ARMED SERVICES BOARD OF CONTRACT APPEALS
Appeal of - )
)
Pave-Tech Inc. ) ASBCA No. 61879
)
Under Contract No. N62473-09-D-1605 )
APPEARANCE FOR THE APPELLANT: Christopher R. Sillari, Esq.
Finch Thornton Baird, LLP
San Diego, CA
APPEARANCES FOR THE GOVERNMENT: Craig D. Jensen, Esq.
Navy Chief Trial Attorney
Anthony Hicks, Esq.
Trial Attorney
OPINION BY ADMINISTRATIVE JUDGE WILSON
ON THE GOVERNMENT’S MOTION FOR PARTIAL SUMMARY JUDGMENT
The Navy moves for partial summary judgment, alleging that Pave-Tech, Inc. may
not recover $1,557,754.28 of its $2,555,408.85 claim, related to field office overhead,
because it has used a per diem rate method, deviating from its prior usage of a percentage
cost basis, thus running afoul of our holding in M.A. Mortenson Co., ASBCA No. 40750
et al., 98-1 BCA ¶ 29,658 at 146,946 (Senior Deciding Group). While we find that a
dispute exists as to material facts related to $929,050.86 of appellant’s appeal, appellant
admitted it used the per diem rate for the other $628,703.42, yet used the percentage rate
for its accounting up to now. We grant the Navy’s motion as it applies to that amount.
STATEMENT OF FACTS (SOF) FOR PURPOSES OF THE MOTION
1. Naval Facilities Southwest (Navy or government) awarded Contract No.
N62473-09-D-1605 to Pave-Tech, Inc. (PT or appellant). This was an Indefinite
Delivery Indefinite Quantity contract for “airfield paving and heavy-duty paving areas for
military operation vehicles at various locations within” several western and southwestern
states. (R4, tab 1 at 1-2) This contract incorporated by reference Federal Acquisition
Regulation (FAR) 52.233-1, DISPUTES (JUL 2002) – Alternate I (DEC 1991) and
Defense Federal Acquisition Regulation Supplement (DFARS) 252.243-7001, PRICING
OF CONTRACT MODIFICATIONS (DEC 1991) which applied FAR Part 31 and
DFARS Part 231 (R4, tab 1 at 28, 30).
2. The parties signed Task Order 12 on July 12, 2012, a firm fixed price contract
for paving at Camp Pendleton, CA (R4, tab 10).
3. The parties held a kickoff meeting on August 29, 2012. The minutes for this
meeting contained the following question and statement: “Field Overhead . . . Does your
company charge their field overhead by the percentage method or daily rate method?
Please be advised, that all of your DOD contracts must use the same method. It cannot
change from contract to contract or modification to modification.” (R4, tab 15 at 4235,
4239) The Navy also sent appellant a letter on December 11, 2012, stating:
[I]n order to comply with [the FAR], the company must have
established one method of field office overhead calculation
based on the company’s established and consistently followed
accounting practices. This generally means calculating either
a per diem rate (time distribution base) or a percentage mark-
up (direct cost distribution base). The contractor’s
established method will be consistently applied in all changes
for all contracts.
(R4, tab 18 at 4258) This letter contained NAVFAC Form 4330/43, which was a sample
form instructing contractors to select either a percentage or per diem method of
accounting for field office overhead (FOOH) costs (R4, tab 18 at 4261).
4. Appellant sent the Navy an updated Time Impact Analysis (TIA) by email
dated June 13, 2013, revising an earlier submission on January 24, 2013 (app. opp’n
ex. A (hereinafter Gonzalez decl.), ex. 15 at 1). This TIA was for “impacts incurred by
Pave-Tech Inc. due to the Government actions that have caused delays to the overall
project” (id. at 1). This showed the current schedule “has a slide or extension of
[Contract Completion Date] of 278 Days” which included “198 Days On Going” for
design delays (id. at 9). “Pave Tech will be seeking compensation for both impacts to our
design and impacts to our construction. Please keep in mind these impacts are ongoing
and as previously stated will be updated monthly.” (Id.)
