Opinion of the court by
JUDGE PAYNT-ERReversing.
The Christian church at Princeton burned, and the congregation, desiring to rebuild it, entered into a contract with the appellee, James E. Lane, a contractor, for that purpose.. The contract price was $4,300, but it was reduced to $4,280. Article 4 of the contract reads as follows:
“In consideration of the fulfillment of the agreement herein made by the contractor, the- owner agrees to pay the said' contractor the sum of forty-three hundred dollars ($4,300.00) in installments as. follows: 85 per cent, of the cost of the-labor and materials incorporated into the construction of the building from time to time as the work progresses and the balance ten days after the entire work has been completed, provided the property is free from all liens or rights of liens for debts due or claimed to be due from the contractor *570and satisfactory evidence thereof is furnished (if requested) to the owners.
“All payments shall he made upon written certificates from the architect to the effect that in their opinion such payments have become due, but no certificates or payments shall be considered as a waiver by the owner of any of the provisions of this contract, nor shall any waiver of any breach of this contract be held as a waiver of any other or subsequent breach.”
Those representing the church, being unwilling to rely upon Lane’s obligation, required him to give a bond to secure the church, which he did, with George 0. Hart and F„ W. Katterjohn as sureties. The bond reads as follows:
“This Agreement Witnesseth: — That whereas James E. Lane, of the city of Paducah, Ky., has entered into a contract in writing of even date herewith, with E. M. Johnson, T. M. Powell and T. J. Johnson as the building committee, selected by the members of the Christian church of Princeton, Ky., through their board of officers, to supervise and direct and contract for the construction of a church building in Princeton, Ky., to furnish the material,' build and erect for them a brick church building on the lot of ground on which the Christian church, which was recently destroyed by fire, stood, for the sum of four thousand and three hundred dollars ($4,300.00) well and truly to be paid to said Lane, and said Lane to furnish said material and build and erect said church building in strict accordance with the plans and specifications furnished.
“Now, therefore, in consideration of the premises, and in order to secure said E. M. Johnson, T. M. Powell and T. J. Johnson, building committee, as aforesaid, in the faithful compliance by said Lane with the terms of said contract, said Lane and the undersigned F. W. Katterjohn, Jr., and George *571O. Hart, his sureties, hereby sdeclare and acknowledge themselves firmly bound and indebted to said E. M. Johnson, T.. M. Powell and T. J. Johnson, building committee as aforesaid, in the sum of two thousand five hundred dollars ($2,500.00); this obligation to be void however if said Lane shall well and truly furnish said material and build and erect saifl church building in strict accordance with the terms and conditions of said contract, otherwise it shall remain and be in full force and effect.”
Pursuant to the contract, Lane began the construction of the church.- According to the claim of the representatives of tiie church, and which is sustained by the evidence, Lane did not construct and complete the church according to 'the plans and specifications and terms of his contract. It will be observed that 85 per cent, of the contract price was to be paid upon the certificate of the architect as the work progressed, and 15 per cent, was to be paid in ten days after the building was completed, providing the property was free from all liens or rights of liens for debts due or claimed to be due from the contractor. The 85 per cent, wa-s paid before the building was completed. After the contractor had quit the work, but before the building was .completed, as required by the contract, the 15 per cent, was paid (less something over $100) to persons having liens on the building for material and labor. After Lane quit work upon the building, it was ascertained' there were several hundred dollars due from the contractor for material which had been used in the construction of the building, and due laborers for work done in the construction of it.. These sums the church was compelled to discharge. This action was brought against the sureties on his bond to recover damages for his failure to complete the building according to his contract, and for failing to discharge the debts for the material and labor, and for which *572liens existed on the building. Defense is made chiefly upon the grounds (1) that the' church was completed; (2J that the bond of the sureties did not make them liable for the defective construction of the building, or to discharge any liens existing for material or labor in its construction; (3) that, as the church did not retain the 15 per cent, of the contract price, the sureties are released from liability on the contract."
