Twenty-second street. (2) It was necessary to dredge' far enough to get to solid bottom through the made ground in order to be able to- drive spiles so as to get a proper foundation for the stone bulkhead wall. (3) To dredge to a maximum depth of thirty feet and to carry that dredging to a point thirty-five feet northerly of the southerly line of Twenty-second street was, in the judgment of the appropriate city officials, necessary in order to secure a proper foundation; this was the contract requirement, and it is not sought to be established that it was not a'necessary and proper essential to the bulk-heading work to be done. ■ (4) Ho dredging was ever done north of the line prescribed in the contract. Plaintiffs do not dispute this, for the court in effect so found at their request. Lines were draw;n on the asphalt of Twenty-second street and ranges put-up to insure the impossibility of any - deviation. (5) Ho proof was made of any negligence on the part of the contractor in the performance óf its contract. There was some question sought to be raised as to a shed' belonging to the Erie railroad having been hit by the bucket of the dredge on several occasions, but even if this was established (which it was not) it would not inure to plaintiffs’ benefit, as plaintiffs concede that the railroad would be entitled to such damages and -not they. (6) The fence which was erected on plaintiffs’ land adjoined the excavated street, was for the protection of the public and was an incident to the use of the street itself by the city’s contractor for the purposes of the dredging. (7) When the improvement was coinpleted there was a paved street in front of plaintiffs’ premises of the same character and width as theretofore ; there was no permanent structure erected .in, under or above the highway, *585and plaintiffs’ land had been filled in and raised to the level of the street without expense to plaintiffs. (8) Upon the proofs there was no evidence of any negligence, unskülfulness or unreasonable delay in the prosecution of any of the work described. (9) The city ultimately acquired plaintiffs’ property by condemnation,
This action was commenced November 30, 1904, and the trial occurred June 14 to 25, 1906. The decision bears date May 7, 1908. At the time of the commencement of the action the plaintiffs complained of the falling of a portion of .their land into the excavation, of the flooding and rendering impassable of the street, and of the erection of a fence on their property, all constituting a continuing trespass upon and nuisance to the plaintiffs. By the time of the trial some of these conditions had been remedied, so that plaintiffs then relied for their right to equitable relief, by way of injunction, on the fact that the street had not yet been repaired (although a contract had been advertised for letting for the doing of that work), and on the further fact that a portion of the fence still remained in position upon their property i
The first question raised is as to the right of a court of equity to take cognizance of the case and grant relief by way of damages only where no equitable relief remained to which plaintiffs were entitled. The test of the jurisdiction of a court of equity is whether facts exist at the time of the commencement of the action sufficient to confer jurisdiction on the court. Jurisdiction having been thus acquired, the only remaining question is whether, at the time of the trial, facts still exist which call for the granting of relief by the court. This merely goes to the question of the amount of relief, if .any, to be then granted. Having once acquired jurisdiction, the court should retain control of the cause and do justice between the parties, awarding such relief as may be appropriate, and granting money damages only, if that be the only relief to wh.ich plaintiffs are entitled, unless a jury trial be duly demanded, when it must be sent to be tried in that forum. (Miller v. Edison Elec. Illuminating Co., 184 N. Y. 17; Van Allen v. N. Y. Elev. R. R. Co., 144 id. 174; Koehler v. N. Y. Elev. R. R. Co., 159 id. 218; McNulty v. Mt. Morris Elec. Light Co., 172 id. 410.) In this case no jury trial was demanded by the defendants, and, therefore, if plaintiffs had made out a cause of action for damages the court was bound to *586award them. But on the present record plaintiffs have proved nothing more than consequential damages, the direct and necessary result of the work properly done in furtherance and execution of a public improvement. The plaintiffs’ grievances " are threefold : (1) The closing of West Twenty-second street in front of their premises for upwards of two years, during most of which time it was excavated and under water; (2) the washing away of the soil from part of their property adjoining the street; (3) the erection of a fence some five feet high on their property extending some thirty feet north thereon, and then westwardly to Thirteenth avenue. As the fence complained of was erected only for. the purpose of preventing persons from falling into the excavated portion of the street and into such part of plaintiffs’ property as had fallen away because of the excavation, the question