5. On November 6, 2013, appellant sent an email to the Navy concerning an
anticipated modification (mod) to include installation of a gas line. Appellant stated
“[t]he [estimated] pricing for this application would be $410,000[ ]to $515,000” but it
didn’t include “excavation, additional base installation with fabric” nor “dewatering or
hazardous material handling and disposal.” (App. supp. R4, tab 105 at 121) Less than an
hour later, appellant sent another email, stating “the costs for the locating of the existing
gas line have been removed from this proposal and will be added to the REA [Request for
Equitable Adjustment] as discussed.” The email also discussed “the [a]ttached 4330’s,
these rates have been accepted on the contract previously” and cited Task Order 11
(Gonzalez decl. ex. 10). Appellant also sent an email dated December 4, 2013,
describing the “Standard Mark Ups that we will utilize on the Gas Line Modification in
2
the spirit of moving this project along: . . . 2. Primes Field Office Overhead-10%”
(Gonzalez decl. ex. 3 at 2-3).
6. These discussions resulted in PT submitting “PROPOSAL/ESTIMATE FOR
CONTRACT MODIFICATION” (PC) 05 to the Navy on December 19, 2013. This
involved pricing for installation of new HDPE 6” gas line for a total cost of $296,384.87
inclusive of PT’s 10% FOOH, priced at $21,807.15. (R4, tab 54 at 4433) The Navy’s
post-negotiation memorandum, dated the same day, applied the same 10% rate for FOOH
in its summary of the overall price in reaching the final negotiated amount (gov’t mot.
tab E at 6). The parties executed bilateral Modification No. (Mod) 03, dated January 22,
2014, priced at $281,900. This mod contained a contractor statement of release accepting
that this was “payment in full for both time and money and for any and all costs” related
to this work, except for the contractor’s “Time Impact Analysis (TIA) [which] is pending
review by the Government. The TIA will be negotiated later upon Government review
and if justified shall be considered separately.” (R4, tab 58 at 4484-85) Mod 3 contained
no explicit endorsement of the 10% FOOH figure.
7. Appellant submitted PC 08, dated March 24, 2014, to the government for
pricing related to removal of various duct banks. This document contained a total price
of $40,551.78, 1 with a 10% FOOH at $2,535.05. (R4, tab 61 at 4497) This was
incorporated in bilateral Mod 05, signed July 3, 2014. The mod provided $42,657and
zero calendar days, with no statement of release or reference to the TIA. (R4, tab 63
at 4502, 4504).
8. On September 8, 2014, PT submitted PC 03 to the Navy concerning various
concrete renovations near the fuel apron for a total price of $622,768.62, including a 10%
FOOH of $30,690.08 (R4, tab 64 at 4506). This was developed into bilateral Mod 06,
executed October 27, 2014, for $622,768.62. This mod included a contractor’s statement
of release and carve-out for PT’s previously submitted TIA which were almost identical
to Mod 03. (R4, tab 66 at 4512-14)
9. The parties executed bilateral Mod 07 on December 18, 2014, concerning work
on the “Type 4 Aircraft Rinse Facility ([Birdbath])” for $710,229. The mod noted PT’s
“indirect rates (prime field overhead . . .) are under review/analysis by the Government
and are not included in the total amount of the modification.” Further language
concerning the contractor’s statement of release and carve-out for the TIA were
substantially similar to Mod 06. (R4, tab 67 at 4516-18)
10. Appellant submitted to the Navy a proposed estimate for a mod on May 18,
2015, concerning a “revised design of existing wet well to minimize dewatering
requirements.” This proposal had a total of $109,978.97 of prime and subcontractor costs
1
Written in pen next to this figure, without any explanation, is $42,657.
3
with $4,681 representing 19.85% FOOH for PT. (R4, tab 73 at 4614) That proposal was
eventually incorporated into bilateral Mod 10 for $99,150.94, executed June 10, 2015.
