Appeal from an order of the Supreme Court (Reilly, Jr., J.), entered March 9, 2007 in Schenectady County, which, among other things, granted the motion of third-party defendants Bast Hatfield, Inc. and Western Surety Company to dismiss the third-party complaint against them.
The contract between Bast Hatfield and the district required that prior to either party initiating legal action against the other, written notice must be given by the party making the claim within 21 days of the actual occurrence, or of the time when the party should have recognized that such a condition giving rise to the claim in fact existed. Here, the district’s claim against Bast Hatfield is that Bast Hatfield, as general contractor, failed to properly supervise and coordinate the activities of the subcontractors on the project. The district maintains that only when it received plaintiffs bill of particulars in February 2006 did it, for the first time, realize that plaintiff’s claims against the district were partially based on Bast Hatfield’s failure to properly execute its responsibilities as general contractor on the project. Shortly after it received plaintiff’s bill of particulars, the district provided Bast Hatfield with written no
On a motion to dismiss made pursuant to CPLR 3211, a court should construe the pleadings liberally, accept the allegations as true and afford the party opposing the motion the benefit of every possible inference to determine whether the facts alleged fit within a cognizable legal theory (see Westbank Contr., Inc. v Rondout Val. Cent. School Dist., 46 AD3d 1187, 1188 [2007]; Bailey v Chernoff, 45 AD3d 1113, 1116 [2007]; Baron v Pfizer, Inc., 42 AD3d 627, 628 [2007]). Here, the district’s third-party complaint alleged that Bast Hatfield breached the parties’ contract and that such breach delayed the work of other contractors and subcontractors such as plaintiff, causing them damages, and resulted in legal action being commenced against the district. These facts, if true, give rise to the district’s cause of action for common-law indemnification against Bast Hatfield (see Westbank Contr., Inc. v Rondout Val. Cent. School Dist., 46 AD3d at 1189). The motion before Supreme Court was a motion to dismiss, not one for summary judgment. On a CPLR 3211 motion, a court should not resolve the merits of a claim by making factual determinations (see Rovello v Orofino Realty Co., 40 NY2d 633, 635 [1976]; Matter of Niagara Mohawk Power Corp. v State of New York, 300 AD2d 949, 952 [2002]). Here, Supreme Court went beyond the appropriate review of a motion to dismiss and erred by deciding on the facts presented to it that the district, as a matter of law, failed to comply with the notice provision of the parties’ contract (see Kingsley Arms, Inc. v Sano Rubin Constr. Co., Inc., 16 AD3d 813, 814-815 [2005]; Hammond Lane Mechs. v Village of Potsdam, 176 AD2d 1038, 1039 [1991]).
Moreover, plaintiff’s complaint against the district did not specify that Bast Hatfield was the cause of any delay incurred in the project. Rather, the complaint specifically alleged that plaintiff was damaged as a result of the “[district’s negligence and failure to properly, effectively, and fully coordinate the work of the separate prime contractors in breach of its contractual
Cardona, P.J., Mercure, Rose and Malone Jr., JJ., concur. Ordered that the order is modified, on the law, without costs, by reversing so much thereof as granted the motion of third-party defendants Bast Hatfield, Inc. and Western Surety Company to dismiss the third-party complaint to the extent that it sought common-law indemnification; motion denied to that extent; and, as so modified, affirmed.
*.
The district’s claim for contractual indemnification was properly dismissed because the contract provided for Bast Hatfield to indemnify and hold harmless the district “from and against claims, damages, losses and expenses . . . arising out of or resulting from performance of the Work, provided that such claim, damage, loss or expense is attributable to bodily injury, sickness, disease or death, or to injury to or destruction of tangible property.”