We must first determine what liability was imposed upon the sureties by their bond. Under the contract the sureties bound themselves that Lane would furnish the material and build the church “in strict accordance with the plans and .specifications furnished,” and “in accordance with the terms and conditions of said contract.” Was the building completed, in the contemplation of the agreement of the parties, if it was not built in accordance with the specifications and terms of the contract? Our opinion is that it was not. The building committee representing the church desired the building to be erected according to plans and specifications agreed upon. ^This the contractor agreed to -do, and the sureties guarantied that it would be so built. The rule is that the sureties are only bound according t'o the terms of their bond. I ■Certainly it would be an utter disregard of the language of the bond to hold that the church was completed, when Lane failed to erect it according to the plans and specifications. The sureties guarantied that Lane would furnish the material and erect the building. In the erection of the building, Lane had to perform the labor himself, or to employ some one to do it. It follows that the sureties guarantied that the necessary materials and labor would be furnished to erect the building. Rut it is urged on behalf of the sureties that the terms of their bond were complied with when the material and labor were furnished; that their contract did not require them to protect the church against the cost of the ma*573terial and labor. Reduced to tbe last analysis, tbeir claim is that Lane complied with his contract by ■ furnishing the material and labor, although the church-was compelled to play, for such part for which Lane failed to pay. Lane did not comply with his contract when he furnished the material and labor, unless he paid for it, or released the building from liability therefor. The parties agreed that Lane was to draw 85 per cent, of the contract price for the purpose of paying his accounts for material and labor, and it may be added here that the church was under no obligation to see to the application of the 85 per cent, to the discharge of such debts. Under the law, a lien existed for the material which went into the building, and for labor performed in its erection. It would be an extremely narrow view to take of the contract to hold that the sureties were under no obligation to protect the ■church against the claims for material and labor for which a lien existed on it. %
The next contention is that they are released because the church paid out most of the 15 per cent, of the contract price before, the church was completed according to the contract. We recognize the law to be that the relation between a creditor and one known to him as surety is one of trust and confidence, and demands the exercise of good faith upon the part of the creditor in dealing with him. Circumstances under which a surety may be released by the conduct of the creditor are well stated in Sneed’s Ex’r v. White, 3 J. J. Marsh., 526, 20 Am. Dec., 175, where the court said: “But any settled agreement or active interference by the obligee whereby the surety may be injured or subjected to increased •risk, or deprived of or suspended in the assertion of his equitable right ’to force the obligee to sue the principal, or of his right to pay the debt, and occupy the attitude, in 'equity, of ■the obligee, will release the surety in equity.” It is perfectly *574manifest that the 15 per cent, was to be withheld until the church was completed, and to be applied to thfe discharge. of any 'liens which might be ascertained to exist against the church. The evidence in this case shows that the 15 per cent, was not sufficient to discharge the lien claims against the church, by several hundred dollars, but whatever part of it was so applied was disposed of as the contract required. The sureties can not complain of that disposition of it, as it was-made according to the terms of the contract. Besides, that' disposition of it released them, pro tanto, of their liability for the debts paid with it. Our conclusion is that the sureties, guarantied that Lane would furnish the material and labor necessary to complete the contract, and after he failed to do it they are liable to the church for the damage which was. sustained by the breach of the contract, not to exceed the-amount of their bond; that their obligation is not discharged until the building has been released of liens for material furnished and labor performed in the erection of the building.
Our opinion is, under the facts of this case, the appellants. are not entitled to recover the $10 per day for the delay in. the completion of the building. It was an action at law,, and the law and facts were submitted to the court, and the-testimony was heard in open court, but the court transferred the case to equity on his own motion while it was so-being heard. The court extended the time until a day in the-next term of court for filing a bill of exceptions. After-wards the court called and held a special term. At the special term the appellants presented the bill qf exceptions, but theappellee objected to having it signed and made part of the record, presumably because it was proper to have it done on the day in the next regular term fixed in the order of extension. The bill of exceptions was presented and signed and made part of the record at the time designated by the order-*575of tbe court. Our opinion is that the intervening of the special term did not affect the order previously made extending the time for filing the hill of exceptions.
The judgment is reversed for proceedings consistent with this opinion.
Petition for rehearing by appellee overruled.