This mod also contained the contractor’s statement of release and carve-out for the TIA.
(R4, tab 74 at 4265, 4627)
11. Appellant submitted PC 12 to the Navy on March 23, 2015, for additional costs
related to concrete in the Birdbath, for a total of $36,599.71 inclusive of 19.85% FOOH
at $4,035.81. (R4, tab 71 at 4531) Appellant submitted PC 14 to the Navy on
September 18, 2015, which included FOOH of 22.79%, totaling $88,506.20 on form 4330.
This form stated “[i]f your company charges [FOOH] as a daily rate, please state that you
charge a daily rate and leave the percentage line blank.” A Navy post-negotiation
memorandum, signed by the contract specialist on September 30, 2015, stated the parties
agreed to a FOOH rate of 13.51% and total of $180,114.06. (Gov’t mot. tab G at 3-4)
This total was incorporated in bilateral Mod 12, dated November 3, 2015, and covered
indirect costs for Mod 07 and PC 12. This mod contained an identical statement of release
and TIA carve-out as Mod 10 (R4, tab 78 at 4667, 4669).
12. Appellant provided an additional update to the TIA dated February 8, 2016,
which primarily concerned “delays encountered and documented in the construction of
the Bird Bath” (app. supp. R4, tab 120 at 673).
13. PT submitted an REA dated June 12, 2017, 2 to the Navy for $2,555,408.85
and 221 calendar days. The monetary aspect was broken down into various categories,
with $779,717.16 of the $1,409,705.16 attributed to the East Apron Delay Costs going to
the following: Equipment in Use During Delay, Equipment on Delay (Stand By), Labor
Delay Cost Post Mobilization, Equipment Site Maintenance, and Equipment Standby
Post Mobilization. The remaining $629,988 was broken into “Overhead Cost-Eichleay”
calculated on a per diem basis and “Increased Design Cost.” Likewise, the Birdbath
Delay Costs attributed $934,629.69 of the total $1,145,703.49 to the following: Birdbath
Labor Delay Costs, Equipment In Use During Delay, and Equipment Stand By Costs.
The remaining $211,074 was attributed to “Overhead Cost-Eichleay” which was
calculated on a per diem basis. (R4, tab 83 at 5391, 5395-96, 5398) This was
incorporated into PT’s certified claim, dated June 7, 2018, which claimed the same
monetary and temporal compensation (R4, tab 87 at 1). The government issued a
contracting officer’s final decision on August 22, 2018, denying the monetary aspect of
the claim in full, but granting the requested 221 days (R4, tab 90 at 5460).
2
One of the pages of the REA stated June 20, 2017 in the footer, and the digital signature
on this document is dated June 16, 2017 (R4, tab 83 at 5390, 5392). The parties
appear to agree that it was sent on June 13, 2017 (app. opp’n, Statement of
Genuine Issues of Material Fact ¶¶ 35, 37, 39). Since the exact date is immaterial
to our decision, we discuss it no further.
4
14. PT timely appealed the final decision on November 19, 2018. In appellant’s
complaint, filed December 20, 2018, PT characterized the requested amounts in its claim
as including $779,717.16 for “extended field overhead” for the East Apron delays, and
$934,629.69 for “extended field overhead” for the Birdbath delays (compl. ¶ 68).
DECISION
The Parties’ Arguments
The government’s motion for partial summary judgment seeks to disallow the
$1,557,754.28 3 that PT characterizes as “extended field overhead” in its complaint
(SOF 14). Having selected the percentage method of reimbursement for FOOH, the
government argues appellant cannot now seek to recover these costs using a per diem
method, alleging this would violate FAR 31.203(b), and our Senior Deciding Group’s
reading of that clause in M.A. Mortenson Co., ASBCA No. 40750 et al., 98-1 BCA
¶ 29,658 at 146,946, which we also relied on in Caddell Constr. Co., ASBCA No. 49333,
00-1 BCA ¶ 30,702. (Gov’t mot. at 14-15, gov’t reply at 4-5) The Navy further argues
that PT’s characterization of these costs in its complaint as “field overhead” constitutes a
judicial admission, so it cannot characterize them as equipment costs to survive this
motion (gov’t reply at 2).
