ACCEPTED
04-14-00429-CV
FOURTH COURT OF APPEALS
SAN ANTONIO, TEXAS
8/31/2015 1:47:50 PM
KEITH HOTTLE
CLERK
NO. 04-00429-CV
IN THE COURT OF APPEALS FOR THE FILED IN
4th COURT OF APPEALS
FOURTH COURT OF APPEALS DISTRICTSAN ANTONIO, TEXAS
SAN ANTONIO, TEXAS 08/31/2015 1:47:50 PM
KEITH E. HOTTLE
Clerk
CITY OF SAN ANTONIO, ACTING THROUGH
CITY PUBLIC SERVICE BOARD OF SAN ANTONIO
Appellant,
v.
CASEY INDUSTRIAL, INC.,
Appellee.
On Appeal from the 408th Judicial District Court
Bexar County, Texas
The Hon. Michael E. Mery, Presiding
CPS ENERGY’S RESPONSE TO
MOTION FOR RECONSIDERATION EN BANC
JUDITH R. BLAKEWAY ANNALYN G. SMITH
State Bar No. 02434400 State Bar No. 18532500
STRASBURGER & PRICE, LLP SCHMOYER REINHARD, LLP
2301 Broadway 17806 IH-10 West, Suite 400
San Antonio, Texas 78215 San Antonio, Texas 78257
Telephone: (210) 250-6000 Telephone: (210) 447-8033
Facsimile: (210) 250-6100 Facsimile: (210) 447-8036
judith.blakeway@strasburger.com asmith@sr-llp.com
ATTORNEYS FOR APPELLANT
CPS ENERGY
1937549.2/SPSA/22244/0110/083115
TABLE OF CONTENTS
TABLE OF CONTENTS ................................................................................... i
TABLE OF AUTHORITIES ............................................................................ ii
ARGUMENT .................................................................................................... 1
A. The panel majority properly considered relevant evidence
necessary to resolve the plea to the jurisdiction without
reaching the merits. .............................................................................. 4
B. Because Casey does not claim damages recoverable under
section 271.153, the panel majority correctly found that CPS
Energy’s immunity from Casey’s claims was not waived. .................... 6
1. There is no balance due and owed by CPS Energy under
section 271.153(a)(1). ....................................................................7
2. The “additional work” for which Casey seeks another $12
million was already included within contract price for the
fixed-price contract, so Casey is not entitled to recover
under section 271.153(a)(2). ........................................................ 8
C. There is no factual issue whether there is a writing signed by
CPS Energy committing the ratepayers to pay an extra $12
million dollars—it is undisputed that there is no such writing. .......... 11
D. Casey had a full and fair opportunity in the trial court to
develop the record as to immunity; it failed to request a
continuance; and in the absence of written change orders—
which Casey admits do not exist—supplementation would be
futile. .................................................................................................... 12
CONCLUSION ............................................................................................... 13
CERTIFICATE OF COMPLIANCE ................................................................ 14
CERTIFICATE OF SERVICE......................................................................... 14
i
1937549.2/SPSA/22244/0110/083115
TABLE OF AUTHORITIES
Page(s)
CASES
City of San Antonio v. Casey Indus., Inc.,
381 S.W.3d 589 (Tex. App.—San Antonio 2012, pet. denied) .................10
Lubbock Cnty. Water Control and Imp. Dist. v. Church & Akin, LLC,
44 S.W.3d 297 (Tex. 2014) ......................................................................... 1
Sharyland Water Sys. v. City of Alton,
354 S.W.3d 407 (Tex. 2011) ....................................................................... 6
Texas Dept. of Parks & Wildlife v. Miranda,
133 S.W.3d 217 (Tex. 2004) ....................................................................... 5
Tooke v. City of Mexia,
197 S.W.3d 325 (Tex. 2006) ..................................................................... 12
Ulico Gas Co. v. Allied Pilots Ass’n,
262 S.W.3d 773 (Tex. 2008) ..................................................................... 11
Zachry Constr. Corp. v. Port of Houston Auth.,
449 S.W.3d 98 (Tex. 2014) .......................................................... 1, 9, 11, 12
STATUTES
TEX. LOC. GOV’T. CODE § 271.152 .................................................................... 13
TEX. LOC. GOV’T. CODE § 271.153(a)(1). ................................................... 7, 8, 9
TEX. LOC. GOV’T. CODE § 271.153(a)(2)............................................................ 8
TEX. LOC. GOV’T. CODE § 271.153(b)(1) ............................................................ 9
ii
1937549.2/SPSA/22244/0110/083115
ARGUMENT
The Texas Local Government Contract Claims Act does not waive
immunity from suit for damages not recoverable under section 271.153.
