State Ex Rel. Ford v. Ellison

Certiorari to quash the record of the Kansas City Court of Appeals. A judgment on certain *Page 686 sewer tax-bills had been rendered in the circuit court in favor of relators and against the Excelsior Springs Light Water Company. Upon an appeal this judgment was reversed by the Court of Appeals. Its rulings are alleged to contraveneStatement. certain decisions of the Supreme Court. The core of the controversy is in the difference between the terms of the ordinance authorizing the work and those of the contract and bond for the faithful performance of same. This is, of course, to be determined from the opinion; correlative facts on which the Court of Appeals bases its ruling are referred to only as aids in more clearly understanding the Court's conclusion.

The ordinance, so far as concers the matter at issue, provides that the "successful bidder shall give a good and sufficient bond in a sum equal to the contract price for the construction of the sewer and laterals, to be forfeited if he shall fail to complete the work of constructing the said district sewer and laterals under his contract within ninety days from the execution thereof."

The contract provides that: "6. The work embraced in this contract shall be begun within ten days after the contract binds and takes effect and shall be prosecuted regularly and uninterruptedly thereafter with such force as to secure the full completion within ninety working days from the date of its confirmation, and the time of beginning, rate of progress and time of completion being essential conditions to this contract. And if the contractor shall fail to complete the work within the time above specified, an amount equal to the sum of four and no/100 dollars per day for each and every day thereafter, until such completion, shall be deducted as liquidated damages for such breach of this contract from the amount of the final estimate of said work."

The bond, which is embodied in the contract, wherein the contractors were the parties of the first part, a liability company, as surety, was the party of the second part, and the City of Excelsior Springs was party of the third part, is, so far as relevant here, as follows: *Page 687

"Said party of the second part hereby guarantees that the said party of the first part will well and truly perform the covenants hereinbefore contained; to pay for the work and all labor of all laborers and teamsters, teams and wagons, employed on the work, and for all materials used therein or any part thereof which shall not be paid for by said first party within ten days after the money for such work, labor and materials becomes due and payable, and this provision shall entitle any or all laborers and teamsters and owners of teams and wagons who may do work, and parties who may furnish materials on or for the improvements to be done under this contract, to sue and recover from the said second party, by said first party; but said second party shall not be liable on this guarantee on account of materials used and labor done upon said work beyond the sum of thirty-four hundred forty and 25/100 ($3,440.25) dollars, the estimated costs of materials used and labor done upon said work. And the said party of the second part hereby agrees with the city of Excelsior Springs that the said party of the first part will well and faithfully perform each and all of the terms and stipulations in the foregoing contract to be done, kept and performed on the part of the said first party, but said party of the second part shall not be liable hereon beyond the sum of thirty-four hundred forty and 25/100 ($3,440.25) dollars.

"And the said party of the second part hereby further agrees with the city of Excelsior Springs, that if the work embraced in the contract be not begun within ten days after this contract binds and takes effect, and prosecuted regularly and uninterruptedly, thereafter in accordance with the terms and provisions thereof with such force as to secure its full completion within ninety working days from the date of its confirmation, they will pay to the city of Excelsior Springs the sum of four and no/100 dollars per day, as liquidated damages for such breach of this contract."

More briefly stated, under the ordinance it is provided in general terms that a forfeiture of the bond is *Page 688 to follow a failure to perform the work within the time stipulated; while, under the contract, of which the bond is a part, the provisions as to the forfeiture are specifically stated in that the liability company as surety for the contractors binds itself to hold the city of Excelsior Springs harmless from all the defaults of the contractors therein specified, in a sum not exceeding the total contract price, except as to the time within which the work is to be performed; as to this, if the limitation is exceeded, for each day the contractors are in default the surety agrees to pay the city of Excelsior Springs four dollars as liquidated damages.

The work contemplated was completed within the time stipulated and in other respects it met the full measure of the contractors' obligation. There is no ground for complaint, therefore, arising between the contracting parties. The malcontent in the original action whose rights the Court of Appeals attempted to determine was a local corporation which refused to pay its proportionate part of the expense incurred in this undertaking, which expense was levied in the form of sewer tax-bills. The improvement effected was one of public necessity, uniformly recognized in all centers of population as promotive of health. While this fact should not and will not control in the interpretation of the Court of Appeals opinion, other than as authorized by its unmistakable terms, the nature of the transaction cannot but cause the reviewer to look upon it with no unkindly eye and to scrutinize with discriminating care any construction the result of which will be to destroy the benevolent purpose intended. This does not mean that the rights of individuals are to be disregarded, but that a wise discretion such as is always present when the law is properly administered, shall be exercised in determining the limit of their protection, which should not be extended except in the presence of an unfair burden illegally imposed.