PT argues first that $929,050.86 of the money at issue is actually “allowable direct
equipment costs,” thus only $628,703.42 4 is at issue (app. opp’n at 1, 2-6). PT also
argues it and the government had agreed “that the extensive delays caused by the conduct
of Respondent would be compensated as part of a TIA and REA submission that would
later be priced in an equitable manner,” thus it cannot be said that it had irrevocably
chosen a single distribution base (id. at 6). So the argument goes, “the parties expressly
reserved the right of Appellant to recover these time and cost impacts in an equitable
manner in Mods 03, 06, 07, 10, and 12” (id. at 7). Finally, the parties disagree on the
presence of special circumstances to justify a change to the cost distribution base, with
PT pointing to “extraordinary and unusual” delays on the project caused by the Navy,
with a passing reference to “the Government’s threats and refusal to agree to compensate
3
The Navy notes that the correct amount under the REA is $1,557,754.28, and the
complaint “lead[s] to an overstated claim amount of $156,592.57” (gov’t mot.
at 14 n.1). PT does not challenge this statement in its opposition, and uses the
$1,557,754.28 figure (app. opp’n at 1). For purposes of this motion, therefore, we
accept this figure as the amount at issue.
4
The parties discuss two other close numbers, but arithmetic leads us to this figure. The
Navy’s motion calls into question $1,555,754.28, and PT says $929,050.86 is
attributable to something else. Subtracting $929,050.86 from $1,555,754.28
leaves $628,703.42, not $628,703.43 nor $628,673.43 as the parties contend.
(App. opp’n at 1, gov’t reply at 1 n.1)
5
Pave-Tech for cost and time impacts” (app. opp’n at 9; see gov’t reply at 4-6). It finally
attempts to distinguish Mortenson and Caddell on the bases of lack of presentation of
evidence of special circumstances in either of those appeals (app. opp’n at 14).
Discussion
The standards for summary judgment are well established. Summary judgment
should be granted if it has been shown that there are no genuine issues of material fact
and the moving party is entitled to judgment as a matter of law. Celotex Corp. v. Catrett,
477 U.S. 317, 322 (1986). A non-movant seeking to defeat summary judgment by
suggesting conflicting facts “must set forth specific facts showing that there is a genuine
issue for trial.” Anderson v. Liberty Lobby, Inc., 477 U.S. 242, 248-49 (1986) (quoting
First Nat’l Bank of Ariz. v. Cities Serv. Co., 391 U.S. 253, 288-89 (1968)). Nevertheless,
“[t]he moving party bears the burden of establishing the absence of any genuine issue of
material fact and all significant doubt over factual issues must be resolved in favor of the
party opposing summary judgment.” Mingus Constructors v. United States, 812 F.2d
1387, 1390 (Fed. Cir. 1987) (citing United States v. Diebold, Inc., 369 U.S. 654, 655
(1962)). Once the government has made a prima facie case, however, appellant “must
come forward with specific facts showing there is a genuine issue for trial” and must
show what specific evidence could be offered. Matsushita Elec. Indus. Co. v. Zenith
Radio Corp., 475 U.S. 574, 586-87 (1986) (citation omitted). “The non-movant may not
rest on its conclusory pleadings, but . . . must set out, usually in an affidavit by one with
knowledge of specific facts, what specific evidence could be offered at trial. . . . Mere
conclusory assertions do not raise a genuine issue of fact.” Pure Gold, Inc. v. Syntex
(U.S.A.), Inc., 739 F.2d 624, 626-27 (Fed. Cir. 1984). See also Colonna’s Shipyard, Inc.,
ASBCA No. 59987 et al., 16-1 BCA ¶ 36,518 at 177,902.
