[Cite as Gaylord v. Frazzini, 2010-Ohio-6385.]
STATE OF OHIO, MAHONING COUNTY
IN THE COURT OF APPEALS
SEVENTH DISTRICT
BRETT GAYLORD, )
) CASE NO. 10 MA 69
PLAINTIFF-APPELLANT, )
)
- VS - ) OPINION
)
DENO FRAZZINI, )
)
DEFENDANT-APPELLEE. )
CHARACTER OF PROCEEDINGS: Civil Appeal from Youngstown Municipal
Court, Case No. 08CVF1399.
JUDGMENT: Affirmed in part; Reversed and Modified
in part.
APPEARANCES:
For Plaintiff-Appellant: Attorney Plato Kalfas
4822 Market Street, Suite 250
Youngstown, Ohio 44512
For Defendant-Appellee: Attorney James Melone
700 Fifth Street
Struthers, Ohio 44471
JUDGES:
Hon. Joseph J. Vukovich
Hon. Gene Donofrio
Hon. Cheryl L. Waite
Dated: December 22, 2010
VUKOVICH, P.J.
¶{1} Plaintiff-appellant Brett Gaylord appeals the decision of the Youngstown
Municipal Court entering judgment in favor of defendant-appellee Deno Frazzini in the
amount of $1,747.37 plus interest.
¶{2} Gaylord’s first argument is a manifest weight of the evidence argument.
He asserts that the municipal court abused its discretion when it determined that the
contract between Gaylord and Frazzini did not have a set completion date. He argues
that the completion date was set for the end of December 2007 and thus, when
Frazzini had not completed the work by February 2008, Frazzini breached the
contract. Alternatively, Gaylord contends that even if the municipal court did not abuse
its discretion in rendering judgment in favor of Frazzini, the municipal court’s
computation of damages was incorrect when considering the findings that it made.
¶{3} Considering the evidence presented at trial, we find that the municipal
court did not abuse its discretion by determining that there was no solid completion
date set by the contract. That said, we find merit with Gaylord’s alternative argument
that the computation of damages was incorrect. The municipal court’s award of
damages does not align with the findings it made; per the evidence presented at trial,
damages only amounted to $970.70, not to $1,747.37. Accordingly, the judgment is
affirmed in part, reversed in part and the award of damages is modified to $970.70
plus interest.
STATEMENT OF THE CASE
¶{4} On March 27, 2008, Gaylord, a real estate developer, filed a breach of
contract complaint against Frazzini, a contractor, seeking damages in excess of
$3,600. Frazzini answered the complaint and counterclaimed for damages in the
amount of $3,490.
¶{5} Following discovery, but prior to trial, the parties stipulated to the
following facts. The parties entered into an oral contract for the rehabilitation of
property at 209 Outlook Avenue in Youngstown, Ohio. The contract price was set at
$6,500, half was due up front and the remainder was to be paid upon completion. The
contract included painting portions of the outside of the house, installing hardwood
floors in the kitchen and dining room, installing kitchen cabinets and countertops,
redoing the upstairs and downstairs bathrooms, installing new front doors and interior
doors, dry walling, texturing and painting walls in the house, installing new windows,
and installing glass block windows in the basement. Work commenced on the house
on or about October 19, 2007 and Gaylord paid Frazzini $3,250 on or about that date.
Gaylord later also paid Frazzini $400 for three windows that were never purchased by
Frazzini. Gaylord terminated Frazzini’s employment shortly after February 22, 2008.
¶{6} During trial, each party offered testimony about the amount of work
completed and whether it was completed in a workmanlike manner. They each also
offered testimony on whether there was a firm completion date for the contract.
¶{7} Following trial, the municipal court found that based on the testimony
there was no firm completion date for the contract, Frazzini had completed 70.58% of
the labor for the project, and Gaylord terminated Frazzini’s employment before the
remainder of the work could be completed. 02/26/10 J.E. Thus, Gaylord’s complaint
for money owed based on breach of contract was denied. The court then entered
judgment for Frazzini on his counterclaim in the amount of $1,747.37 plus interest.