of the propriety of its existence depends on whether or not the city had a right to suspend the use of the street temporarily in order to prosecute the main work. If the city had such a right, the placing of the fence -was a mere incident to the work, and would have been for plaintiffs’ benefit in that it prevented the possibility of any liability on their part for damages to any one who might be injured while on their land by reason of the presence of the excavation or the subsidence therein of soil from their property. As to the suspension of the use of the street itself, it was purely a temporary one. It is not claimed that the work could have -been done.in any other way, or that the requisite foundations could have been secured without the excavation and dredging resorted to. The very nature of the soil rendered necessary the depth and width to which the work was carried. From the evidence herein the operations proceeded with all reasonable speed, and due diligence was used to restore the street to its public use as soon as possible. The delay in repaving was explained by the fact that the soil subsided and it was necessary to await its' complete settlement before the paving was done, but the final steps to pave it had been taken before the trial was had. The premises owned by plaintiffs were not improved with any buildings except a freight house which was the property of the Erie railroad. When the street was repaired, and the plaintiffs’ land brought up to its level, conditions were permanently restored to what they had been before the dredging began. The street remained a public highway *587undiminished in width, unrestricted in use, and with no additional, structures or burdens upon, over or under it. The third grievance, that o£ the washing away of the soil from a portion of plaintiffs' premises, was inevitable. The very nature of that soil, being made ground, loose and unstable in its nature, rendered unavoidable its sliding into the open cut, even without the influence of such wash as was caused by the continual dropping and raising of the bucket of the dredge. No precaution could have prevented this result.
The rule in regard to consequential damages is laid down in Atwater v. Trustees, etc. (124 N. Y. 602): “ The doctrine, however, is well established in this State, that public officers lawfully employed in making public improvements, and corporations engaged in the performance of work of a public nature authorized by law, are not liable for consequential damages occasioned by it to others unless caused by misconduct, negligence or unskillfulness. (Radcliff’s Executors v. Mayor, etc., 4 N. Y. 195; Bellinger v. N. Y. C. R. R., 23 id. 42; Moyer v. N. Y. C. & H. R. R. R. Co., 88 id. 351; Uline v. N. Y. C. & H. R. R. R. Co., 101 id. 98.) And such is the weight of authority elsewhere. (Transportation Co. v. Chicago, 99 U. S. 635, 641.) * * * And assuming as we do, for the purpose of the question now under consideration, that it was such [i., e., a necessity for the purpose of the work of public improvement], and that they properly and expeditiously performed the work, it is not seen within the doctrine before .stated, how the defendants can be held liable for the consequences resulting from it to others. Within this rule serious injury to property may be occasioned by the lawful exercise of powers of public character pursuant- to law, and if the work is carefully and skillfully performed the consequences may be damnum Ibsque injuria, when the Legislature has provided for no compensation. * * *
“In the present case the action of the defendants in the performance of the work was confined within the limits where the)7 had the right to execute it, and the effect upon property beyond those bounds resulting in damages, was the consequence of such performance of the work, and not the direct act of its execution by them. * * * The dam was but a temporary structure, essential to make the public improvement, and was removed when that was accomplished. The damages so resulting from such cause have *588quite uniformly- been treated as furnishing no common-law remedy. (Plant v. L. I. R. R. Co., 10 Barb. 26; Matter of Squire, 34 N. Y. St. R. 722). * * * The circumstances- of this case1 are not such that the omission of the defendants to resort to all possible means to overcome the obstruction by the dam to the flow of water into- and through this channel during the time reasonably necessary for the work, rendered them chargeable with- negligence in the performance of their duty, although the consequence was that water remained on the plaintiff’s premises longer that season than usual.” '