The central question which this motion presents is whether appellant may recover
costs which it characterized as FOOH on a percentage basis while pricing mods, yet on a
per diem basis when seeking an equitable adjustment. Both parties focus on the same
passage from M.A. Mortenson. In that passage, we stated with regard to FAR 31.203(b):
[The] reference to “a distribution base” requires use of a
single distribution base for allocating a given overhead pool
to cost objectives (such as changes). A contractor may
choose any acceptable distribution base for allocating its job
site overhead pool to particular cost objectives, but not more
than one. We hold that appellant’s practice of switching
between a time distribution base (per diem rate) and a direct
cost distribution base (percentage markup) for allocating job
site overhead costs to changes, depending on whether a time
extension was involved, on its face violated the FAR
6
requirement for a single distribution base for allocating a
given overhead pool.
98-1 BCA at ¶ 29,658 at 146,946 In a footnote, we further stated:
We see no convincing rationale for routinely using different
job site overhead distribution bases on changes that extend or
shorten contract performance, say, by one day (or one week,
or one month), and changes that do not. A change order that
does not change the contract completion date is simply at the
center of a continuum which runs from a substantial increase
in the time of performance at one end to a substantial
decrease in the time of performance at the other. Even when
a contractor proves it has failed to recover its entire overhead,
that is insufficient justification for permitting an accounting
change from one distribution base to another (absent special
circumstances involving a distortion of results, as
contemplated by FAR 31.203(d)).
Id. at 146,948 n.7 (citations omitted). Appellant repeatedly priced FOOH for the various
bilateral mods on a percentage basis, agreeing to seek additional compensation which
was still disputed in the TIA. Almost all of the mods involved a carve-out for this
additional avenue of compensation, but does not discuss the method of calculation.
(SOF 6, 8-11) The plain language of our holding in Mortenson, however, does not allow
recovering FOOH on a percentage basis in mods and per diem basis in an REA any more
than it allows switching between the two distribution bases from mod to mod. This is
reflective of FAR 31.203(d), which states “[o]nce an appropriate base for allocating
indirect costs has been accepted, the contractor shall not fragment the base by removing
individual elements.”
Appellant’s “special circumstances” argument is unappealing. While there are not
clearly defined boundaries as to what does and does not qualify as special circumstances,
we have disallowed the use of per diem costs in a materially similar fact pattern. In Watts
Constructors, LLC, ASBCA No. 59602, 15-1 BCA ¶ 35,873 at 175,372, appellant Watts
attempted to recover FOOH on a per diem basis for allegedly government-caused delays
related to a mod after electing and employing the percentage method for all contract work
beforehand. The government had agreed to some of the costs associated with the mod,
but the parties disputed other costs associated with the delay of the mod, resulting in an
agreement to allow Watts to submit the claimed costs in a TIA. Watts argued it should be
allowed to recover some of these costs on a direct basis because they “were not incurred
for the same purpose and in a like manner as field office overhead costs.” Id. at 175,373.
In denying that argument, we did not find special circumstances there, nor do we now.
Mortenson specifically stated that failure to recover a contractor’s entire overhead would
7
not by itself constitute special circumstances allowing a retroactive accounting change.
98-1 BCA ¶ 29,658 at 146,946 n.7. Run-of-the-mill government-caused delays alone,
like those forming the basis of this appeal, are also not so special as to qualify, even
where they more than double the performance period.
PT makes several other supporting points, but we also find them lacking. PT’s
argument that it should be able to recover FOOH under the equitable principles of the
Changes clause is no more availing than it was when Watts made a nearly identical
argument (app. opp’n at 12-13); Watts, 15-1 BCA ¶ 35,873 at 175,374. Likewise, PT’s
argument employing FAR 31.201-2(c), and suggesting it must implicitly allow some
inconsistent accounting methods is identical to the argument advanced and rejected in
Caddell Constr. Co., ASBCA No. 53144, 02-1 BCA ¶ 31,850 at 157,398-99 (app opp’n
at 13). PT also argues that it agreed to these mods “under economic duress, and under
threat of liquidated damages” but does not meaningfully develop this argument (app
opp’n at 8). PT never indicates that the government either caused or directly took
advantage of its economic duress, nor details the government’s culpability in forcing PT
to work “under threat of liquidated damages” beyond having a liquidated damages
provision in the contract (see, e.g., app opp’n at 8, Gonzalez decl. at 7). This is likewise
not discussed in the complaint. PT does not show “what specific evidence could be
offered at trial” to prove these theories, thus they do not survive summary judgment.