The waiver does not depend on the outcome, but it “does require a showing
of a substantial claim that meets the Act’s conditions.” Zachry Constr.
Corp. v. Port of Houston Auth., 449 S.W.3d 98, 109 (Tex. 2014). Casey
contends the panel majority impermissibly considered facts relating solely
to the merits of Casey’s claim and CPS’s affirmative defenses rather than
limiting its review to facts relevant to the trial court’s jurisdiction. Not so.
“[U]nder Chapter 271, the terms of the written contract are
themselves the substance that determines whether immunity is waived.
Lubbock Cnty. Water Control and Imp. Dist. v. Church & Akin, LLC, 44
S.W.3d 297, 304 (Tex. 2014). Here, the contract was a fixed-price contract
under which CPS agreed to pay $85,760.12, and not a penny more. There is
no writing in which CPS Energy agreed to pay an extra $12 million. That in
itself demonstrates that the additional $12 million was not contemplated by
the parties to the contract.
That conclusion is buttressed by other terms of the contract. The
contract charges Casey (the “D/B Contractor”) with the responsibility to act
as the overall construction manager of the contract and oversee
1
1937549.2/SPSA/22244/0110/083115
Wheelabrator’s performance using the “design-build” project delivery
method consistent with a traditional turnkey approach. C.R. 156. Casey is
responsible for delivering the complete and fully operational facility to CPS
Energy on a lump-sum fixed-price basis. C.R. 79. Casey—not CPS Energy—
assumes all risks of delay in the project’s schedule and is responsible for all
costs related to bringing the project back on schedule. C.R. 108. To obtain
a schedule relief change order, the contract requires Casey to show CPS
Energy-caused delay. C.R. 114-15. Casey agreed that it was not entitled to
more time or money for delays caused by Wheelabrator. C.R. 141, 142.
Casey expressly agreed that no adjustment to price or schedule would be
authorized as a result of mistakes relating to Casey or Wheelabrator’s
respective portions of the work. C.R. 118. And although the contract
authorized Casey to request a change order for more time or money if Casey
was not in default itself and a default by Wheelabrator resulted in
impairment of Casey’s work through no fault of Casey, C.R. 135, Casey
never requested or obtained any change orders for the claims for which CPS
Energy sought dismissal. Each of these provisions is just as relevant to
determination of the trial court’s jurisdiction as the one sentence that Casey
plucks out of context (Casey has no responsibility for Wheelabrator’s
obligations).
2
1937549.2/SPSA/22244/0110/083115
As conceded by Casey’s counsel at oral argument:
Casey agreed there was no indication of owner-caused delays;
Casey agreed there were no construction change directives;
Casey agreed there were no actual change orders.
In the absence of any of these facts, Casey’s claims do not fall within
section 271.173 and, hence, there is no claim for damages allowed by section
271.153, and thus no waiver of governmental immunity.
Also without merit is Casey’s contention that CPS’s alleged waiver of
compliance with the change order procedure somehow waived immunity
from suit. This is a red herring. Even if Casey had complied with the
change order procedure in every respect, but CPS Energy still refused to
issue a change order or amend the contract to award Casey another $12
million (i.e., there was no meeting of the minds on the terms of an
amendment), Casey would not be entitled to damages under section 271.153
and, thus, there would be no waiver of immunity.
The court’s jurisdiction does not depend on CPS Energy’s conduct. If
the court has jurisdiction, nothing CPS Energy can do will deprive it of
jurisdiction. Conversely, if the court does not have jurisdiction, there is
nothing CPS Energy can do to give it jurisdiction. Only the Legislature can
determine the jurisdiction of the courts by saying who can sue
3
1937549.2/SPSA/22244/0110/083115
governmental entities. If the legislature says a contractor must have a
properly executed writing to waive immunity from suit, a contractor cannot
sue without one, no matter what CPS Energy says or does. So any factual
issue about whether CPS Energy waived contractual procedures is
immaterial.
To allow a waiver of a written change order procedure to permit a
contractor to recover without a signed writing would defeat the purpose of
the statute. In effect, it would allow a contractor to recover the reasonable
value of its services when the government entity had not agreed to pay, i.e.,
in quantum meruit. It would also frustrate the purpose of the competitive
bidding statute if a contractor could submit the low bid, be awarded a fixed-
price contract, and then recover an additional $12 million when/if that
amount had been included in its original bid, the contractor would never
have been awarded the contract in the first place.
