IN THE COURT OF APPEALS OF IOWA
No. 18-0622
Filed May 1, 2019
REICHER ELECTRIC, INC.,
Plaintiff-Appellant,
vs.
ATUL PATEL and SHRI GANAPATI & BAJRANGBALI, INC., an Iowa
Corporation, d/b/a FAIRFIELD INN & SUITES,
Defendants-Appellees.
________________________________________________________________
Appeal from the Iowa District Court for Black Hawk County, John J.
Bauercamper, Judge.
A subcontractor appeals a district court order denying a claim for unjust
enrichment. AFFIRMED.
Dan McClean of McClean & Heavens Law Offices, Dyersville, for appellant.
Max E. Kirk of Ball, Kirk & Holm PC, Waterloo, for appellees.
Considered by Tabor, P.J., and Mullins and Bower, JJ.
2
BOWER, Judge.
Reicher Electric, Inc. (Reicher) appeals the district court’s ruling in favor of
Atul Patel and Shri Ganapati & Bajrangbali, Inc. (SGB). Reicher contends SGB
was unjustly enriched by receiving the benefit of work when Reicher was not paid.
We find Reicher did not establish a direct contract between Reicher and SGB and
cannot support a claim of unjust enrichment.
I. Background Facts & Proceedings
On August 19, 2013, SGB entered into a construction contract with general
contractor Main Street Developers (MSD), a Wisconsin company, to build a
commercial hotel property in Waterloo.1 The contract specified a firm price of
$4,450,000 and required any changes or substitutions be approved by SGB in
writing. Under the agreement, MSD was to “provide all labor, materials, equipment
and services necessary to complete the Work.” The contract had as an exhibit a
list of items to be provided by MSD, including “Interior Lighting Fixtures
(Permanent).”
MSD hired Reicher for the electrical work on the hotel. The contract
provided MSD would pay Reicher $300,000 for the electrical work. After the
project began, MSD approached Reicher and asked for assistance in obtaining the
lighting fixtures; Reicher agreed for a price of ten percent of the cost of the lighting.
1
The parties’ appendix violates the clear requirements in Iowa Rule of Appellate
Procedure 6.905(2)(b). In particular, this appendix does not contain the initial pleadings
between these parties, a copy of the order in question, a list of relevant docket entries, or
relevant portions of the transcript (though a list of relevant transcript portions was
included). The briefs refer to documents not included in the appendix. The failure to
compile a minimally-adequate appendix forces the court to search a record of over 2000
pages for basic information and impedes the efficiency of this court’s ability to address the
issues in a timely manner.
3
Reicher approached Crescent Electric Supply Company (Crescent) to supply the
necessary materials. Following an initial partial estimate from Crescent, MSD
provided $70,000 to Reicher for lighting fixture orders.
After work had already begun, Reicher and Atul Patel, president of SGB,
met with a hotel chain representative who suggested converting to LED lighting
and provided a “spec book” of appropriate fixtures. Reicher informed Patel while
the conversion would save electric costs, it would cost more upfront. Reicher
claims Patel said to change to the LED lighting. Patel testified he never received
a quote for the lighting and did not have a formal meeting with MSD regarding the
LED lighting. No change orders were submitted to SGB or approved for electric
work or light fixtures.
MSD was not present at either LED lighting meeting, but was aware Reicher
was ordering and installing LED lights. The owner of MSD testified the change in
lighting was a separate agreement between Reicher and Patel that MSD was not
part of, and he denied MSD was responsible for paying for the LED lighting.
Numerous other changes to Reicher’s work were requested, including electric car
charging stations, floor boxes in the conference room, rewiring offices, adding
notification lights to sump pumps, and additional outlets. Reicher also had to
rewire for some appliances when fixtures provided by MSD did not match the
electrical requirements on the plans Reicher was working from. Reicher included
costs for all changes in its bill to MSD.
From January 2014 through April 2015, Reicher ordered lighting fixtures
from Crescent. Crescent ordered and Reicher installed the LED lights listed in the
hotel chain’s “spec book.” As the $70,000 was paid over time by MSD, Reicher
4
made payments to Crescent; no other party made payments on the light fixtures
ordered for the hotel. At the end of the project, Reicher still owed $106,209.31 to
Crescent. Reicher provided all the invoices to MSD, and MSD indicated Reicher
probably would not get paid for everything. One week before completion, Reicher
raised the issue of payment with Patel and SGB.
Around the time of opening the hotel, MSD walked off the project without
issuing a statement of substantial completion. After discovering MSD and SGB
would not pay for the LED lighting and extra work performed, Reicher refused to
do additional uncontracted work on the project. Reicher did not complete rebate
forms for the lighting installed and did not complete warranty work in the hotel.2
Some lighting materials were returned to Crescent, but some of the items were
special order or outside the time period for returns and Reicher could not get
refunds for them.