Pure Gold, Inc., 739 F.2d at 626-27.
Another of PT’s central arguments is that the parties agreed “the extensive delays
caused by the conduct of Respondent would be compensated as part of a TIA and REA
submission that would later be priced in an equitable manner” (app. opp’n at 6). As
evidence of this agreement, appellant points to the claim release carve-outs for the TIA
submission in the mods, as well as portions of a declaration by Ben Gonzalez, PT’s
Military Division Manager (app. opp’n at 6-9, Gonzalez decl.). However, this agreement,
effectuated in mods 3, 6, 7, 10, and 12, is only for PT to pursue its disputed costs in a
TIA which would not be subject to the Statements of Release in each mod (SOF 6, 8-11).
PT has done this (SOF 4). Further, “Pave-Tech and the Government agreed that the TIA
would include pricing for cost impacts determined in an equitable manner” (Gonzalez
decl. at 4). Suggestions that the government required PT to submit its pricing for mods
using a percentage method or its TIA using a per diem method are unsupported. PT
points to no evidence of anything more, such as an agreement that the Navy would accept
or grant the TIA or REA once submitted. Thus, it’s unclear how this agreement would
help PT avoid Mortenson’s bar on switching accounting methods.
PT’s last argument concerns $929,050.86 of this amount, which it claims is
actually direct equipment costs expressly allowable under FAR 31.105(d)(2), and not
FOOH (app. opp’n at 5). The Navy claims otherwise, calling the characterizations in
PT’s complaint judicial admissions by which PT should be bound (gov’t reply at 2-3).
8
The complaint characterizes a total of $1,714,346.85 5 as “extended field overhead,” a
different term than FOOH (SOF 14). This same amount is attributed to various other
costs aside from FOOH in the REA supplement, which was incorporated into the claim
(SOF 13). Even if appellant’s complaint did explicitly refer to these costs as FOOH, the
doctrine of judicial admissions does not rigidly apply where a complaint’s allegations are
readily contradicted by evidence in the record. N.L.R.B. v. Merrill, 388 F.2d 514, 518-19
(10th Cir. 1968) (petitioner was not bound by allegation in complaint where evidence
showed allegation was incorrect, because complaint can be amended to conform to
evidence where justice so requires). PT does, however, agree that the remaining
$628,703.42 (see supra fn. 4) of its appeal constitutes FOOH costs “using a daily rate
calculation” (app. opp’n at 1, 15). This does run afoul of our holding in Mortenson.
Thus, we grant the government’s motion as to this amount only. The remaining
$929,050.86 is, at minimum, subject to a dispute of material fact and, as such, cannot be
resolved by summary judgment.
CONCLUSION
For the reasons stated above, the government’s motion is granted in part, as to
$628,703.42 of appellant’s appeal, and denied in part as to the remaining $929,050.86
at issue in this appeal.
Dated: March 23, 2022
OWEN C. WILSON
Administrative Judge
Vice Chairman
Armed Services Board
of Contract Appeals
I concur I concur
RICHARD SHACKLEFORD MICHAEL N. O’CONNELL
Administrative Judge Administrative Judge
Acting Chairman Armed Services Board
Armed Services Board of Contract Appeals
of Contract Appeals
5
See supra, fn. 3.
9
I certify that the foregoing is a true copy of the Opinion and Decision of the
Armed Services Board of Contract Appeals in ASBCA No. 61879, Appeal of Pave-Tech
Inc., rendered in conformance with the Board’s Charter.
Dated: March 23, 2022
PAULLA K. GATES-LEWIS
Recorder, Armed Services
Board of Contract Appeals
10