The panel majority got it right. The motion for reconsideration
should be denied.
A. The panel majority properly considered relevant evidence
necessary to resolve the plea to the jurisdiction without
reaching the merits.
Despite Casey’s attempts to convince this Court otherwise, the panel
majority did not improperly consider the merits, rather than limiting its
4
1937549.2/SPSA/22244/0110/083115
review to jurisdictional facts. “If a plea to the jurisdiction challenges the
existence of jurisdictional facts, a court is required to consider relevant
evidence submitted by the parties.” Texas Dept. of Parks & Wildlife v.
Miranda, 133 S.W.3d 217, 226-28 (Tex. 2004). The court takes all evidence
favorable to the nonmovant as true and indulges every reasonable inference
and resolves any doubts in the nonmovant’s favor. Id. at 228. If the
evidence raises a fact issue regarding the jurisdictional issue, then the trial
court cannot grant the plea to the jurisdiction, and the fact issue must be
left to be resolved by the fact finder. Id. However, if the relevant evidence
fails to raise a fact question on the jurisdictional issue or is undisputed,
then the trial court must rule on the plea to the jurisdiction as a matter of
law. Id. There is not the slightest indication that the panel majority
deviated from these standards.
Casey argues that failure to give notice or follow a contract procedure
does not deprive a court of jurisdiction. This is true, but beside the point.
A failure to give notice under an agreement, i.e., to comply with the
provisions of existing contract, is different than a failure to bind a party to
an agreement in the first place, i.e., to obtain an amendment or change
order. Here there is no agreement by CPS Energy to amend the contract to
increase the fixed price by $12 million. Contractual procedures may be
5
1937549.2/SPSA/22244/0110/083115
waived, but subject matter jurisdiction cannot be. Sharyland Water Sys. v.
City of Alton, 354 S.W.3d 407, 413-14 (Tex. 2011). If the Legislature says a
contractor must have a properly executed writing to waive immunity from
suit, a contractor cannot sue without one, even if CPS Energy expressly
agrees in the contract to waive immunity from suit. Allowing a contractor to
recover for additional costs when an owner refuses to issue a change order
would allow massive cost overruns for which the taxpayers could be liable
when no one had authorized the additional work. But the panel majority
did not hold that CPS Energy’s immunity was not waived because Casey
failed to comply with the notice provisions of the contract. Rather, it held
that Casey did not seek damages recoverable under section 271.153.
B. Because Casey does not claim damages recoverable under
section 271.153, the panel majority correctly found that CPS
Energy’s immunity from Casey’s claims was not waived.
Mindful of its obligation to find waivers of governmental immunity
only in “clear and unambiguous language” that leaves “no doubt”— to
accord proper deference to the Legislature’s prerogative to decide whether,
when, and how to waive the government’s immunity—the panel majority
carefully and strictly construed the limitations found in section 271.153.
Contractors can recover three categories of damages under section 271.153:
(1) the balance due and owed by the local governmental
entity under the contract as it may have been amended,
6
1937549.2/SPSA/22244/0110/083115
including any amount owed as compensation for the
increased cost to perform the work as a direct result of
owner-caused delays or acceleration;
(2) the amount owed for change orders or additional
work the contractor is directed to perform by a local
governmental entity in connection with the contract; and
(3) interest as allowed by law.
TEX. LOCAL GOV’T. CODE § 271.153(a)
But contractors cannot recover “consequential damages, except as
expressly allowed under Subsection (a)(1).” Id. § 271.153(b).
1. There is no balance due and owed by CPS Energy
under section 271.153(a)(1).
It is undisputed that Casey was fully paid all sums due under the
lump sum contract except for properly withheld retainage. It is undisputed
that the contract was never amended to increase the price by $12 million. It
is undisputed that there is no amount owed for increased cost “as a direct
result of owner-caused delays;” it is undisputed the delays were caused by
Wheelabrator, not CPS Energy. Casey misunderstands the majority’s
statement that “accordingly any compensation owed to Casey for delays
caused by Wheelabrator does not fall within the scope of Subsection (a)(1)
to 271.153(a).” The reason that Wheelabrator’s default is not within
271.153(a)(1) is because Subsection (a)(1) allows costs caused by owner-
caused delays, and Casey is seeking damages for delays caused by
7
1937549.2/SPSA/22244/0110/083115
Wheelabrator. Thus, Casey is not entitled to damages under section
271.153(a)(1).