The portions of the opinion immediately pertinent to the matter at issue are as follows: *Page 689

"The contractor gave a bond in the sum of the contract price, but it did not provide that it should be forfeited if the work was not completed within ninety working days, but it provided that if it was not completed within that time $4 per day should be paid to the city as liquidated damages for each day over the ninety days that the work was not completed. . . . But we think there is merit in the contention that there was no bond given that the work should be completed within ninety days, and that if the work was not completed within that time the bond should be forfeited. The provisions of the bond were that it should not be forfeited, but that only $4 per day should be paid for each working day that the work was not completed after ninety days. The council passing the ordinances authorizing the work regarded it as material that the work should be completed within ninety days, and in order to be assured that the work would be completed in that time provided that a bond should be given to that effect, and if the work was not so completed the bond should be forfeited."

I. Under the issue presented we are concerned only with the part of the bond to which the foregoing excerpt refers. The other parts are in compliance with the general law regulating contracts for public work. [Sec. 1247, R.S. 1909, sec. 1040, R.S. 1919.] A right of action for a breach of eitherPublic Improvements: of these is not affected by theContract and Bond: presence of the others in theConformity to Ordinance. instrument; the validity of either is to be determined by its own terms. If those terms are in substantial compliance with the law in that they contravene no statute, are not in violation of public policy and import a valid consideration, their variance in verbiage from the statute or ordinance upon which they are based will not render the obligation nugatory and hence militate against its enforcement. [State ex rel. Fisher v. Rodecker, 145 Mo. 450; State ex rel. Lafayette Co. v. O'Gorman, 75 Mo. l.c. 378; State ex rel. West v. Thompson, 49 Mo. *Page 690 l.c. 189; Gathwright v. Callaway County, 10 Mo. 664; Grant v. Brotherton's Admr., 7 Mo. 458; Barrett v. Stoddard County, 183 S.W. l.c. 647.] It is the subject-matter as indicative of the purpose and not the mere form that the court looks to in construing the terms of an obligation as at bar. [Henry County v. Salmon, 201 Mo. l.c. 152; Wimpey v. Evans, 84 Mo. 144; State ex rel. McKown v. Williams, 77 Mo. l.c. 470; Newton v. Cox, 76 Mo. l.c. 354; Flint ex rel. v. Young, 70 Mo. l.c. 225; State to use Cameron v. Berry, 12 Mo. 377.] Here the validity of the bond is assailed not on account of its different conditions but its variance from the ordinance which it is contended is such as to make the entire obligation void. This conclusion does not follow, even if it be conceded that the condition as to the time limit of performance is invalid. The binding obligations of the other conditions would not thereby be affected authorized as they are by the statute and drawn in conformity therewith. In ruling therefore as to the invalidity of the entire bond by reason of the alleged variance of one of the conditions from the tenor of the ordinance, the Court of Appeals either inadvertently or otherwise ignores the other conditions, and in so doing contravenes the cases above cited. However, giving immediate consideration to the condition in controversy, there is no such variance between it and the ordinance as to affect the obligations of the bond. For immediate reference we repeat that the ordinance authorizes a forfeiture of the bond upon a failure to perform the work within ninety days, while the bond prescribes that the work shall be begun within ten days after the execution of the contract and prosecuted with such force as to secure its completion within ninety days; and if not so completed the contractors and surety will pay to the city of Excelsior Springs four dollars per day for each day's default. From this it will be seen, without quibbling with words in attempting to make more clear that which is already clear, that the mandatory obligation of the bond as to the time of the completion of the work is the same in effect as that of the ordinance. *Page 691

II. The only remaining ground for controversy is what is meant by a forfeiture of the bond. The meaning of similar terms in statutes and ordinances as defined in the rulings of courts of last resort in other jurisdictions, while not determinative of the question of the contravention of opinionsBond: Forfeiture. here involved, are not inappropriately cited to show that the current of authority is uniform on this subject, and, as we will show, is in accord with our own rulings. In United States v. Distillery at Spring Valley, 25 Fed. Cases, 854, the court said the words "shall forfeit as used in the Act of Congress, March 31, 1868 (15 Stat. 59), declaring that a distiller operating without a license shall forfeit his distillery and distilling apparatus, means that they shall be subject to forfeiture."

The Supreme Court of Vermont in Woodcock v. Bolster,35 Vt. 632, held that where the word forfeit is used it is usually construed to mean a cause of forfeiture requiring some judicial proceeding to effect it.

The Court of Appeals of Indiana in Barber-Asphalt Co. v. City of Wabash, 43 Ind. App. 167, held that when a contract for the improvement of a city street provided for its completion at a certain date and for a failure the contractor was to pay a forfeit of $25 per day as liquidated damages until the completion of the work, that while the word forfeit usually means a penalty the damages will be considered liquidated regardless of whether the city suffered actual damages.

The Supreme Court of Texas in Galveston Ry. v. State, 81 Tex. 572, in construing a statute of that State (Sec. 4280, R.S. Tex.) which provides that if a railroad company fails to file its annual report it shall forfeit its charter, was intended to prescribe the ground of forfeiture which the state could enforce by a judicial proceeding.