Crescent filed a mechanic’s lien on July 23, 2015, for $104,388.94, naming
Reicher as general contractor for the building owned by SGB. On August 14, 2015,
nearly four months after completing its work on the hotel, Reicher filed a
mechanic’s lien against SGB for items provided between December 2014 and April
2015, claiming a sum of $191,805. It appears Reicher’s mechanic’s lien is still
outstanding.
On November 11, Crescent filed a petition at law against Reicher for breach
of contract, quantum meruit, unjust enrichment, and statement on account.
Crescent requested relief of the principal due plus statutory interest and court
2
According to Reicher, the rebates would have been worth approximately fifteen to
twenty thousand dollars.
5
costs. On June 2, 2016, Reicher filed a cross-petition for breach of contract,
quantum meruit, and unjust enrichment against Patel and SGB as third-party
defendants. Reicher did not name MSD in the petition. Reicher claimed to have
entered into an oral contract with Patel and SGB for the installation of electrical
fixtures and lighting at the hotel and to have conferred benefit in the form of
material, services, labor, and time for which the company is entitled to the
reasonable value. Reicher’s requested relief included full contribution and
indemnity, attorney fees, court costs, and interest.
On June 1, 2017, the district court entered a judgment order agreed to by
Crescent and Reicher in favor of Crescent, entering a judgment of $119,207.60
against Reicher.3 On June 8, the cross-petition between Reicher and SGB was
tried to the court.
On February 10, 2018, the court filed its findings of fact, conclusions of law,
judgment and decree. The court found no express contract—written or oral—
existed between Reicher and SGB. The court then noted changes in a contract
between a general contractor and subcontractor do not create a contract between
the subcontractor and the owner. Without contractual privity, the court ruled “no
common law remedy of restitution is available.” Reicher appeals only the issue of
unjust enrichment.
II. Standard of Review
“A claim for unjust enrichment ‘arises from the equitable principle that one
shall not be permitted to unjustly enrich oneself by receiving property or benefits
3
The judgment included both Reicher’s outstanding balance with Crescent, statutory
interest, and court costs.
6
without making compensation therefor.’” Legg v. W. Bank, 873 N.W.2d 763, 771
(Iowa 2016) (quoting Ahrendsen ex rel. Ahrendsen v. Iowa Dep’t of Human Servs.,
613 N.W.2d 674, 679 (Iowa 2000)). The district court expressly noted the case
was being tried at law without objection from the parties. Therefore, our review is
for correction of errors at law. See Iowa R. App. P. 6.907; Pursell Constr., Inc. v.
Hawkeye-Sec. Ins. Co., 596 N.W.2d 67, 69 (Iowa 1999).
III. Analysis
In Henning v. Security Bank, 564 N.W.2d 398, 401–03 (Iowa 1997), our
supreme court analyzed the rights and remedies available to subcontractors in
comparison to general contractors. While general contractors have common-law
remedies for the value of materials and labor in addition to statutory mechanic’s
lien rights, these remedies are based on the existence of express or implied
contracts. Henning, 564 N.W.2d at 402. Because the subcontractor’s contractual
relationship is with the general contractor, contractual and common-law remedies
are against the contractor, not the owner. Id. at 403 (citing Roger W. Stone,
Mechanic’s Liens in Iowa, 30 Drake L. Rev. 39, 45–46 (1980)). Iowa’s mechanic’s
lien law provides the means of recovery by a subcontractor against the property
owner. Id. The court found in the absence of a contractual arrangement with the
owner, subcontractors do not have a common-law right of action based on implied
contract or unjust enrichment for the work and materials furnished. Id. at 399.
In order to prove a right to a common-law recovery, Reicher had to prove a
direct contract with SGB—either express or implied. The district court found no
express contract existed directly between Reicher and SGB. SGB’s fixed-price
contract with MSD specifically assigned the responsibility to provide the permanent
7
interior lighting fixtures to the contractor. MSD then delegated that job to Reicher
as an addition to their original contract. “The law will not imply a contract where
there is an express contract.” Clemens Graf Droste Zu Vischering v. Kading, 368
N.W.2d 702, 712 (Iowa 1985). An express contract supersedes an implied
contract. Welte Ins., Inc. v. Big Red Lighting & Elec., Inc., No. 11-0254, 2011 WL
5391616, at *7 (Iowa Ct. App. Nov. 9, 2011). Because the contract between the
owner and general contractor expressly covers permanent interior lighting fixtures,
and MSD then contracted with Reicher on the light fixtures, we cannot find an
implied contract between Reicher and SGB.
Reicher’s primary remedies as a subcontractor on the project are
contractual actions against the general contractor. If the principal contractor
becomes insolvent or otherwise defunct, then our mechanic’s lien law provides a
means of recovery. Louie’s Floor Covering, Inc. v. DePhillips Interests, Ltd., 378
N.W.2d 923, 927 (Iowa 1985). It does not appear from the record before us that
Reicher has sought recovery from MSD or attempted to foreclose its mechanic’s
lien. We find Reicher has not established the express contract between Reicher
and SGB necessary to support a claim of unjust enrichment and is limited to
recovery from MSD or through its mechanic’s lien.
AFFIRMED.