2. The “additional work” for which Casey seeks another
$12 million was already included within contract price
for the fixed-price contract, so Casey is not entitled to
recover under section 271.153(a)(2).
There is no amount owed for change orders or additional work CPS
Energy directed Casey to perform. Casey never requested—and CPS Energy
never signed—any change orders for the claims for which CPS Energy
sought dismissal. There was no “additional work” the contractor was
directed to perform by CPS Energy. Casey agreed there were no
construction change directives, and there is no evidence of any directive
from CPS Energy.
Furthermore, the work for which Casey sought $12 million was not
“additional work.” It was work already included in the contract price of the
fixed-price contract. Allowing Casey to recover additional compensation
would not only bypass the change order procedure in the contract, but flatly
contradict its negotiated terms, reallocating the risk of loss in a carefully
negotiated fixed-price contract, depriving CPS Energy of the benefit of its
bargain and imposing on innocent ratepayers costs that they never agreed
to pay.
8
1937549.2/SPSA/22244/0110/083115
In an attempt to avoid section 271.153(b)(1)’s unmistakable
prohibition on the recovery of consequential damages except as expressly
allowed under subsection (a)(1), Casey argues that delay damages were
specifically contemplated by parties in the contract, and thus were direct
damages, not consequential damages. There is absolutely nothing in the
contract that supports that notion. Far from demonstrating that the parties
intended for Casey to recover damages for performing Wheelabrator’s
work, the contract in fact provides just the opposite. Casey agreed that if
additional costs were incurred because of Wheelabrator delays (Section
15.3) or Wheelabrator’s work (Section 9.4), the additional costs were to be
borne by Casey. C.R. 142, 118. Casey was not entitled to recover more time
or money for delays caused by Wheelabrator (C.R. 142), and not entitled to
any adjustment to price as a result of mistakes relating to Wheelabrator’s
work (C.R. 118). Thus, those damages were consequential damages
forbidden by section 271.153(b). Zachry Constr. Corp. v. Port of Houston
Auth., 449 S.W.3d 98, 113 n.71 (Tex. 2014) (“Delay damages are
consequential damages”).
Similarly misguided is Casey’s argument that the provision that
“Casey shall bear no responsibility or liability for [Wheelabrator’s]
obligations …” entitled Casey to additional compensation. The fact that
9
1937549.2/SPSA/22244/0110/083115
Casey did not have to pay CPS Energy for Wheelabrator’s obligations does
not mean that CPS Energy had to pay Casey for Wheelabrator’s obligations.
The inference the dissenting opinion draws—that Casey cured
Wheelabrator’s work because CPS Energy directed it to do so, even though
there is no evidence that is so—is not reasonable. Casey did not perform
Wheelabrator’s work because CPS Energy directed Casey to do so. Casey
performed Wheelabrator’s work because Casey was contractually obligated
to do so at no additional cost to CPS Energy. The contract obligated Casey
to act as overall construction manager of the project and oversee
Wheelabrator’s performance (C.R. 156), to be responsible for delivering a
complete and fully operational facility to CPS Energy on a lump sum, fixed-
price basis (C.R. 79), and to assume all risk of delays in the project schedule
and responsibility for all costs related to bringing the project back on
schedule (C.R. 108). Casey also agreed in the contract that it was not
entitled to more time or money for delays caused by Wheelabrator (C.R.
142) or any adjustment to price as a result of mistakes relating to
Wheelabrator’s work (C.R. 118). This court has already decided that this
contract is a true design-build contract and that Casey and Wheelabrator
were a design-build team, City of San Antonio v. Casey Indus., Inc., 381
S.W.3d 489, 596 (Tex. App.—San Antonio 2012, pet. denied). As Casey
10
1937549.2/SPSA/22244/0110/083115
concedes “under a true design-build contract, under no circumstance would
the design-build contractor be entitled to seek additional compensation
from the owner for a default by a member of the design build-team.” Id. at
594.
C. There is no factual issue whether there is a writing signed
by CPS Energy committing the ratepayers to pay an extra
$12 million dollars—it is undisputed that there is no such
writing.