Under our own rulings and those of the Courts of Appeals the word forfeit as used in criminal law is equivalent to a fine; but when used in a civil proceeding in connection with the enforcement of a civil right it *Page 692 contemplates an ordinary civil judgment, having nothing peculiar in its nature. [State ex rel. Stinger v. Kruger, 280 Mo. 293; Edwards v. Brown, 67 Mo. 377; Ex parte Alexander, 39 Mo. App. l.c. 109; Greene County to use v. Wilhite, 29 Mo. App. l.c. 466.] The language of the ordinance, therefore, in requiring a forfeiture of the bond upon a failure of the contractor to comply with the prescribed time limit in the completion of the work was not employed in the strict sense of a penalty as in criminal law, but in a definitive manner to afford the city the right to a civil proceeding to recover from the contractor or his surety the stipulated amount per day for each day's default beyond the time limited in the bond.

While it would have been a loose and irregular manner for a municipality to have contracted for public wark in simply requiring a bond in the general language of an ordinance, the right of action on such an obligation would have differed in no material particular from that authorized under the present bond except as to the manner of determining damages. In the one case the right of recovery would have been limited to proof of the damages actually sustained, while in the other that right would have been measured by the number of days the contractor was in default, the sum stipulated as a penalty to be taken as a unit in estimating the total. Under either there would have been such a forfeiture of the bond as is meant by the ordinance and is authorized by law but not such as is held to have been required by the Court of Appeals opinion. Ordinances authorizing work of the character here under review are usually couched in general terms, leaving the conditions of the contract and bond to be specified by the parties. The necessities of the case demand this latitude in the effective discharge of the duties devolving upon municipal authorities in the letting of public work whose rights and powers in regard thereto are not limited to those expressly granted but include such implied powers as are necessary to carry into full force and effect those expressly granted. As was well said in City St. Louis v. *Page 693 Von Phul, 133 Mo. 567: "The power to make improvements and to let contracts therefor and to exact of the contractor a bond for the faithful performance of his contract, necessarily implies the power to do everything necessary for the faithful performance of the work, for the protection of the city and its citizens, and for the securing of the best and lowest possible bids. Indeed, we are unable to conceive of any matter of detail incident to the contract and the work that the city might not require that a private person could require."

In ruling, therefore, that the bond given illegally extended the powers granted the municipal authorities under the ordinance and thus prevented competitive bidding for the work, the Court of Appeals ran counter to the Von Phul and other cases of like character.

III. It is difficult to determine from the opinion of the Court of Appeals what is held therein to be the limit of the obligee's right of recovery upon a breach of the condition of a bond drawn in the language of the ordinance alone. We have shown that if it be meant by this ruling that such right is to beDamages. limited to a recovery of the actual damages sustained, an adequate remedy is afforded by the bond given; and, hence, the contention as to the invalidity of same must go for naught.

If, however, it is meant that the obligee is to be entitled to a different right of recovery, the ruling is in direct conflict with numerous decisions of this court. [State ex rel. Cochran v. Cooper, 79 Mo. l.c. 467; State to use Gates v. Fitzpatrick,64 Mo. 185; State to use Reyburn v. Ruggles, 20 Mo. 99.] The rule has never been recognized in this State that the obligee upon the breach of a condition was entitled to a judgment for the full penalty of a bond when a less sum was actually due. As was said in Burnside v. Wand, 170 Mo. l.c. 560: "Our law is opposed to forfeitures. It has ever been considered unconscionable to demand the full penalty when a lesser sum is actually due. Hence, it has ever been the law in our State that in suits upon penal bonds the *Page 694 obligor can discharge himself by paying what is really due with interest and cost, and thereupon the cause is discontinued."

IV. Summarizing what has heretofore been said: the rule announced in Barber-Asphalt Co. v. Munn, 185 Mo. 552, and other cases declaratory of the same doctrine, as to the supervening control of an ordinance in determining the time within which the work is to be performed can have no application here.Summary. The time limit in the contract and bond was identical with that prescribed in the ordinance. Furthermore, the language of the ordinance being general, the provision in the contract and bond defining the manner in which the damages were to be determined did not exceed the implied power of the municipal authorities in contracting for the performance of the work but constituted a wise and necessary exercise of same. The rule limiting the powers of municipalities in contracting for public work to the terms of ordinances applies only when the latter contain specific provisions in regard to the work contracted for and necessary to secure its performance as exemplified in State v. Butler, 178 Mo. 272; Heman Const. Co. v. Lyon, 277 Mo. 628.

From all of which the conclusion is authorized that the opinion of the Court of Appeals contravenes decisions of this court in the particulars stated and that its record should be quashed. It is so ordered. All concur except Woodson, J., who dissents in separate opinion.