02/26/10 J.E.
¶{8} Following that decision, Gaylord filed a motion for reconsideration on the
amount of damages owed to Frazzini. However, prior to a decision being rendered on
that motion, Gaylord filed a timely appeal from the February 26, 2010 judgment and
requested a stay of execution. The stay of execution was granted. 04/06/10 J.E.
FIRST ASSIGNMENT OF ERROR
¶{9} “WHETHER A LOWER COURT ABUSES ITS DISCRETION BY NOT
FINDING A PARTY TO A CONTRACT IN BREACH OF THAT CONTRACT FOR
FAILURE TO PERFORM IN A TIMELY MANNER WHEN THE BREACHING PARTY
ADMITTED THAT THERE WAS A COMPLETION DATE TO THE CONTRACT, AND
DID NOT COMPLETE THE CONTRACT BY THAT DATE.”
¶{10} This assignment of error presents a manifest weight of the evidence
argument. Appellate review of a manifest weight of the evidence argument in a civil
case is much more deferential to the trial court than in a criminal case. State v.
Wilson, 113 Ohio St.3d 382, 2007-Ohio-2202, ¶26. The civil manifest weight of the
evidence standard provides that judgments supported by some competent, credible
evidence going to all the essential elements of the case will not be reversed by a
reviewing court as being against the manifest weight of the evidence. Id. at ¶24, citing
C.E. Morris Co. v. Foley Constr. Co. (1978), 54 Ohio St.2d 279, syllabus.
¶{11} The reviewing court is obliged to presume that the findings of the trier of
fact are correct. Id., citing Seasons Coal Co., Inc. v. Cleveland (1984), 10 Ohio St.3d
77, 80-81. This presumption arises in part because the fact-finder occupies the best
position to observe the witnesses’ demeanor, gestures, and voice inflections and to
utilize these observations in weighing credibility. Id., citing Seasons Coal, 10 Ohio
St.3d at 80.
¶{12} Here, the concentration is on the municipal court’s finding that there was
“[n]o fixed time completion date.” 02/26/10 J.E. The municipal court further expanded
upon that finding by stating:
¶{13} “The Court further finds that defendant provided 70.58 per cent [sic] of
the labor for the project and based on testimony and circumstances (an understanding
by plaintiff of defendant’s skill level and timeliness from previous agreements and
projects) the work was not untimely or not in a workmanlike manner.” 02/26/10 J.E.
¶{14} At trial, Gaylord testified that their oral contract set a “tentative deadline”
for the work to be completed by November 30, 2007. (Tr. 10). He later explained that
the deadline was extended by a month to the end of December. (Tr. 12-13). However,
in stating all of this, he explained that he had previously used Frazzini on two other
jobs and while he was happy with the price and quality of work for those two jobs,
timeliness was an issue. (Tr. 9, 33-34). During cross-examination he made the
following statements about his willingness to deal with the timeliness issue:
¶{15} “Q. You got two out of three and thought based on the price and based
on the work I am willing to deal with the timeliness?
¶{16} “A. Right.
¶{17} “* * *
¶{18} “Q. Would you agree that you were willing to give a bit on timeliness in
exchange for quality of work and a good price?
¶{19} “A. Would I give way to timeliness?
¶{20} “Q. Willing to not be as strict on timeliness so you could get the good
price and the quality of work, is that fair to say?
¶{21} “A. To a degree, yes.
¶{22} “Q. You showed that by agreeing to extend it at least one time from
November 30th to the end of December?
¶{23} “A. Correct.
¶{24} “Q. So you knew that would be an issue and, in fact, it was an issue,
correct?
¶{25} “A. Yes.” (Tr. 33-34).
¶{26} Frazzini concurred that the original agreement was for the work to be
completed by November 30th. (Tr. 54). However, he then explained that the
November 30th deadline was not set in stone, rather it was a date that Gaylord “would
like” the work to be done by, i.e. it was an aspirational completion date. (Tr. 55).