The rule - was reaffirmed in Uppington v. City of New York (165 N. Y. 222) and Bates v. Holbrook (171 id. 469) and has been' followed without.-question in numerous decisions., ' That persons act.ing under an authority conferred by the Legislature to grade, level and improve streets and highways, if-they exercise proper care and skill, are not answerable for tlie consequential damages which may be sustained by those who own lands bounded by the street or highway, and this whether the damage results either from cutting down or raising the street, and even though the grade of the street had been before established,'and the adjoining landowners had erected buildings with-reference to such grade, was held in Radcliff’s Executors v. Mayor, etc., of Brooklyn (4 N. Y. 195). So in Moore v. City of Albany (98 N. Y. 396) it was said: “As to the excavation outside of the street- lines. This was clearly a trespass upon private property if made without the consent of the owners. If . in excavating with proper care within .the street lines, the- adjoining soil had fallen down into the street, its owner would-have had nó legal cause of complaint.” , ■
This ease seems to come directly within the rules heretofore quoted. There is no proof of misconduct, negligence or' unskillfulness upon the part of the city or its contractor; the work was done entirely within the line of the city property ; the' temporary withdrawal of the street from public use was followed .by its complete restoration thereto; the falling away of soil from plaintiffs’ land was caused by its nature: and was incident to the proper and careful doing of the contractor’s work ; plaintiffs were put to no expense, to restore the soil thus lost.. While they have: .sustained inconvenience and perhaps loss, it was such as the law does not *589compensate them for, for their private loss is the unavoidable consequence of a work for the public good. The appellants rely upon the opinion in Matter of Rapid Transit R. R. Comrs. (197 N. Y. 81) as determining their rights to damages. But I do not view that decision as in any way overruling the rules laid down in the earlier cases. There the use made of Joralemon street was in constructing a subway therein and operating a railroad through the same. It was a municipal use, but not a street purpose. As the court said : “ A street purpose, on the other hand, is exclusively a highway purpose, and any use of the street which improves or benefits it as a highway is a proper street use. Sewers, which drain surface waters, electric lights, which make traveling safer, and water mains, that may be used to sprinkle and clean, are all street purposes, as was shown by J udge Haight in the Larchmont case.” * (P. 97.) The court held that not only surface structures and superstructures, but sub-structures as well of the character of a subway railroad, must be governed by the same principle. “ So that a railroad constructed beneath the surface of a street is a new burden, not contemplated by the original owner of the land when it was devoted to use as a street.” (P. 100.) Mynderse and Abbott, as owners o-f the fee in the street to the center thereof were, therefore, held entitled to the full value of their property taken and to just compensation for the injury done to the remainder. With respect to Hotman, who was an owner of abutting property, it was held that he was entitled to the lateral support of the land in the street and that, therefore, he. could recover the damages inflicted on his property by interference with the lateral support thereof through the proper construction and operation of the underground road.
In the present case no such question arises, for there were no buildings belonging to plaintiffs upon the lands in question, and no proof of any damage caused by the falling in of the land, for the city restored it and plaintiffs paid nothing to restore the land to its former condition. The case just cited was one where the damage was caused in the prosecution of a work which constituted a permanent change in and additional burden upon the use and character of the high- • way, even though it was under and not upon the surface thereof. *590The street was never restored to its former condition, for the under-. ground structure remained there. It was devoted to an additional use, never contemplated when its character ás a highway was created. Here the work in the street was incident to a reconstruction of the dock system of the city and of the highways forming a part thereof. When the street was filled in, and repaired, its former character as a highway was restored, unchanged, with no additional burdens imposed upon it. There was no railway upon, over or under it,- and no occupation for railroad use, which is, of course, essentially different from a public usé. The lateral support theretofore given to plaintiffs’ land by the land in the street was restored as soon as the latter was again filled in. The street led to a part of the dock system of the city and its docks, wharves, piers and bulkheads are a part of the public highways and devoted to public use. The fact that when the improvements were completed a bulkhead existed on the southerly side of the street, across 'from the plaintiffs’ land, did not destroy the character of the street as a public highway.
The judgments appealed from should be modified, in view of all the circumstances, by striking out the provisions allowing costs to the'city of New York and allowing plaintiffs to institute an action at law for trespass, and as modified affirmed, with costs to respondents.
McLaughlin, J., concurred.
Judgments reversed, new trial ordered, costs to appellants to abide event.
Palmer v. Larchmont Electric Co. (158 N. Y. 231).— [Rep.