Assuming for the sake of argument that Casey complied with all
contract procedures governing a request for a change order, it is still
undisputed that Casey did not get one. In the absence of a written change
order, there is nothing signed by the government authority agreeing to pay
Casey additional compensation for curing Wheelabrator’s work. In effect,
Casey is attempting to establish a contract by waiver. However, a contract
cannot be created by waiver. Ulico Gas Co. v. Allied Pilots Ass’n, 262
S.W.3d 773, 779 (Tex. 2008). Allowing Casey to recover without a signed
writing—a change order as required by the contract—defeats the purpose of
governmental immunity. In effect, it allows a contractor to recover the
reasonable value of its services when the government entity has not agreed
to pay (i.e., in quantum meruit).
11
1937549.2/SPSA/22244/0110/083115
D. Casey had a full and fair opportunity in the trial court to
develop the record as to immunity; it failed to request a
continuance; and in the absence of written change orders—
which Casey admits do not exist—supplementation would
be futile.
Casey’s plea that it be given more time to bring forth evidence
creating a factual dispute on jurisdiction should be rejected. This case has
been pending since April, 2008. The parties have conducted discovery for
years, producing over a million pages of documents and taking the
depositions of numerous fact and expert witnesses. Casey had a full and
fair opportunity in the trial court to—and did—develop the record as to
immunity, amend its pleadings, and submit the evidence it chose. Casey
failed to ask for a continuance and failed to tell the trial court—or this
court—what it would prove if it was given more time. It is too late now for
Casey to ask for another opportunity, especially when the undisputed
evidence shows that the dispute is legal, not factual.
Moreover, as the Supreme Court noted in Zachry, the conclusion
reached in Zachry that a local government entity waived sovereign
immunity subject only to the terms and conditions of the Act was reached
in Tooke v. City of Mexia, 197 S.W.3d 325 (Tex. 2006) and was in the
Court’s word “obvious” and “the text of section 271.152 and our decision in
12
1937549.2/SPSA/22244/0110/083115
Tooke ought to have settled the matter.” Zachry Const. Corp. v. Port of
Houston Auth., 449 S.W.3d 98, 107 (Tex. 2014).
In any event, in addition to the fact that Casey is not seeking damages
recoverable under 271.153, Casey does not have a properly executed written
contract in which the local government entity agreed to pay an additional
$12 million. For this additional reason, there is no waiver of governmental
immunity under section 271.152, regardless of what damages Casey seeks
under section 271.153. TEX. LOC. GOV’T. CODE § 271.152.
CONCLUSION
The motion for reconsideration should be denied.
Respectfully submitted,
JUDITH R. BLAKEWAY ANNALYN G. SMITH
State Bar No. 02434400 State Bar No. 18532500
STRASBURGER & PRICE, LLP SCHMOYER REINHARD, LLP
2301 Broadway 17806 IH-10 West, Suite 400
San Antonio, Texas 78215 San Antonio, Texas 78257
Telephone: (210) 250-6000 Telephone: (210) 447-8033
Facsimile: (210) 250-6100 Facsimile: (210) 447-8036
judith.blakeway@strasburger.com asmith@sr-llp.com
By: / S / Judith R. Blakeway
Judith R. Blakeway
ATTORNEYS FOR APPELLANT
CPS ENERGY
13
1937549.2/SPSA/22244/0110/083115
CERTIFICATE OF COMPLIANCE
In accordance with Texas Rule of Appellate Procedure 9.4, the
undersigned certifies that this Response to Motion for Reconsideration En
Banc contains 2,745 words.
/ S / Judith R. Blakeway
Judith R. Blakeway
CERTIFICATE OF SERVICE
The undersigned certifies that a true and correct copy of this
document has been delivered, pursuant to the Texas Rules of Appellate
Procedure on the 31st day of August, 2015, to the following:
ALLEN STEIN & DURBIN, P.C. WATT TIEDER HOFFAR & FITZGERALD,
John C. Howell LLP
SBN 10101650 Christopher A. Wright
6243 IH-10 West, Suite 700 Pro Hac Vice
San Antonio, Texas 78201 1215 Fourth Avenue, Suite 2210
(210) 734-7488 Seattle, Washington 98161
(210) 738-8036 (Fax) (206) 204-5800
jhowell@asdh.com (206) 204-0284 (Fax)
cwright@wattieder.com
HOUSTON DUNN, PLLC
Nissa M. Dunn
SBN 14766450
4040 Broadway, Suite 440
San Antonio, Texas 78209
(210) 775-0880
(210) 826-0075 (Fax)
nissa@hdappeals.com
/S/ Judith R. Blakeway
Judith R. Blakeway
14
1937549.2/SPSA/22244/0110/083115