¶{27} The above testimony regarding the tentative nature of the completion
date for the contract and the effect of past transactions on the contract is competent
credible evidence that can easily be interpreted to show that any completion date was
not firm. Despite that, Gaylord argues that an e-mail admitted into evidence at trial
from Frazzini to Gaylord dated February 2008 shows that the deadline was firm. In the
e-mail, Frazzini acknowledges that the project was not completed and it was past the
“Nov/Dec deadline.” This is not a clear indication that the contract had a set deadline;
and it does not state that it was a firm deadline instead of an aspirational deadline.
Consequently, that e-mail does not provide clear evidence that the municipal court’s
decision was against the manifest weight.
¶{28} Gaylord also focuses his argument on Frazzini’s admission on the stand
that half the delays in the completion of the project were contributable to him. (Tr. 70).
That admission, however, does not alter any testimony concerning whether or not the
deadline was tentative. Thus, it provides no support for the position that the municipal
court’s decision was against the manifest weight of the evidence.
¶{29} Accordingly, considering the standard used to review the argument
presented and all the evidence admitted at trial, we find that there was competent
credible evidence to support the municipal court’s decision to deny Gaylord’s
complaint for breach of contract; the municipal court’s finding that there was not a firm
completion date to the contract was not against the manifest weight of the evidence.
This assignment of error does not have any merit.
SECOND ASSIGNMENT OF ERROR
¶{30} “WHETHER THE LOWER COURT UTILIZED AN IMPROPER
MONETARY FIGURE TO CALCULATE THE AWARD TO THE DEFENDANT-
APPELLEE.”
¶{31} The court found that Frazzini did not breach the contract and that he
completed 70.58% of the work he was contracted to perform. Also, it was stipulated
that the contract price was $6,500. By those numbers, Frazzini was entitled to
$4,587.70 for the work that was completed. It was also stipulated that Frazzini had
already been paid $3,250 at the start of the job. The municipal court determined that
Gaylord was to be credited for an additional $400 he paid to Frazzini for windows that
he never received. Thus, in all Gaylord paid Frazzini $3,650. Subtracting $3,650 from
$4,587.70, the remainder owed to Frazzini for the work he actually completed was
$937.70.
¶{32} Given the above computations, we find merit with Gaylord’s argument
that the municipal court incorrectly awarded Frazzini $1,747.37 instead of the $937.70.
The purpose of contract damages is to compensate the nonbreaching party for the
loss suffered as a result of the breach. Lake Ridge Academy v. Carney (1993), 66
Ohio St.3d 376, 381. See, also, Miller v. Irvin (1988), 49 Ohio App.3d 96, 98 (stating
purpose of damages is to compensate a party for the injuries suffered and to make
that party whole). Furthermore, a damage award is unreasonable if it places a party in
a better position than the party would have enjoyed if the breaching party had fully
performed its obligations. Thomas K. Dillon, M.D., Inc. v. Four Development Co.
(Sept. 11, 1992), 6th Dist. No. L-91-231, citing Cincinnati Fluid Power, Inc. v.
Rexmord, Inc. (C.A.6, 1986), 797 F.2d 1386, 1393. The municipal court’s award of
$1,747.37 is over the amount due on the contract and, as such, places Frazzini in a
better position than he would have been had he been permitted to complete the
contract. While it is true that Frazzini’s counterclaim sought damages in excess of the
contract price, at trial he did not argue or present evidence to show why he was
entitled to any more than was owed on the contract.
¶{33} Accordingly, based on the above espoused principles of damages, the
municipal court’s findings, and the evidence presented at trial, this assignment of error
has merit.
CONCLUSION
¶{34} For the foregoing reasons, the judgment of the trial court is affirmed in
part, and reversed and modified in part. In conclusion, the first assignment of error
lacks merit. The municipal court’s decision to deny Gaylord’s complaint for breach of
contract is affirmed. However, the second assignment of error has merit. The award
of damages is reversed and modified from $1,739.37 plus interest to $937.70 plus
interest.
Donofrio, J., concurs.
Waite, J., concurs.